general terms and conditions_jnk
DESCRIPTION
xzczxTRANSCRIPT
Page 1 of 14
GENERAL TERMS AND CONDITIONS
FOR PURCHASE and SUB CONTRACTING
DOCUMENT NO: JNKI-PROC-0001
0 04-Feb-2016
FOR PURCHASE /
SUB CONTRACTING
REV DATE DESCRIPTION MADE BY PM CEO
Page 2 of 14
Contents
CLAUSE 1 - THE ORDER
CLAUSE 2 - FORMATION / ACCEPTANCE OF THE ORDER
CLAUSE 3 - MODIFICATIONS
CLAUSE 4 - SUB-CONTRACTING/ASSIGNMENT/CHANGE OF CONTROL
CLAUSE 5 - PRICES - INVOICING - TERMS OF PAYMENT
CLAUSE 6 - DESIGN - MATERIALS
CLAUSE 7 - MODELS AND TOOLS
CLAUSE 8 - PACKING - DELIVERY
CLAUSE 9 - QUALITY ASSURANCE – AUDITS - INSPECTION AND TESTS
CLAUSE 10 - ACCEPTANCE
CLAUSE 11 - GUARANTEES FOR DELAY AND PERFORMANCE
CLAUSE 12 - TRANSFER OF OWNERSHIP – TRANSFER OF RISKS
CLAUSE 13 - WARRANTIES
CLAUSE 14 - HEALTH, SAFETY AND ENVIRONMENT (HSE)
CLAUSE 15 - OBSERVANCE OF LAWS AND REGULATIONS
CLAUSE 16 - FORCE MAJEURE
CLAUSE 17 - INTELLECTUAL PROPERTY - CONFIDENTIALITY
CLAUSE 18 - LIABILITY - INSURANCE
CLAUSE 19 - ADVERTISING
CLAUSE 20 - TERMINATION - SUSPENSION
CLAUSE 21 - APPLICABLE LAW AND JURISDICTION
CLAUSE 22 - SPARE PARTS
CLAUSE 23 - IMPORT / EXPORT LICENCE
PREAMBLE
The present General Terms and Conditions shall define the principles of implementation of the Order
awarded to the Vendor / sub-contractor / Fabricator for the purchases by JNK HEATERS COMPANY
LIMITED of studies, equipment and/or services as further defined in the General Terms & Conditions
(referred to hereinafter as the "Supply" or “work”).
These Purchase Conditions are an integral part of the Order and they exclude any terms and
conditions of the Vendor, whatever the date and the way of their communication, including when
appearing on a purchase order accepted by JNK HEATERS COMPANY LIMITED.
Page 3 of 14
CLAUSE 1 - THE ORDER
1.1 The Order includes, without being exhaustive, the following documents, listed in order of
precedence: the Purchase Order Form signed by both Parties and its annexures, the Special
Terms and Conditions of the Order and its annexures, the technical specifications of the
Order as mentioned in the Purchase Order, the present General Terms and Conditions
All in their latest agreed version, it being understood, that any amendment to the contractual
documents shall only be valid if agreed in writing.
1.2 In the event of ambiguity, discrepancy or contradiction between the provisions contained in
one or more of the contractual documents which cannot be settled by reference to the order
of precedence above mentioned, Vendor shall inform JNK HEATERS COMPANY LIMITED,
which shall decide which document shall prevail. It being understood that performance of
any such WORK prior to JNK HEATERS COMPANY LIMITED's clarification shall be at Vendor's
risks, and Costs & Time effect shall be to vendor account.
1.3 The Order constitutes the entire agreement between the Parties with respect to the subject
matter hereof and shall supersede and cancel all prior agreements or understandings,
whether oral or written.
1.4 No waiver of any of the provisions of the Order shall be effective, unless it is given in writing
and signed by both Parties. Failure by JNK HEATERS COMPANY LIMITED to exercise or
enforce any right or provision of the Order shall not constitute a waiver of such right or
provision.
CLAUSE 2 - FORMATION / ACCEPTANCE OF THE ORDER
2.1 The Order shall be binding upon receipt by JNK HEATERS COMPANY LIMITED of the
acceptance by Vendor of the Order without any reservation, notwithstanding the
Commencement Date defined in the Order.
Vendor shall sign with date & Company Stamp and return to JNK HEATERS COMPANY
LIMITED the Order within Five (5) Working days from the receipt of the Order. Signature of
all or part of the Order entails acceptance by Vendor of the Order and of the documents
referenced in the Order. If Vendor fails to return the Acceptance within the above mentioned
period, or if the Acceptance includes reservations or comments, JNK HEATERS COMPANY
LIMITED shall have the right to cancel the Order, without any indemnity for Vendor.
The acceptance of the Order by Vendor implies that the Vendor irrevocably commits themself
to meet the schedule which is one of the essential conditions of the Purchase / Work Order.
