3 - addmfmt for construction projects
TRANSCRIPT
![Page 1: 3 - ADDMFMT FOR CONSTRUCTION PROJECTS](https://reader034.vdocument.in/reader034/viewer/2022050717/6251add6d233291e0d6a2d53/html5/thumbnails/1.jpg)
CONSTRUCTION OF NEW MUNICPAL SOFTBALL PARK REBID
PROJECT NO.: 08-18-C28-608 BID OPENING DATE: AUGUST 6, 2018 at 4:00 PM
A D D E N D U M N O. 2
Prospective bidders are advised that for purposes of this project, all original bid requirements and Addendum No. 2 requirements as expressed herein shall be considered part of the bid package. As such, bidders are advised to recognize and comply with all aspects of this bid. Please see attached items as noted by project engineer CONTRACTOR IS TO ACKNOWLEDGE ALL ADDENDUMS ON ORIGINAL BID PROPOSAL FORM Signature, Acknowledge Add. #2 Date Company Name (Print/Type Name)
August 2, 2018 Gerardo Noriega, CTPM Date Director of Purchasing & Contracting / All Addenda issued in respect to this project shall be considered official changes to the original bidding documents. It shall be the Respondent(s) responsibility to ensure that all Addenda have been received. Furthermore, respondents are advised that they must recognize, comply with, and recognize all Addendums on bid proposal form. Respondent(s) signature on bid form shall be interpreted as the bidder’s “recognition and compliance to” official changes as outlined by the City of McAllen and as such are made part of the original solicitation/bidding documents.
![Page 2: 3 - ADDMFMT FOR CONSTRUCTION PROJECTS](https://reader034.vdocument.in/reader034/viewer/2022050717/6251add6d233291e0d6a2d53/html5/thumbnails/2.jpg)
Page 1 of 3
AUGUST 02, 2018 AVO 33348.001 ADDENDUM No. 2 SOFTBALL FIELD FACILITIES MUNICIPAL PARK McALLEN, TEXAS This Addendum shall be considered part of the Construction Documents and is issued to change, amplify, add to, delete from, or otherwise explain the plans and specifications. Where provisions of this Addendum differ from those of the original Construction Documents, this Addendum shall take precedence over the original plans and specifications and shall govern. CLARIFICATIONS
1. Revision to Clarification 1 of Addendum No 1: a. As part of the base bid, the existing scoreboards on Fields 1 and 3 are to be utilized. The
base bid also includes the relocation of the scoreboard on Field 2 to the location as shown on Sheet L4.03. The scoreboards on Fields 4, 5 and 6 are also in the base bid. Alternate #4 is to furnish and install new scoreboards for Fields 1, 2 and 3.
2. Revision to Clarification 2 of Addendum No 1: a. Existing scorekeeper’s table on Field 1, Field 2 and Field 3 are to be removed by
Others/City. New scorekeeper’s table and overhead to be furnished and installed by contractor. Refer to Detail 2, Sheet L4.06.
3. Trench drains clarifications: a. BASE BID: Sheet C3.01 Issued on 7-11-2018: Trench drains along the fence line at New
Fields 4, 5 & 6 will be included in base bid. Sheet C3.02 Issued on 7-11-2018: No trench drains along the fence line at New Fields 1, 2, & 3.
b. ALTERNATE #5: Sheet C3.02 Issued on 7-26-2018: Trench drains along the fence line at New Fields 1, 2 & 3 is to be included in Alternate #5.
4. Cover Material and finish for all warm-air dryers of the restroom shall be stainless steel. Refer to enclosed revised Toilet, Bath, and Laundry Accessories specification Section 102800.
QUESTIONS
1. Bidder Question (7/26/2018): a. Question: On sheet A2.1 door schedule doesn’t show overhead coiling counter doors.
Missing size on coiling doors. b. Answer: Concession counter roll-up doors shall be or equal to: Overhead Door Corp.-
Roll Up Counter Door: Model 651 Stainless Steel, Face of Wall Mounted Clear opening = 4’-0” width x 4’-0” height.
2. Bidder Question (7/30/2018): a. Question: Per Addendum #1, the added cupola is it to be priced separately (as an
alternate, or just listed separately, or included in the base price). b. Answer: As per Addendum #1, the added cupola will be priced within the base bid.
3. Bidder Question (7/31/2018): a. Question: RFI Louvers (Attached RFI)
![Page 3: 3 - ADDMFMT FOR CONSTRUCTION PROJECTS](https://reader034.vdocument.in/reader034/viewer/2022050717/6251add6d233291e0d6a2d53/html5/thumbnails/3.jpg)
Page 2 of 3
b. Answer: RUSKIN Co.: EME520MD – 5” Miami Dade Louver with Double Drainable Blades, 47% Free Area, 1,250 fpm Water Penetration. Offers both Wind Driven Rain and Impact-Resistance. Delete the following: Thinline PTAC decorative louver w/ non-drainable blades, Blank Off Panels, Security Bars, Multiple Sill Extensions Provide: Insect Screens (Aluminum: 18-16 mesh, mill finish, .011 inch wire, alum. frame) Louver Finish: 2 Coat - 70% PVDF painted finish (Color to be selected by City of McAllen) Refer to enclosed answer from BSG Architects
4. Bidder Question (8/1/2018): a. Question: Top rail for the baseball fields it is showing a 2 3/8”….There is no rail
ends or loop caps for that rail. Do you want it welded to the line post or can we install 1 5/8” top rail which is the normal way to install a fence?
b. Answer: All top rails for field fences shall be 1 5/8” in diameter with rail end cup to match. Poly-Cap is to remain 4½” in diameter. Refer to attached revised Sheet L4.01.
