agreement for vatika
TRANSCRIPT
-
7/29/2019 Agreement for Vatika
1/4
This agreement is made on this 20.09.2013 between Payonidhi Kasliwal s/o
Late sh. Kamal Chand Kasliwal r/o Kamal Ratan enclave, Vatika Road, Vatika
Jaipur (hereinafter called the Owners) and GLOBAL BUILDSTATE PROJECT
PRIVATE LIMITED having its registered office at h-17, Gautam Marg, Shyam
Nagar, Jaipur-through its director Sh. Vikas Garg s/o Sh. R.K Garg party of the
Second Part (hereinafter called the Contractors).
The Owner is willing to get the construction and erection of the complex
completed as specified in clause no. 2 of this Agreement (hereinafter call the
specified work), by the contractor, who is willing to carry out the said specified
work, on the terms and conditions mentioned below.
The contractor had agreed with the Owner to start construction work at said
premises vide Work Order letter 10th
August 2011 for which both the parties
having already agreed have now entered into this written agreement on following
terms and conditions:
TERM OF WORK
1. That the contractor has commenced the execution of the specified work
w.e.f 20h June ,2013 and shall completely finish the civil works of the said
project within period of 6 (Six) months from the date of commencement i.e
20.06.2013.
2. That in case of delay in completion of the specified work, the period
specified in clauses-I above the Owners shall be entitled to deduct
liquidated damages Rs. 1,000/- (Rupees One Thousand Only) per day
with a maximum limit of Rs. 25,000/- after giving a grace period of 30
days.
3. In case the project is temporarily or permanently abandoned by the
contractor he is liable pay a fine of Rs 25000.
4. Time delay from the side of Owners/unforeseen delay/ legal or JDA
problem will not be counted in the stipulated time - 6 (Six) months.
SCOPE OF WORK
Refer to the tender for a detailed list of tasks to be completed.
MATERIALS and RESOURCES
-
7/29/2019 Agreement for Vatika
2/4
6 (i) Cement & Steel will be supplied by the Owners at the base rate. The cost of
Cement & Steel will be deducted from the running bills of Contractor as per the
actual consumption.
(ii) The contractor shall give the requisition of the material which is to be
supplied by the Owners to the Owners at least 10 days in advance of the daywhen material is scheduled to be used at Owners cost. Electricity & water will be
provided by Owners will provide one water supply point and one electricity point
as site for construction. Cost for the further distribution and maintenance as per
construction requirement, will be borne by contractor but running electricity
consumption bill will be borne by Owners.
(iii) The Owners shall provide complete Building plans including working drawing
from time to time for expeditious completion of work.
(iv) The contractor shall develop/employ adequate skilled and unskilled labour,technical and supervisory staff, and tools, machinery required for construction, in
sufficient numbers in order to complete the construction within stipulated time
and as per stipulated specification.
PRICES and COSTS
7 Payments will be made on a running bill on a monthly basis
8. The payment of running bills raised by the Building contractors shall be made
after the approval of the quality of construction by the technical staff present at
site or by Architects office with in seven days of submitting the running bill. The
payment of running bills shall be come due after following stages:
9. On submission of bill 75% payment shall be released within 7 days, and
balance 15% after verification by the architect, remaining 10% shall be retained
as security. Advance, if any, shall be deducted from 75% payment. Fifty percent
security amount shall be released after successful completion of construction of
work and balance 50% shall be refunded after defect liability period
10. That all the payments to contractor shall be subject to the statutorydeductions as per law for the time being in force in India , viz. T.D.S etc. and
liabilities towards service tax, Works Contract Tax, Labour Cess & any new
taxes etc, as applicable to be borne by the Owner.
-
7/29/2019 Agreement for Vatika
3/4
11. No payment will be made for temporary construction, necessary for labour
huts etc. there will not be any payment for material shifting required during
construction period.
12. No escalation clause will be operated under the agreement
SAFETY AND QUALITY
13. The contractors shall complete the construction work with latest modern
technology and under the personal supervision.
14. The contractors shall take utmost care and follow proper safety measures
security measures and during the course of construction under this agreement. In
the event of any miss happening or casualty during construction of the Building,
the Owners shall not own any responsibility and the contractors alone shall besolely responsible for such casualty and all the consequence arising therefore
including any financial damage, civil liability or criminal liability.
LABOR and WORKFORCE
15 That all payments relating to labour including P.F., E.S.I., Minimum Wages
Act, compensation to worker due to accident and other statutory liabilities under
the relevant labour Acts, for the time being in force in relation to workers
employed by him, for the said work shall be borne by contractor. Any cost ofinsurance for workers and staff at the site is to be borne by the contractor.
16. The contractor shall not employ any child labour as per the relevant law for
the time being in force.
17. (a) The contractor shall complete the work with proper coordination and in
harmony with other contractors for electrical, sanitary,carpentary etc.
(b) For technical guidance, the architects/structural engineers shall be
regularly consulted & directions shall be followed by the Contractors
DEFECTS AND CHANGES
18. The additional cost due to any alternations/additions in the specified work
shall be borne by the Owners. The contractor shall be paid the actual cost of
additional work/alternations and 15% of the cost, over and above the cost, as his
-
7/29/2019 Agreement for Vatika
4/4
supervision charges (subject to verification of the actual cost, to be finalized by
the architect).
19. Defect Liability Period: 12 Month after completion of the project in all respect
whichever is later and subject to Indemnity Bond executed separately. Any defect
during Defect Liability Period will be rectified/reconstructed/replaced by thecontractor at his own cost, otherwise Owners will have the right to do so on his
own sources and cost will be recovered from security deposit amount.
20. That in case of defective execution of the said work the Owners shall be
entitled to get the work done as per specification, either by contractor at his
(Contractors) cost or from other persons at the cost of the contractor.
21. That in case of any disputes and difference between Owners and contractors
in respect of this agreement the matter shall be dealt as per the Arbitration And
Conciliation Act 1996. The contractors and Owners (jointly) mutually agree tochoose panel of one person of the rank not less than Superintending Engineer
(Civil) of state/central government undertaking mutually acceptable to both
parties.
IN WITNESSS WHEREOF, THE PARTIES HERETO HAVE PUT THEIR
RESPECTIVE HAND ON THE DATE MENTIONED AT THE BEGINNING OF
THIS INDENTURE.
WITNESS SIGNATURE OF PARTIES
1. For Kamal Ratan Towers
(Authorized Signatory)
2. For Global Buildestate Projects
Pvt. Ltd.
Vikas Garg
(Director)