2.2 The Work further includes the provision of such necessary or incidental supplies,
consumables, utilities, tools, labour, facilities, equipment, and services.
2.3 Prior to acceptance, Vendor is required to verify the information and data contained in the
documents handed over to him by JNK HEATERS COMPANY LIMITED. By entering into the
Order, Vendor recognises that he is fully satisfied as to the correctness and completeness of
the Order and that all documents are in all points fit and sufficient for their intended purpose
and do not contain any errors, omissions or contradictions. Vendor is deemed to have
satisfied itself as to all the conditions for implementation of the Order.
The same principles shall apply to any equipment and/or material provided by JNK HEATERS
COMPANY LIMITED to Vendor for the performance of the Order. Such equipment and /or
material shall be deemed in Vendor’s custody from the day it is put at Vendor’s disposal.
CLAUSE 3 - MODIFICATIONS
3.1 JNK HEATERS COMPANY LIMITED may, at any time, modify the scope of the Order, or ask
for additional Work. The Vendor shall, within Fifteen (15) calendar days starting from receipt
of the request for modification, indicate to JNK HEATERS COMPANY LIMITED in writing and
at its own cost, the impacts on prices and/or schedule of the modifications requested (with
Page 4 of 14
relevant justification). After this deadline, no claim and/or objection by Vendor shall be
accepted by JNK HEATERS COMPANY LIMITED.
The correlative modifications to prices and/or schedule accepted by JNK HEATERS COMPANY
LIMITED are subject to a written amendment signed by both parties.
If Vendor does not issue the impact within the indicated period of time, and if Vendor
proceeds with the implementation of the Modification, this implementation shall be
considered as an acceptance that the Modification has no effect on price and/or schedule.
3.2 The following events do not constitute modifications of the Order and cannot lead to
adjustment to any terms of the Order: Modifications and corrections that occur during the
engineering design/ phase for the Order which are necessary to convert general design intent
into sufficient details for the Order execution, Corrective actions which are necessary due to
non-compliance of the Vendor or one of its Sub-Vendor with the requirement of the Order,
instructions, drawings, specifications, or any documents sent to Vendor in relation with the
Order, Supplying of equipment and / or services not previously authorized by JNK HEATERS
COMPANY LIMITED .
3.3 Vendor shall not change, modify or alter any part of the Supply or of the Order without JNK
HEATERS COMPANY LIMITED’s prior written agreement.
3.4 Modifications shall in no event slow down the execution of the Order, nor shall it postpone
the schedule of the Order, unless mutually agreed.
CLAUSE 4 – SUB-CONTRACTING / ASSIGNMENT / CHANGE OF CONTROL
4.1 Vendor may not subcontract part or all of the Order without prior written authorization from
JNK HEATERS COMPANY LIMITED.
4.2 Vendor shall communicate to JNK HEATERS COMPANY LIMITED for approval the choice of
the said sub-contractor's company as well as a copy of sub-contractors' Order (unpriced).
JNK HEATERS COMPANY LIMITED reserves the right to refuse sub-contractors if he does not
comply / fulfil the pre-qualification requirements if required.
4.3 Vendor shall ensure his sub-supplier or sub-contractors are solvent and sufficiently
experienced for the implementation of the part of the Order it has to perform.
4.4 Vendor shall pass on his own Vendors and sub-contractors the provisions of the Order
applying to their obligations.
4.5 Approval by JNK HEATERS COMPANY LIMITED of a sub-contractor or sub-contracting by
Vendor shall not release Vendor from his obligations and responsibilities.
4.6 In case JNK HEATERS COMPANY LIMITED considers that a sub-contractor or a sub-supplier
is not performing a part of the work in accordance with the Order, JNK HEATERS COMPANY
LIMITED shall notify it to Vendor who shall immediately remove such sub-contractor or sub-
supplier and, without any delay, shall replace him with competent approved substitute, at
no extra cost to JNK HEATERS COMPANY LIMITED and Vendor will not be granted additional
time.
4.7 JNK HEATERS COMPANY LIMITED may assign the Order to any Third Party, including its
Client. In that case, JNK HEATERS COMPANY LIMITED will inform Vendor of the assignment
and sub-supplier, sub-supplier shall obtain all necessary insurance policy endorsements
relating to the Order so that the assignee has the same rights under such policies as JNK
HEATERS COMPANY LIMITED.
In such case, Vendor agrees to be responsible towards assignee for the proper performance
of the Order and agrees to sign any required assignment agreement which shall not modify
the terms of the Order.
4.8 Vendor shall not assign nor transfer all or part of the Order, without JNK HEATERS COMPANY
LIMITED’s prior written consent.
Page 5 of 14
4.9 Vendor shall immediately inform JNK HEATERS COMPANY LIMITED of any change of
shareholding structure, change of control or any event having an impact on Vendor’s ability
(financial or other) to perform the Order.