5. Bidder Question (8/2/2018): a. Question: Can you please clarify if the base bid includes the new scoreboards for
Fields 1, 2 and 3 and if the alternate includes Fields 4, 5 and 6. b. Answer: Clarification 1 on Addendum No 1 is incorrect, refer to Clarification 1 on
current Addendum above. TECHNICAL SPECIFICATIONS
1. Specification 102800 Toilet, Bath, and Laundry Accessories, revised warm-air dryer cover material to be stainless steel.
PLAN SHEETS
1. Civil: Sheet C0.04 Coordination with AEP for the relocation of the existing light pole located at the south entrance is to be included in base bid. AEP will provide relocation services. Existing curb and gutter/pavement at both north and south entrances are to be sawcut, replaced and regarded as needed by contractor. This work needs to be included in base bid. Existing outfield fences for Existing Baseball Field 2 & 4 (as labeled on sheet C0.04) will remain in place and be utilized for the proposed softball fields’ outfield fencing.
2. Landscape: Sheet: L4.01 Revised top rails on all softball outfield fence details to be 1 5/8” in diameter. Revised Details 4, 5 and 6.
![Page 4: 3 - ADDMFMT FOR CONSTRUCTION PROJECTS](https://reader034.vdocument.in/reader034/viewer/2022050717/6251add6d233291e0d6a2d53/html5/thumbnails/4.jpg)
Page 3 of 3
Sub-bidders are hereby notified that this addendum shall be incorporated in their proposals, and it shall be construed that sub-bidders’ proposals shall reflect with full knowledge, all items, changes and modifications to the Contract Documents herein specified. NOTE: This form must be filled out completely (see section below) and submitted with your Bid Proposal. WARNING: Failure of an Offeror to acknowledge receipt of this Addendum, as described herein, may result in REJECTION OF THE OFFER. ACKNOWLEDGE RECEIPT OF ADDENDUM NO.2 OFFEROR AUTHORIZED SIGNATURE OFFEROR PRINTED NAME COMPANY NAME
![Page 5: 3 - ADDMFMT FOR CONSTRUCTION PROJECTS](https://reader034.vdocument.in/reader034/viewer/2022050717/6251add6d233291e0d6a2d53/html5/thumbnails/5.jpg)
AUSTIN 11525 Stonehollow Drive, Suite 150 Austin, TX 78758 P: (512) 452-2500 F: (512) 452-3794
Texas Air Products, Ltd.
SAN ANTONIO 11122 Gordon Road San Antonio, TX 78216 P: (210) 495-8100 F: (210) 495-8200
Serving South-Central Texas Since 1983
WESLACO 406 S. Nebraska, Suite B Weslaco, TX 78596 P: (956) 447-2500 F: (956) 447-2300
www.txap.com 09/2011
REQUEST FOR INFORMATION MEMO Date: 7/31/2018 Attn: Gerardo Noriega Email: [email protected] Bid date: 8/6/18
PROJECT: McAllen Softball Field Facilities
______________________________________________________________________
PRODUCT: Louvers There are discrepancies within the louver spec. The spec notes the louvers are “Thinline PTAC” decorative louvers with non-drainable blades; however, the basis of design model listed, ELF6375DX, is a standard 6” drainable louver. Additionally, the accessories noted on page 6 list blank off panels, security grilles, and multiple extended sill and louver finish types. Please clarify what type louver and what type accessories and finishes are required for these louvers. S1.00 notes the wind speed is 138 mph. We offer the following recommendations for an area with increased wind load.
ELF6375DX - 6” Standard Drainable Louver, 57% Free Area, 1,023 fpm Water Penetration. Not impact or Wind-Driven Rain Resistant.
ELF6375DFL – 6” Drainable Louver, Florida Approved for 50PSF Windload, 57% Free Area, 1,023 fpm Water Penetration. Not Impact or Wind-Driven Rain Resistant.
ELF6375DXD – 6” Drainable Miami Dade Louver, 57% Free Area, 1,023 fpm water penetration, +/-148 PSF Windload. Impact-Resistant.
EME520MD – 5” Miami Dade Louver with Double Drainable Blades, 47% Free Area, 1,250 fpm Water Penetration. Offers both Wind Driven Rain and Impact-Resistance.