CLAUSE 5 - PRICES - INVOICING - TERMS OF PAYMENT
5.1 Prices: The prices indicated on the Order are inclusive of taxes and duties as specified in the
Purchase order are firm and not subject to revision.
5.2 Invoicing: For each instalment, the related invoice shall be sent to the Accounting
Department in triplicate, together with the document justifying the payment and the Order
reference number.
Failure to comply with the instructions set forth in the Order entails rejection of the invoices,
which shall be returned to the Vendor.
Vendor’s issuance of its last invoice for the balance of the total amount of the Order
(including modifications or liquidated damages) shall be construed as an acknowledgement
of full settlement on its part.
5.3 Terms of payment:
5.3.1 Upon satisfactory fulfilment of the Vendor’s obligations, JNK HEATERS COMPANY
LIMITED shall pay, by bank transfer or cheque, the undisputed invoices within the time
specified in the Purchase Order. Disputed invoices rejected by JNK HEATERS COMPANY
LIMITED shall be corrected by Vendor and resubmitted for payment.
5.3.2 JNK HEATERS COMPANY LIMITED shall have the right to offset, from any invoice, any
amount due by Vendor to JNK HEATERS COMPANY LIMITED under the Order.
5.4 Accounting and audit : Vendor shall safely keep and cause its Vendors and sub-contractors
to keep in accordance with generally accepted accounting practice accurate detailed records
and accounts pertaining to the performance of the work, including personnel records,
correspondence, receipts, vouchers, memoranda, computerised data and such other
information necessary for an accurate audit and verification of any reimbursable costs, for
the duration of the Order and for a period of five (5) years following termination of the
Order.
CLAUSE 6 – DESIGN - MATERIALS
The Supply shall be carried out according to the Vendor’s design, on the basis of JNK
HEATERS COMPANY LIMITED’s specifications and/or drawings. Vendor shall take full
responsibility therefore and satisfy the requirements (qualify, performance…) set forth in the
Order.
Should the design of the Supply be imposed by JNK HEATERS COMPANY LIMITED, Vendor
shall be responsible for verifying it, and if necessary, for completing it.
Vendor shall be responsible for procuring the materials (origin, conformity…) in compliance
with the regulations in force applicable to the Order, concerning the origin and provenance
of the Supply components. Vendor is responsible for the accuracy of the certificates.
The drawings furnished by Vendor shall be available to JNK HEATERS COMPANY LIMITED in
native format.
CLAUSE 7 - MODELS AND TOOLS
The drawings, models including 3D models, databases and tools entrusted to the Vendor
shall remain the exclusive property of JNK HEATERS COMPANY LIMITED. The drawings,
models including 3D models, databases and tools fabricated or created by the Vendor for
execution of the Order shall become the property of JNK HEATERS COMPANY LIMITED as
soon as they are created. All models and tools that might not be returned shall be stored
free of charge by the Vendor, sheltered from bad weather and insured against all risks of
deterioration. They shall bear the mark "JNK HEATERS COMPANY LIMITED," very legibly
Page 6 of 14
painted, and shall be returned upon JNK HEATERS COMPANY LIMITED's request. Prior to
execution of the Order, the Vendor shall ensure compatibility between the models and
tools that JNK HEATERS COMPANY LIMITED may make available to him. Non-matching
parts shall be rejected, even if they come from models and tools of the SUPPLY. All
necessary models and tools and the corresponding drawings for performance of the Order
shall be assigned exclusively to this purpose. They shall not be used, reproduced or
communicated to third parties without prior written authorization from JNK HEATERS
COMPANY LIMITED.
At the end of the performance of the Order, the drawings, 3D models and databases shall
be returned to JNK HEATERS COMPANY LIMITED, in whatever state they may be, at the
same time as the consignment note, for the remainder.
CLAUSE 8 – PACKING - DELIVERY
8.1 Prior to packing the supply, Vendor shall take all measures necessary to protect the
equipment from bad weather, corrosion, loading incidents, and transportation or storage
constraints.
The packing, marking and loading of the Goods shall be carried out at the cost and risk of
the Vendor, who undertakes to deliver the Goods at the place specified and on the date
scheduled in the Order.
If the delivery is not made at the agreed place, or within the agreed period of time, all costs
incurred in connection with dead freight, demurrage, warehousing, insurance and/or any
other costs to ensure delivery shall be borne by Vendor, as well as the possible associated
costs incurred by JNK HEATERS COMPANY LIMITED .
8.2 In the event of supply of equipment or materials, all shipments shall be subject to the
notice of shipment by the Vendor sent to the Purchasing Department which issued the Order
(these documents are a precondition for invoicing any instalment under the Order), and it
shall be attached to the package.
Early deliveries can only be carried out with JNK HEATERS COMPANY LIMITED’s prior
intimation / written consent.