Please let me know if you would like any data sheets for these proposed louver models. Thank you for your assistance, Rebecca Wilbanks Texas Air Products [email protected]
Delete the following: Thinline PTAC decorative louver w/ non-drainable blades, Blank Off Panels, Security Bars, Multiple Sill Extensions Provide: Insect Screens (Aluminum: 18-16 mesh, mill finish, .011 inch wire, alum. frame) Louver Finish: 2 Coat - 70% PVDF painted finish
![Page 6: 3 - ADDMFMT FOR CONSTRUCTION PROJECTS](https://reader034.vdocument.in/reader034/viewer/2022050717/6251add6d233291e0d6a2d53/html5/thumbnails/6.jpg)
TOILET, BATH, & LAUNDRY ACCESSORIES 102800 - 1
SECTION 102800
TOILET, BATH, AND LAUNDRY ACCESSORIES
PART 1 - GENERAL
1.1 RELATED DOCUMENTS
A. Drawings and general provisions of the Contract, including General and Supplementary Conditions and Division 01 Specification Sections, apply to this Section.
1.2 SUMMARY
A. Section Includes:
1. Public-use washroom accessories. 2. Private-use bathroom accessories. 3. Warm-air dryers. 4. Childcare accessories. 5. Underlavatory guards. 6. Custodial accessories.
1.3 COORDINATION
A. Coordinate accessory locations with other work to prevent interference with clearances required for access by people with disabilities, and for proper installation, adjustment, operation, cleaning, and servicing of accessories.
B. Deliver inserts and anchoring devices set into concrete or masonry as required to prevent delaying the Work.
1.4 ACTION SUBMITTALS
A. Product Data: For each type of product.
1. Include construction details, materials description, dimensions of individual components and profiles, and finishes.
2. Include anchoring and mounting requirements, including requirements for cutouts in other work and substrate preparation.
3. Include electrical characteristics.
B. Samples: Full size, for each exposed product and for each finish specified.
1. Approved full-size samples will be returned and may be used in the Work.
![Page 7: 3 - ADDMFMT FOR CONSTRUCTION PROJECTS](https://reader034.vdocument.in/reader034/viewer/2022050717/6251add6d233291e0d6a2d53/html5/thumbnails/7.jpg)
Softball Field Facilities Municipal Park McAllen, Texas
TOILET, BATH, & LAUNDRY ACCESSORIES 102800 - 2 Addendum No 2
C. Product Schedule: Indicating types, quantities, sizes, and installation locations by room of each accessory required.
1. Identify locations using room designations indicated. 2. Identify accessories using designations indicated.
1.5 INFORMATIONAL SUBMITTALS
A. Sample Warranty: For manufacturer’s special warranty.
1.6 CLOSEOUT SUBMITTALS
A. Maintenance Data: For accessories to include in maintenance manuals.
1.7 WARRANTY
A. Manufacturer's Special Warranty for Mirrors: Manufacturer agrees to repair or replace mirrors that fail in materials or workmanship within specified warranty period.
1. Failures include, but are not limited to, visible silver spoilage defects.
2. Warranty Period: 15 years from Date of Substantial Completion.
PART 2 - PRODUCTS
2.1 PERFORMANCE REQUIREMENTS
A. Electrical Components, Devices and Accessories: Listed and labeled as defined in NFPA 70, by a qualified testing agency, and marked for intended location and application.
2.2 PUBLIC-USE WASHROOM ACCESSORIES
A. Source Limitations: Obtain public-use washroom accessories from single source from single manufacturer
B. Toilet Tissue (Jumbo-Roll) Dispenser (TP):
1. Manufacturers: Subject to compliance requirements, provide products by one of the following available manufacturers offering products that may be incorporated into the Work include, but are not limited to, the following: a. American Specialties, Inc. b. Bobrick Washroom Equipment, Inc. c. Bradley Corporation
![Page 8: 3 - ADDMFMT FOR CONSTRUCTION PROJECTS](https://reader034.vdocument.in/reader034/viewer/2022050717/6251add6d233291e0d6a2d53/html5/thumbnails/8.jpg)
Softball Field Facilities Municipal Park McAllen, Texas
TOILET, BATH, & LAUNDRY ACCESSORIES 102800 - 3 Addendum No 2
2. Description: Two-roll unit with sliding panel to expose another roll. 3. Mounting: Surface mounted 4. Capacity: 9 or 10-inch diameter rolls. 5. Material and Finish: Stainless steel, No. 4 finish (satin). 6. Lockset: Tumbler Type 7. Refill Indicator: Pierced slots at front.
C. Liquid-Soap Dispenser (SD):
1. Manufacturers: Subject to compliance requirements, provide products by the following available manufacturers offering products that may be incorporated into the Work include, but are not limited to, the following: a. AJW Architectural Products b. American Specialties, Inc.; Model #9343 c. Bobrick Washroom Equipment, Inc. d. Bradley Corporation
2. Description: Designed for dispensing antibacterial soap in liquid or lotion form. 3. Mounting: Horizontally oriented, surface mounted. 4. Capacity 48 fluid oz. 5. Materials: Plastic valve body & push button and stainless steel (type 304)
reservoir. 6. Lockset: Tumbler type. 7. Refill Indicator: Window type.
D. Grab Bar:
1. Manufacturers: Subject to compliance requirements, provide products by the following available manufacturers offering products that may be incorporated into the Work include, but are not limited to, the following: a. American Specialties, Inc. b. Bobrick Washroom Equipment, Inc. c. Bradley Corporation
2. Mounting: Flanges with concealed fasteners. 3. Material: Stainless steel, 0.05 inch (1.3 mm) thick.
a. Finish: Smooth, No. 4 finish (satin) on ends and slip-resistant texture in grip area.
4. Outside Diameter: 1-1/2 inches (38 mm). 5. Configuration and Length: As indicated on Drawings.
E. Mirror Unit:
![Page 9: 3 - ADDMFMT FOR CONSTRUCTION PROJECTS](https://reader034.vdocument.in/reader034/viewer/2022050717/6251add6d233291e0d6a2d53/html5/thumbnails/9.jpg)
Softball Field Facilities Municipal Park McAllen, Texas
TOILET, BATH, & LAUNDRY ACCESSORIES 102800 - 4 Addendum No 2
1. Manufacturers: Subject to compliance requirements, provide products by the following available manufacturers offering products that may be incorporated into the Work include, but are not limited to, the following: a. AJW Architectural Products b. American Specialties, Inc.; Model #9343 c. Bobrick Washroom Equipment, Inc. d. Bradley Corporation
2. Frame: Stainless-steel channel.
a. Corners: Welded and ground smooth. 3. Hangers: Produce rigid, tamper- and theft-resistant installation, using method
indicated below. a. Wall bracket of galvanized steel, equipped with concealed locking devices
requiring a special tool to remove.
4. Size: As indicated on Drawings.
2.3 WARM-AIR DRYERS
A. Source Limitations: Obtain warm-air dryers from single source from single manufacturer.
B. Warm-Air Dryer
1. Manufacturers: Subject to compliance requirements, provide products by the following available manufacturers offering products that may be incorporated into the Work include, but are not limited to, the following:
a. American Dryer, Inc. b. American Specialties, Inc. c. Bobrick Washroom Equipment, Inc. d. Bradley Corporation. e. Sloan Valley Company f. World Dryer Corporation
2. Description: Standard-speed, warm-air hand dryer. 3. Mounting: Surface mounted, with low-profile design. 4. Operation: Electronic-sensor activated with timed power cut-off switch.
a. Operation Time: 30 to 40 seconds
5. Cover Material and Finish: Stainless Steel. 6. Electrical Requirements: As indicated in drawings.
![Page 10: 3 - ADDMFMT FOR CONSTRUCTION PROJECTS](https://reader034.vdocument.in/reader034/viewer/2022050717/6251add6d233291e0d6a2d53/html5/thumbnails/10.jpg)
Softball Field Facilities Municipal Park McAllen, Texas
TOILET, BATH, & LAUNDRY ACCESSORIES 102800 - 5 Addendum No 2
2.4 CHILDCARE ACCESSORIES
A. Source Limitations: Obtain childcare accessories from single source from single manufacturer.
B. Diaper-Changing Station:
1. Manufacturers: Subject to compliance with requirements, available manufacturers offering products that may be incorporated into the Work include, but are not limited to, the following:
a. American Specialties, Inc. b. Diaper Deck & Company, Inc. c. Foundations Children’s Products d. GAMCO Specialty Accessories; a division of Bobrick. e. Koala Kare Products f. SafeStrap Company, Inc. (SSC, Inc.)
2. Description: Horizontal unit that opens by folding down from stored position and with child-protection strap. a. Engineered to support minimum of 250-lb static load when opened.
3. Mounting: Surface mounted, with unit projecting not more than 4 inches from wall when closed.
4. Operation: By pneumatic shock-absorbing mechanism. 5. Material and Finish: HDPE in manufacturer's standard color. 6. Liner Dispenser: Built in.
2.5 UNDERLAVATORY GUARDS
A. Underlavatory Guard: 1. Manufacturers: Subject to compliance with requirements, provide products by the
following available manufacturers offering products that may be incorporated into the Work include, but are not limited to, the following: a. Plumberex Specialty Products, Inc. b. Truebro by IPS Corporation.
2. Description: Insulating pipe covering for supply and drain piping assemblies that prevent direct contact with and burns from piping; allow service access without removing coverings.
3. Material and Finish: Antimicrobial, molded plastic, white.
2.6 CUSTODIAL ACCESSORIES
A. Source Limitations: Obtain childcare accessories from single source from single manufacturer
B. Mop and Broom Holder:
![Page 11: 3 - ADDMFMT FOR CONSTRUCTION PROJECTS](https://reader034.vdocument.in/reader034/viewer/2022050717/6251add6d233291e0d6a2d53/html5/thumbnails/11.jpg)
Softball Field Facilities Municipal Park McAllen, Texas
TOILET, BATH, & LAUNDRY ACCESSORIES 102800 - 6 Addendum No 2
1. Manufacturers: Subject to compliance with requirements, provide products by the following available manufacturers offering products that may be incorporated into the Work include, but are not limited to, the following: a. AJW Architectural Products. b. American Specialties, Inc. c. Bobrick Washroom Equipment, Inc. d. Bradley Corporation.