CLAUSE 9 - QUALITY ASSURANCE – AUDITS - INSPECTION AND TESTS
9.1 Quality Assurance
Vendor shall provide, maintain and observe for the duration of the Order a complete Quality
Assurance System and set up a suitable organization securing the various related functions.
Throughout the performance of the Order, the Vendor shall give JNK HEATERS COMPANY
LIMITED and/or its Client (or End-User if any) and/or their representative free access to any
place where part of the Supply is being performed.
9.2 Audits
During the performance of the Order, JNK HEATERS COMPANY LIMITED is entitled to effect
by its own specialists or by a designated Third Party technical and safety audits in respect
of all aspects of the Order. JNK HEATERS COMPANY LIMITED shall be entitled to instruct
Vendor to perform adjustments as are required by the audit expert to comply with the
requirements of the Order, at Vendor's cost.
During the visits by JNK HEATERS COMPANY LIMITED and/or its Client (or End-User if any),
Vendor shall afford the necessary assistance, and supply the necessary documentation to
JNK HEATERS COMPANY LIMITED and/or its Client (or End-User if any) to enable them to
monitor the progress of the WORK and to ascertain that the materials used, and the method
of performing the work, meet the requirements of the Order.
Vendor shall bear all costs associated with providing such assistance.
Page 7 of 14
Should the progress of the work be behind the Schedule, or should JNK HEATERS COMPANY
LIMITED find any anomaly, JNK HEATERS COMPANY LIMITED shall notify Vendor of the same
and Vendor shall take such action to remedy such delay or anomaly within the shortest
possible time or within the time specified by JNK HEATERS COMPANY LIMITED.
JNK HEATERS COMPANY LIMITED may propose remedy actions and/or execute by itself such
remedy plan if it deems that Vendor’s corrective measures are not satisfactory. The resulting
costs shall be borne by Vendor.
9.3 Inspection and Tests
The Supply is subject to inspection by JNK HEATERS COMPANY LIMITED, his Client (or End-
User if any), Third party, or their authorized representative. Inspection will take place in
Vendor’s premise.
Vendor shall provide safety and protective clothing, as required, including but not limited to
safety boots, hard hats, goggles, gloves for JNK HEATERS COMPANY LIMITED, Client’s
and/or End-User’s representatives.
The inspection does not relieve Vendor of the responsibility to supply which conform to the
specifications nor shall it relieve Vendor of the responsibility to provide its own quality control
and in-house inspection of the SUPPLY. Test reports, if required, shall be submitted by
Vendor to the inspector at the time of inspection.
The costs for the inspection and testing of the equipment’s are deemed to be included in the
Order. All and any extra costs of JNK HEATERS COMPANY LIMITED and/or of its Client and/or
End-User, if any, attributable to additional inspections due to Vendor’s failure under the
Order will be borne by Vendor.
Neither JNK HEATERS COMPANY LIMITED’s comments, approval, visits, checks, nor the
presence of JNK HEATERS COMPANY LIMITED’s representative in Vendor’s workshop shall
release the Vendor from any of its responsibilities under the Order.
CLAUSE 10 - ACCEPTANCE
10.1 Upon completion of the Order, an Acceptance Certificate shall be issued by JNK
HEATERS COMPANY LIMITED upon Vendor’s request in writing, acknowledging the latter’s
fulfilment of its obligations.
Acceptance of the SUPPLY shall occur following verification by JNK HEATERS COMPANY
LIMITED that the Supply conforms to the Order and, where applicable, following receipt by
JNK HEATERS COMPANY LIMITED of the documents relating to the SUPPLY (including
material certificates, drawings, final documentation) and more generally receipt of any
document set out in the Order
If JNK HEATERS COMPANY LIMITED believes that any Vendor’s obligations have not been
fulfilled, it shall notify Vendor in writing of the tasks which remain to be finished. Vendor
shall then complete all outstanding obligations prior to the issuance of the Acceptance
Certificate. In case of minor punch list items, Acceptance may be issued by JNK HEATERS
COMPANY LIMITED, provided that Vendor completes the punch list within a mutually agreed
period of time.
Any acceptance of the Supply or portions thereof, even by a recognized authority shall not
relieve Vendor from its responsibility for the proper execution of the Order.
10.2 Rejection of the Supply
Should JNK HEATERS COMPANY LIMITED believe that Vendor is unable to complete all or
part of the SUPPLY as per the requirements of the Order and after an unsuccessful formal
notice to Vendor, JNK HEATERS COMPANY LIMITED reserves the right, without prejudice to
its rights under the Order or at law, to reject all or any part of the Supply. Any Supply that
is rejected shall be taken back by the Vendor, at Vendor’s costs, within ten (10) days
following receipt of the notice of rejection, unless otherwise instructed by JNK HEATERS
Page 8 of 14
COMPANY LIMITED , and the Vendor shall reimburse all sums already paid by JNK HEATERS
COMPANY LIMITED in connection with the rejected Goods/Supply. Title to the rejected
Goods and care and custody of the same shall automatically be transferred back to Vendor,
unless otherwise notified by JNK HEATERS COMPANY LIMITED.