2. Description: Unit with shelf, hooks, holders, and rod suspended beneath shelf. 3. Length: 36 inches . 4. Hooks: Four. 5. Mop/Broom Holders: three, spring-loaded, rubber hat, cam type. 6. Material and Finish: Stainless steel, No. 4 finish (satin).
a. Shelf: Not less than nominal 0.05-inch- (1.3-mm-) thick stainless steel. b. Rod: Approximately 1/4-inch- (6-mm-) diameter stainless steel.
2.7 MATERIALS
A. Stainless Steel: ASTM A 666, Type 304, 0.031-inch (0.8-mm) minimum nominal thickness unless otherwise indicated.
B. Brass: ASTM B 19, flat products; ASTM B 16/B 16M, rods, shapes, forgings, and flat products with finished edges; or ASTM B 30, castings.
C. Steel Sheet: ASTM A 1008/A 1008M, Designation CS (cold rolled, commercial steel), 0.036-inch (0.9-mm) minimum nominal thickness.
D. Galvanized-Steel Sheet: ASTM A 653/A 653M, with G60 (Z180) hot-dip zinc coating.
E. Galvanized-Steel Mounting Devices: ASTM A 153/A 153M, hot-dip galvanized after fabrication.
F. Fasteners: Screws, bolts, and other devices of same material as accessory unit and tamper-and-theft resistant where exposed, and of galvanized steel where concealed.
G. Chrome Plating: ASTM B 456, Service Condition Number SC 2 (moderate service).
H. Mirrors: ASTM C 1503, Mirror Glazing Quality, clear-glass mirrors, nominal 6.0 mm thick.
2.8 FABRICATION
A. General: Fabricate units with tight seams and joints, and exposed edges rolled. Hang doors and access panels with full-length, continuous hinges. Equip units for concealed anchorage and with corrosion-resistant backing plates.
![Page 12: 3 - ADDMFMT FOR CONSTRUCTION PROJECTS](https://reader034.vdocument.in/reader034/viewer/2022050717/6251add6d233291e0d6a2d53/html5/thumbnails/12.jpg)
Softball Field Facilities Municipal Park McAllen, Texas
TOILET, BATH, & LAUNDRY ACCESSORIES 102800 - 7 Addendum No 2
B. Keys: Provide universal keys for internal access to accessories for servicing and resupplying. Provide minimum of six keys to Owner's representative.
PART 3 - EXECUTION
3.1 INSTALLATION
A. Install accessories according to manufacturers' written instructions, using fasteners appropriate to substrate indicated and recommended by unit manufacturer. Install units level, plumb, and firmly anchored in locations and at heights indicated.
B. Grab Bars: Install to withstand a downward load of at least 250 lbf (1112 N), when tested according to ASTM F 446.
3.2 ADJUSTING AND CLEANING
A. Adjust accessories for unencumbered, smooth operation. Replace damaged or defective items.
B. Remove temporary labels and protective coatings.
C. Clean and polish exposed surfaces according to manufacturer's written instructions.
END OF SECTION
![Page 13: 3 - ADDMFMT FOR CONSTRUCTION PROJECTS](https://reader034.vdocument.in/reader034/viewer/2022050717/6251add6d233291e0d6a2d53/html5/thumbnails/13.jpg)
N
CIT
Y O
F M
cA
LLE
N
Sheet Number
Sheet Title
Checked By:
Drawn By:
Project No.:
Issued:
No.
Date
Description
Revisio
n
Scale:
MA
NN-2
347
MC
A...\
HA
LFF_
MO
N_P
EN
TA
BLE.T
BL
PD
F_2
D_
MO
N_
MW
_C
R_300.plt
Desig
n
I:\3
3000s\3
3348\0
01\C
AD
D\S
heets\C
0.0
4-D
P-3
3348.d
gn
HA
LFF
ah2961
3:3
2:1
4 P
M8/2/2
018
MU
NICIP
AL P
AR
KS
OF
TB
ALL FIE
LD F
ACILITIE
S
Mc
ALLE
N, T
EX
AS
33348.001
FC
RM
AS NOTED
TB
PE FIR
M #
F-3
12
FA
X (956) 664-0
282
TE
L (956) 664-0
286
Mc
ALLE
N, T
X 7
8503
5000 W
ES
T M
ILIT
AR
Y H
WY, S
UIT
E 1
00
July 2018
1007550250
SCALE 1"=100' (11 X 17)SCALE: 1"=50' (22 X 34)
TBM #1
TBM #2
(NAD83)
E= 1070579.89
N= 16606328.72
ELEVATION= 115.80 (NAVD88)
N. BICENTENNIAL BLVD.
CORNER OF TAMARACK AVENUE AND
SET ON CURB INLET AT THE SOUTHWEST
(NAD83)
E= 1070065.94
N= 16605622.31
ELEVATION= 115.16 (NAVD88)
AND N. BICENTENNIAL BLVD.
THE INTERSECTION OF QUINCE ST.
LOT LIMITS , APPROXIMATELY 450' WEST OF
SET ON CURB INLET WITHIN PARK'S PARKING
TBM #1
TBM #2
(NAD83)
E= 1070579.89
N= 16606328.72
ELEVATION= 115.80 (NAVD88)
N. BICENTENNIAL BLVD.
CORNER OF TAMARACK AVENUE AND
SET ON CURB INLET AT THE SOUTHWEST
(NAD83)
E= 1070065.94
N= 16605622.31
ELEVATION= 115.16 (NAVD88)
AND N. BICENTENNIAL BLVD.
THE INTERSECTION OF QUINCE ST.
LOT LIMITS , APPROXIMATELY 450' WEST OF
SET ON CURB INLET WITHIN PARK'S PARKING
TBM #1
TBM #2
(NAD83)
E= 1070579.89
N= 16606328.72
ELEVATION= 115.80 (NAVD88)
N. BICENTENNIAL BLVD.
CORNER OF TAMARACK AVENUE AND
SET ON CURB INLET AT THE SOUTHWEST
(NAD83)
E= 1070065.94
N= 16605622.31
ELEVATION= 115.16 (NAVD88)
AND N. BICENTENNIAL BLVD.
THE INTERSECTION OF QUINCE ST.
LOT LIMITS , APPROXIMATELY 450' WEST OF
SET ON CURB INLET WITHIN PARK'S PARKING
TBM #1
TBM #2
(NAD83)
E= 1070579.89
N= 16606328.72
ELEVATION= 115.80 (NAVD88)
N. BICENTENNIAL BLVD.
CORNER OF TAMARACK AVENUE AND
SET ON CURB INLET AT THE SOUTHWEST
(NAD83)
E= 1070065.94
N= 16605622.31
ELEVATION= 115.16 (NAVD88)
AND N. BICENTENNIAL BLVD.
THE INTERSECTION OF QUINCE ST.
LOT LIMITS , APPROXIMATELY 450' WEST OF
SET ON CURB INLET WITHIN PARK'S PARKING
BENCHMARKS PROVIDED BY CITY OF McALLEN
PP
GM
CV
SS
LP.
V
VV
V
V
V
SPSP
SP SP SP SP
SP
SP
SP
SPSP
SP
SP
SP
SP
SP
SP
SPSP SP
SPSP
SP
SP
SP
SP
SP
SP
SP
VV
V
SP
SP
SP
SP
SP
V
V
VV
VV
V
V
VVV
SP
V
V
VV
V
V
V
WMWM
WVWVWV
WVWV
VV
V
LP
LP
V
V
V
V
V
LP
LP
V
VV
V
V
V VV
V
V
V
VV
V
V
V
V
V
LP
SP
VV
VV
LPPP LP
LP
LP
V
EE
E
E
SP
VV
WV
FIBER OPTIC
MARKER POST
DYH
DYHLP
LP
LP
LP
V
VV
V V
V
LP
LP
VV
LP
LP
SP
V
LP
SS
LP.
V
V
V
V
V
LP
LP
V
SS
LP
EB
EB
EB
EBLP
LP
LP
LP
LP
VV
V
VV
V
VV
SP
V
VVV
RESTROOM
TAMARACK AVE.