All expenses connected to the rejection of the Supply shall be borne by Vendor.
CLAUSE 11 – GUARANTEES FOR DELAY AND PERFORMANCE
11.1 Vendor acknowledges that compliance with all dates indicated in the Schedule is
imperative and that delivery of the work by the Delivery Date is an essential condition of the
Order and therefore Vendor hereby undertakes to complete the work on or before the dates
and times for completion set forth in the Schedule.
In particular, the Schedule specifies the following: The date(s) scheduled for the beginning
and the progression of the performance of the Order. The date(s) of delivery and/or
completion of the Supply or parts thereof.
11.2 Without prejudice to any other provisions of the Order and/or JNK HEATERS COMPANY
LIMITED’s rights at law, should Vendor fail to complete all or part of the WORK as per the
Schedule and the Delivery Date, JNK HEATERS COMPANY LIMITED shall have the right to
apply liquidated damages or contract reduction clause for delay. The foregoing shall not
apply in case of Force Majeure.
The amount of the liquidated damages or contract reductions shall be specified in the Order.
They can be offset from amounts due by JNK HEATERS COMPANY LIMITED to Vendor under
the Order.
11.3 The payment by the Vendor of these liquidated damages or contract reduction clause
shall not affect JNK HEATERS COMPANY LIMITED’s right (i) to claim all damages incurred by
JNK HEATERS COMPANY LIMITED as a consequence of such delay (including potential claims
by third parties), and/or (ii) to cancel the Order, as of right, for Vendor’s default, and/or (iii)
to request reimbursement of sums already paid by JNK HEATERS COMPANY LIMITED for the
SUPPLY (if any).
The application of liquidated damages shall not release Vendor of its obligation to diligently
complete the Order or from any other obligations and liabilities under the Order or at law.
11.4 The Vendor guarantees that the Supplies shall meet the performance and yields
described in the Order.
Should such performance not be met in whole or in part, for reasons not attributable to JNK
HEATERS COMPANY LIMITED, Vendor shall, at its costs, promptly proceed with any
replacement, repair, change or adjustment necessary in order to meet the requirements of
the Order (including dismantling and re-assembly of the supply).
JNK HEATERS COMPANY LIMITED may not issue its Acceptance of the Supply until the Supply
has met all the performances defined in the Order.
CLAUSE 12 - TRANSFER OF OWNERSHIP – TRANSFER OF RISKS
12.1 The Supply and parts thereof shall become the property of JNK HEATERS COMPANY
LIMITED through Vendor as soon as such are ordered by sub-supplier or a sub-contractor
and identifiable as being attributed to the Order, notwithstanding the phase of progress
(such as in the course of manufacturing, fabrication, welding, transportation, installation)
and notwithstanding any payment considerations. Vendor shall guarantee that the Supply is
free of any lien, encumbrance or pledge.
12.2 The Vendor waives any right of recourse to any retention of title clause not expressly
agreed by JNK HEATERS COMPANY LIMITED.
12.3 The Vendor shall ensure that its own sub-supplier’s chain and its subcontractors are
imposed the same obligations than above.
Page 9 of 14
12.4 The Supply (including free issued materials if any) shall remain under Vendor's care
and custody until delivery to JNK HEATERS COMPANY LIMITED or its Client as per the
Incoterm defined in the Purchase Order form.
CLAUSE 13 - WARRANTIES
13.1 Vendor shall perform the work with all proper skill and care, in accordance with good
engineering practice and the state of the art, and in compliance with the Order, the
regulations, the standards and codes in force.
Vendor guarantees that the equipment supplied are new, fit for the intended purpose, of
good quality and workmanship and meet the description and specification referred to in the
Order.
13.2 Except otherwise provided, the Vendor warrants that the Supply, including associated
documentation shall be free from errors, defects or failures for a period of eighteen (18)
months starting from the Acceptance by JNK HEATERS COMPANY LIMITED of the SUPPLY
or thirty (30) months from the Delivery Date, whichever comes first.
13.3 Should the Vendor breach this warranty, JNK HEATERS COMPANY LIMITED may, at its
option, either require the Vendor to repair or to replace the Supply or if the Vendor does not
do so within ten (10) calendar days from the date of the request by JNK HEATERS COMPANY
LIMITED, take appropriate measures to arrange the same itself or through a third party. In
any event, the Vendor shall bear all costs of any replacement and repair of the Supply,
including but not limited to travel expenses, the costs of dismantling and returning the
Supply to the factory and any parts and labour, but without prejudice to any other rights or
remedies JNK HEATERS COMPANY LIMITED may have.