CONC
LP
LP
BASEBALL FIELD 1BASEBALL FIELD 1BASEBALL FIELD 1BASEBALL FIELD 1
BLE
AC
HE
RS
BASEBALL FIELD 1
TAMARACK AVENUETAMARACK AVENUE( 60' R.O.W. )
SCOREBOARD
BASEBALL FIELD 4
SANITARY SEWER MANHOLETOP= 117.33INV.=
SCOREBOARD
SCOREBOARD
WIT
H C
AN
OP
Y
BLE
AC
HE
RS
WIT
H C
AN
OP
Y
BASEBALL FIELD 2
SCOREBOARD
BLEACHERS
WITH CANOPY
WITH CANOPY
BLEACHERS
BLEACHERS
WITH CANOPY
WITH CANOPY
BLEACHERS
WIT
H C
AN
OP
Y
BLE
AC
HE
RS
BLE
AC
HE
RS
WIT
H C
AN
OP
Y
BASEBALL FIELD 3
SCOREBOARD
COVEREDPAVILLION
SANITARY SEWER MANHOLETOP= 116.92
FL.= 106.92 N/S FL.= 111.32 E
PICNICPICNIC
TABLES(CONCRETE)
IRON FENCEWROUGHT
IRON FENCEWROUGHTIRON FENCE
ASPHALT PARKING LOT
CURB AND GUTTER
CURB AND GUTTER CURB AND GUTTER
CURB AND GUTTER
IRON FENCEIRON FENCE
WROUGHT
BE
NC
H
BENCH
4' SIDEWALK
PLAYGROUND
4' SIDEWALK
4' SID
EW
AL
K
IRON FENCE
WROUGHT
PICNICPICNIC
TABLES(CONCRETE)
BE
NC
HB
EN
CH
BE
NC
H
PLAYGROUND
4' SIDEWALK
4' SIDEWALK
ASPHALT PARKING LOT
VALLEY GUTTER
IRON FENCEWROUGHT
IRON FENCE
WROUGHTWROUGHT
ASPHALT PARKING LOT
VALLEY GUTTER
IRON FENCE
WROUGHT
IRON FENCE
WROUGHTWROUGHT
CURB AND G
UTTERCURB A
ND GUTTER
FL. = 111.17
TOP = 115.17STORM INLET
ASPHALT PARKING LOT
WROUGHTIRON FENCE
IRON FENCEWROUGHT
GRATE
STORMINLET
TOP= 114.00
FL.= 111.20
CHAINLINK FENCE
FIBER OPTIC
MARKER POST
FIBER OPTIC
WR
OU
GH
T I
RO
N F
EN
CE
WR
OU
GH
T I
RO
N F
EN
CE
WROUGHT IRON FENCE
WATER TOWER
SITE
WR
OU
GH
T I
RO
N F
EN
CE
WROUGHT IRON FENCE
SANITARY SEWER MANHOLETOP= 117.82
FL.= 112.82
TABLES
PICNIC
(CONCRETE)
WR
OU
GH
T I
RO
N F
EN
CE
WR
OU
GH
T I
RO
N F
EN
CE
BENCH BENCH
TRANSFORMER
ELECTRICALELECTRICAL
ELECTRICALAREA
TRAFFIC
SIGNAL BOX
POLEPOLECAMERA
POLESERVICE
QUINCE AVENUE( 60' R.O.W. )
GRATE
STORMSTORMINLET
TOP= 114.55
FL.= 112.20
ELECTRICAL
BOXBOX
FLAG
POLE
ELECTRICAL
BOX
ELECTRICAL
BOX
PP
PP
114.5
114.5
114.5
114.51
14.5
114.5
114.5
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.011
5.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.0
115.5
115.5
115.5
115.5
115.5
115.5
115.5 115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
115.5
116.0
116.0
116.0
116.0
116.0
116.0
116.0
116.0
116.
0
116.0
116.0116.0
116.0
116.0
116.0
116.0
116.0
116.0
116.0
116.0
116.0
116.0
116.0
116.0
116.0
116.0 116.0
116.0
116.0
116.0
116.0
116.0116.0
116.0
116.0
116.0
116.0
116.0116.0
116.0
116.0 116
.0
116.0
116.5
116.5
116.5
116.5
116.5
116.5
116.5
116.5
116.5
116.5
116.5
116.
5
116.5
116.5
116.5
116.5
116.5
116.5
116.5
116.5
116.5
116.5
116.5
116.5
116.5
116.5116.5
116.5
116.5116.5
116.5116.5116.5
116.5
116.5
116.5
116.5
116.5
116.5
116.5
116.5
116.5
116.5
116.5
116.5
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.0117.0
117.0
117.0
117.0
117.0
117.0
117.0
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
117.5
118.0
118.0
118.0
118.0
118.0
118.0
118.0
118.0
118.0
118.0
118.0
118.0
118.0
118.0
118.0
118.0
118.0
118.0
118.0
118.0
118.0
118.5
118.5
118.5
118.5
118.5
118.5
118.5
118.5
118.5
118.5
118.5
118.5
118.5
118.5
118.5
118.5
119.0
119.0
119.0
119.0
119.0
119.0
119.0
119.0
DYH
x x
D
x x
1
2
2
2
2
2
2
C0.04
LEGEND
LIGHT POLE
MANHOLE DRAIN
WATER METER
ELECTRICAL BOX
DOWN GUY
SPRINKLER
INLET
TRAFFIC SIGN
ALAMO TREE
TRAFFIC SIGNAL BOX
WATER VALVE
POWER POLE
CONTROL VALVE
FIRE HYDRANT
FRESNO TREE
MESQUITE TREE
SIGN
PALM TREE
TELEPHONE MARKER
GAS METER
TV CABLE BOX
TRANSFORMER
FIELD DRAIN/GRATED INLET
SANITARY SEWER MANHOLE
FENCE LINE
WROUGH IRON FENCE
DRAINAGE MANHOLE
LAMP POST
JUNCTION BOX
WATER VALVE MARKER
WATER LINE
GAS LINE
SAN. SEW. LINE
DRAINAGE LINE
TELEPHONE LINE
IRRIGATION LINE
G
W
S
D
T
IR
EBONY TREE
V
E
WM
SP
SM
SS
WM
C
TR
GM
T
WV
AREA OF DEMOLITION
TBM #1
(TYP.)
TO BE REMOVED
EXIST. TREES
BY OTHERS
TO BE REMOVED
EXIST.STORM LINE
PERFORMED BY OTHERS
CAP EXIST. STORM LINE
BY OTHERS
TO BE REMOVED
EXIST.STORM INLET
WILL REMAIN IN PLACE
EXIST. SHADE STRUCTURES
BY OTHERS
PERFORMED
SEWER
CAP EXIST.
REPLACED BY CONTRACTOR
TO BE SAWCUT BY OTHERS &
EXIST. CURB AND GUTTER/PAVEMENT
TRANSFORMER INFORMATION.
REFER TO ELECTRICAL PLANS FOR NEW
WITH CLIENT & AEP FOR NEW TRANSFORMER.
REMAIN IN PLACE. CONTRACTOR TO COORDINATE
EXIST. ELECTRICAL TRANSFORMER PAD IS TO
BY OTHERS.
BE REMOVED AND RELOCATED
AND APPURTENANCES ARE TO
EXIST. BASKETBALL PAVILION
FOR FURTHER DIRECTION.
IRRIGATION PLANS
WITH THE CITY AND REFER TO
IS TO COORDINATE
BY OTHERS. CONTRACTOR
IS TO BE REMOVED (TYP.)
EXIST. IRRIGATION SYSTEM
BY OTHERS.
IS TO BE DEMOLISHED
CONCRETE PAD
EXIST. BASKETBALL
OTHERS.
AND RECONSTRUCTED BY
DISMANTLED, RELOCATED
EQUIPMENT IS TO BE
EXIST. PLAYGROUND
BY OTHERS.
IS TO BE DEMOLISHED
EXIST. FLATWORK
BY OTHERS
TO BE REMOVED
EXIST.STORM INLET
OF TRANSFORMER
WITH CITY AND AEP ON REMOVAL
CONTRACTOR TO COORDINATE
E=1069795.61
N=16606383.45
E=1069965.23
N=16606358.17
(REFER TO LANDSCAPE PLANS)
NEW FIELD BY CONTRACTOR.
ARE TO BE REMOVED & RELOCATED TO
EXIST. SHADE STRUCTURES AND BLEACHERS
6. COORDINATE WITH IRRIGATION PLANS FOR ADDITIONAL IRRIGATION INFORMATION.
5. COORDINATE WITH LANDSCAPE PLANS FOR ADDITIONAL TREES THAT MAY NEED REMOVAL
TO PROVIDE CERTIFIED WEIGHT TICKETS FOR PAYMENT OF THIS ITEM. (PER TON) FOR THIS ITEM. THE OWNER WILL REQUIRE THE CONTRACTOR TO A DEPTH OF FIVE (5) FEET. BIDDERS SHALL PROVIDE A UNIT COST RESPONSIBLE FOR REMOVAL AND DISPOSAL OF SAID FOUNDATIONS CONCRETE FOUNDATIONS WITH REBAR. THE CONTRACTOR WILL BE4. DURING CONSTRUCTION THE CONTRACTOR MAY ENCOUNTER BURIED
REUSED.
3. POLES AND BASES TO BE REMOVED. SIGNS TO BE SALVAGED AND
AND CONCRETE SIDEWALK AS REQUIRED. PAVEMENT , BASE MATERIAL, SUBGRADE, CURB & GUTTER, WHEEL STOPS2. PAVEMENT REMOVAL IS INCLUDING, BUT NOT LIMITED TO, ASPHALT
BE DISPOSED IN A LEGAL MANNER AT THE CONTRACTOR'S EXPENSE.1. ALL MATERIAL CALLED OUT TO BE REMOVED BY THE CONTRACTOR SHALL
NOTES:
AND RELOCATED BY CONTRACTOR
EXIST. SCOREBOARD TO BE REMOVED
17-2
6-2
018
Addendu
m N
o.1
2Addendu
m N
o.2
8-2-2
018
TO REMAIN IN PLACE
EXIST. OUTFIELD FENCE
TO REMAIN IN PLACE
EXIST. OUTFIELD FENCE
REGRADED AS NEEDED BY CONTRACTOR
SAWCUT, REPLACED AND
EXIST. CURB AND GUTTER/PAVEMENT IS TO BE
LEGAL MANNER.
PROPERLY DISPOSED OF IN A
SHALL BE REMOVED AND
OR IMPACT NEW WORK
THIS PLAN, THAT CONFLICT
OTHER THAN SHOWN ON
REMAINING,
CONTRACT. ANY ITEMS
MCALLEN UNDER SEPARATE
PROVIDED BY CITY OF
DEMOLITION BEING
DEMOLITION PLANREFER TO ELECTRICAL PLANS
OF THE EXISTING LIGHT POLE.
CLIENT AND AEP FOR THE RELOCATION
CONTRACTOR TO COORDINATE WITH
![Page 14: 3 - ADDMFMT FOR CONSTRUCTION PROJECTS](https://reader034.vdocument.in/reader034/viewer/2022050717/6251add6d233291e0d6a2d53/html5/thumbnails/14.jpg)