13.4 Reworks shall be performed within the period requested by JNK HEATERS COMPANY
LIMITED, having regard to the urgency of the case and in such a manner so as to cause a
minimum of interruption in the use of the Supply. Any replacement or repair of the Supply
under warranty shall give rise to a new warranty for a minimum period of twelve (12) months
from the date of JNK HEATERS COMPANY LIMITED’s acceptance of delivery of the repaired
or replaced SUPPLY.
CLAUSE 14 - HEALTH, SAFETY AND ENVIRONMENT (HSE)
Vendor shall ensure implementation of the highest HSE standards by active involvement at
all levels in his organisation, including sub-contractors.
Vendor shall be responsible for all HSE aspects in all aspects of the work.
Management of HSE means activities related to the prevention of: Fatalities, injuries and
occupational diseases. Damage to the environment. Damage to property. Unscheduled down
time
HSE management shall be an integrated part of the work and shall be performed in a proper,
systematic way based on established standards and safety objectives.
Vendor shall implement a HSE management system and shall report the situation in the
Monthly Progress Report.
CLAUSE 15 – OBSERVANCE OF LAWS AND REGULATIONS
Vendor is aware of, and shall in all respect abide by laws, decrees and regulations issued by
any authorities, whether local or other, having jurisdiction over the work.
Vendor shall not offer, make payments, loans or other special considerations to any public
official or to any employee of JNK HEATERS COMPANY LIMITED , its Client (or End-User if
any) or their affiliates, failing which the Order may be terminated in accordance with Clause
20.1 hereof.
In the field of HSE, Vendor acknowledges that it is aware of all applicable rules or regulations,
including site rules, when site works are involved. Vendor shall bear all financial and/or
Page 10 of 14
administrative consequences incurred by JNK HEATERS COMPANY LIMITED or its Client (or
End-User if any), as a result of Vendor’s failure to abide by the above mentioned laws and
regulations.
CLAUSE 16 - FORCE MAJEURE
16.1 Force Majeure shall mean any event outside the reasonable control of the Parties which
is unforeseeable and unavoidable and which is preventing one of the Parties from performing
its obligations under the Order.
16.2 The party affected by an event of force majeure shall immediately notify the other party
of the situation by fax or official e-mail confirmed by registered letter with receipt, supplying
all necessary documentary evidence. The party claiming an event of force majeure shall
make every effort to mitigate as far as possible any adverse effect arising from this situation.
16.3 Force majeure shall only relieve the affected party from its contractual obligations to
the extent and for such period as the said party is prevented from performing those
obligations.
16.4 In any case, the following shall not be considered as cases of Force Majeure: Strikes,
except national strikes; implementation of the Order which is particularly difficult or onerous;
any event attributable to Vendor or to its subcontractors or sub suppliers; potential delays
in the supply of products or of raw materials.
16.5 Should the consequences of the event of Force Majeure last more than sixty (60) days
starting from the date of notification and if the Parties have not reached an agreement on
the most appropriate course of action in view of the circumstances, JNK HEATERS COMPANY
LIMITED shall be entitled to terminate all or part of the Order under the same conditions as
those provided for in Clause 20.2 hereafter.
16.6 Each party shall bear its own expenses resulting from the occurrence of a force majeure
event.
CLAUSE 17 - INTELLECTUAL PROPERTY - CONFIDENTIALITY
17.1 The documents, drawings and data disclosed by JNK HEATERS COMPANY LIMITED to
Vendor shall remain JNK HEATERS COMPANY LIMITED’s property and may not be used or
disclosed for purpose other than the implementation of the Order, without JNK HEATERS
COMPANY LIMITED’s approval.
17.2 JNK HEATERS COMPANY LIMITED shall be free to use the drawings and documents
prepared by Vendor under the Order for the purpose of executing JNK HEATERS COMPANY
LIMITED’s own contract with its Client.
17.3 The Vendor declares that all intellectual property rights relating to the Suply are either
the exclusive property of the Vendor or subject to a license granted to the Vendor by a third
party holding these rights, under conditions allowing JNK HEATERS COMPANY LIMITED to
freely use and/or transfer the Supply.
17.4 Consequently, Vendor shall indemnify and hold harmless JNK HEATERS COMPANY
LIMITED against any and all claims, costs, damages, expenses or legal action by third parties
in connection with any actual or alleged infringement of intellectual property rights in relation
to the supply. If in the opinion of JNK HEATERS COMPANY LIMITED the supply carries a risk
of claim or legal action, the Vendor shall take all steps necessary to ensure that such risk of
infringement is eliminated, including if necessary carrying out modification or replacement.
17.5 All information obtained by the Vendor during performance of the Order shall be kept
confidential and shall not be disclosed by Vendor to any third party save to the extent
necessary for the execution of the Order and then only on the basis that the recipient of
such information will be bound by similar confidentiality obligations than those undertaken
by the Vendor hereunder. Provided however that this obligation shall not apply to
information which is or shall become part of the public domain otherwise than as a result of
a breach by Vendor of its obligations under this clause, or was in Vendor’s possession prior
Page 11 of 14
to receiving this information under the Order, or was received from third parties without
restriction on disclosure.
17.6 Vendor shall only be entitled to use the documents, information and/or elements
received or obtained for the performance of the Order and shall not disclose the same to
any third party or to any staff of the Vendor other than on a “need-to-know” basis.
17.7 The confidentiality undertaking under this Clause 17 shall apply for a period of Five (5)
years from signature of the Order. The Vendor shall, at the expiry of the term of the Order,
return to JNK HEATERS COMPANY LIMITED every document and data and every copy of the
same, which may have been kept in connection with the performance of the Order.
CLAUSE 18 - LIABILITY - INSURANCE
18.1 The Vendor shall be liable for any damages, liabilities, claims, judgments, losses or
expenses that it or its employees, representatives and/or sub-contractors cause to the
Supply, or to the personnel or property of JNK HEATERS COMPANY LIMITED or of its Client
(and End-User if any) or of a third party during the implementation of the Order and the
Vendor shall defend, indemnify and hold harmless JNK HEATERS COMPANY LIMITED , its
Client (and End User if any) or the third party from and against any such damages, liabilities,
claims, judgments, losses or expenses that these latter may suffer.
18.2 Vendor shall defend, indemnify and hold JNK HEATERS COMPANY LIMITED , its Client
(and End-User if any), harmless from and against any and all liabilities, claims, judgments,
losses, expenses and any costs related to bodily injury including death, property damage of
Vendor’s personnel or representatives, its Vendors’, sub-contractors’ or any affiliates’
thereto.
18.3 Vendor shall, at its own costs, take out and maintain in force all insurances necessary
for covering his liability under the Order and at law.
Unless otherwise specified in the Order, Vendor shall procure the following insurance: A
policy covering the risk of loss or damage (and the financial consequences thereof) of the
Supply occurring prior to delivery to JNK HEATERS COMPANY LIMITED for its full replacement
value and a Third Party Liability Insurance (including a Product liability policy)
covering death and personal injury and property damages of third parties, including JNK
HEATERS COMPANY LIMITED , its Client (and End-User if any), before and after the delivery
of the Supply and caused by a fault, error or omission attributable to Vendor Workmen’s
compensation Insurance as per the law applicable to the employment contracts of Vendor’s
personnel.
None of the amounts set out in the insurance policies shall be construed or interpreted as
limiting the Vendor’s liability in any respect.
Upon JNK HEATERS COMPANY LIMITED’s request, Vendor shall provide insurance certificate
from first rank insurance companies acceptable to JNK HEATERS COMPANY LIMITED,
certifying the existence, insured capital, guarantees, and duration and renewal dates of the
policies.
18.4 Neither party shall be liable to the other party for any loss of production, loss of profit,
loss of contract, loss of opportunity, loss of business, loss of use, loss in downtime facilities
or for any indirect, consequential, or special loss or damages that may be suffered by the
other party.
18.5 Vendor’s maximum liability under this Order is limited to 100% (one hundred percent)
of the price of the Order, except in case of defective engineering, of gross negligence or
wilful misconduct for liability under Clause 18.1 to 18.4 “Liability – Insurance” and Clause
17 “Intellectual property confidentiality”, for which Vendor’s liability is not limited.
CLAUSE 19 - ADVERTISING
Page 12 of 14
Any publicity or communication to third parties concerning the Order shall be subject to JNK
HEATERS COMPANY LIMITED’s prior written approval.
CLAUSE 20 - TERMINATION - SUSPENSION
20.1 Termination for default
In the event of Vendor‘s default under the Order (including in the event the Vendor has a
petition for its winding up presented, goes into liquidation, or otherwise has a petition
presented for appointment of any administrator in respect of the Vendor’s business), JNK
HEATERS COMPANY LIMITED shall have the right to terminate the Order, as of right, without
any indemnity to Vendor and without prejudice to the right of JNK HEATERS COMPANY
LIMITED to claim for the payment of liquidated damages or cost reduction for late delivery
and/or all the damages incurred by JNK HEATERS COMPANY LIMITED as a consequence of
Vendor’s default, including the extra costs resulting from the award of a contract to another
contractor to terminate the Order. JNK HEATERS COMPANY LIMITED shall notify such
termination by registered letter with acknowledgement of receipt.
JNK HEATERS COMPANY LIMITED may, by giving notice to Vendor, terminate all or part of
the Order without compensation of any sort to Vendor, if the Vendor is the subject of a
merger, take-over, acquisition or transfer of business that would in the sole discretion and
opinion of JNK HEATERS COMPANY LIMITED, have a detrimental effect upon Vendor’s ability
to perform its obligations under the Order.
20.2 Termination for convenience
In the absence of default by Vendor, JNK HEATERS COMPANY LIMITED may, at any time,
cancel all or part of the Order by registered letter.
In this case, JNK HEATERS COMPANY LIMITED shall pay the Vendor, upon presentation of
supporting documents, for the part of the Supply completed, at JNK HEATERS COMPANY
LIMITED’s satisfaction, as of the date of termination, after deduction of any down payments
or advance payments already paid.
20.3 In all event of termination, Vendor shall, no later than fifteen (15) days after receipt of
the notice of termination, refund and hand over to JNK HEATERS COMPANY LIMITED the
following:
a) All sums that have been paid to Vendor as advance or as down payment;
b) The documents used for the performance of the Order, as well as all data, books,
manuals, drawings, information, etc. established for JNK HEATERS COMPANY
LIMITED under the Order (except Vendor’s proprietary documents);
c) Title to and of possession the Supply and its constituting parts (including
documents, drawings, data…), as it is, on the date of termination;
d) Title to and of possession the equipment or materials provided to Vendor as a
free issue for incorporation in the main Supply/ modularisation of the equipment
part
Vendor shall also, if so required by JNK HEATERS COMPANY LIMITED, assign to JNK HEATERS
COMPANY LIMITED its sub-contracts entered into in connection with the Order.
20.4 Suspension
JNK HEATERS COMPANY LIMITED shall, at any time, have the right at its sole discretion, to
suspend all or part of the Order. Vendor shall, forthwith upon receipt of JNK HEATERS
COMPANY LIMITED’s notice, suspend performance of the Order and shall during the period
of such suspension properly protect and secure the Supply.
The delivery schedule shall not be extended and JNK HEATERS COMPANY LIMITED shall not
reimburse Vendor for costs incurred as a result of any suspension attributable to Vendor’s
failure to comply with any provision of the Order or necessary for the safety of the Supply.
Page 13 of 14
Any request for extension of the schedule or for reimbursement of direct extra costs caused
by such suspension shall be duly documented by Vendor.
Upon notice from JNK HEATERS COMPANY LIMITED, Vendor shall promptly resume the
performance of the Order.
20.5 Receivership, Insolvency, Bankruptcy
Any and all judgment or other decision of equal value such as a petition for winding up,
decision of liquidation, of bankruptcy or other petition presented for appointment of any
receiver or administrator in respect of the Vendor’s business must be immediately notified
to JNK HEATERS COMPANY LIMITED by the Vendor.
In case of petition presented for appointment of a receiver or an administrator, JNK HEATERS
COMPANY LIMITED will request in writing whether the receiver or the administrator insists
upon performance of the Order.
If the administrator does not insist upon the continuation of the performance of the Order,
or in case of silence for more than one (1) month from the date of issuance of the above
mentioned written request, the Order will be deemed terminated as of the expiry of the one
(1) month period.
A judge may modify such time period before its expiry.
The termination of the Order shall be effective as of the day of the receiver’s decision not to
pursue the performance of the Order or at the expiry of the above mentioned one (1) month
period, whichever comes first.
In case of bankruptcy or insolvency, the termination of the Order is deemed effective as of
the date of the bankruptcy or insolvency judgment, unless the judge expressly authorizes
continuation of the business of the SELLER.
CLAUSE 21 - APPLICABLE LAW AND JURISDICTION
The Order shall be governed and construed according to Indian law.
Any or all disputes regarding the validity or performance of the Order, which cannot be
amicably be solved within thirty (30) days from the notice of dispute, shall be submitted to
the Court in Mumbai.
However, notwithstanding any pending settlement of dispute, Vendor shall continue the
performance of the Order as per the Order.
CLAUSE 22 – SPARE PARTS
Vendor shall ensure the availability of necessary spare parts, special tools for the
maintenance of the Supply for a duration of ten (10) years.
CLAUSE 23 – IMPORT / EXPORT LICENCE
23.1 Vendor shall be responsible for identifying if any export license is required in any place
where the Supply is to be performed, for any parts of the Supply, including import licenses
for any materials and/or tools used by Vendor.
23.2 Where compulsory, Vendor shall obtain such import / export license from the relevant
authorities at its own costs. Vendor shall take all necessary measures to ensure that all
export/import licenses and shipping documentation are arranged and issued in a timely
manner consistent with the constraints of the Order.
23.3 Vendor shall provide JNK HEATERS COMPANY LIMITED with all necessary documents
for JNK HEATERS COMPANY LIMITED to obtain customs clearance for the, exportation of
the work or re-exportation of any part of the work.
Page 14 of 14
Vendor is responsible for obtaining and maintaining at his own cost all licences, visas,
permits, clearance, certifications, governmental or administrative authorisations necessary
for the performance of the work.
*****