notice inviting e-tender regional office employees’ … · page 1 of 51 notice inviting e-tender...

of 51

NOTICE INVITING e-TENDER

REGIONAL OFFICE

EMPLOYEES’ STATE INSURANCE CORPORATION R.S. NO. 89/2, BOUVANKARE STREET, ESIC COMPLEX,

MUDALIARPET, PUDUCHERRY - 605 004.

ABSTRACT OF SCHEDULE

Name of Work: Special repairs (Civil & Electrical) for Ramp Repairs to Old Quarters (12 Unit) including Electrical rewiring arrangements, Shifting of Pillar box from the power room in the ESI Hospital and Staff Quarters, ESI Hospital, Gorimedu, Puducherry. Name of the Contractor:

SI.No. Abstract of Schedule Amount 01 Civil- DSR Item Total 49,54,443.21 02 Civil- PSR & MR Total 75,436.00 03 Civil- Total 50,29,879.21 04 Electrical - DSR Item Total 20,50,312.00 05 Electrical - SSR & SD 5,80,654.00 06 GST for SSR & SD (@12%) 69,678.48 07 Electrical – PSR & MR 12,50,655.70 08 Electrical - Total 39,51,300.18 08 Civil and Electrical-Total 89,81,179.39 08 Labour Cess @ 1% 89,811.79

Total 90,70,991.18 Value put into Tender (say) 90,70,991.00

Minus _____________________% (or) On PAR the estimated cost (or) Plus________________% Quoted percentage in words ___________________________________________________Only (Bidder is to quote/select any one of the above, Clearly striking out the others. The offer will be summarily rejected if found conflicting) Note:

1. The Percentage rate quoted by the tenderer shall be firm and fixed. 2. The Estimated Cost Put to Tender has been worked out by taking into consideration of

prevailing Cost Index for the particular zone, DSR 2016 for Civil items, DSR 2018 for electrical items and SSR 2018 (Civil & Electrical) and also considering the Market Rates.

3. The Percentage shall be typed only in figures upto 2 (two) places of decimal along with algebraic sign.

of 51

Signature of the contractor

NOTICE INVITING e-TENDER ANNEXURE – ‘A’

REGIONAL OFFICE EMPLOYEES’ STATE INSURANCE CORPORATION

R.S. NO. 89/2, BOUVANKARE STREET, ESIC COMPLEX, MUDALIARPET, PUDUCHERRY - 605 004.

Name of work : Special repairs (Civil & Electrical) for Ramp Repairs to Old Quarters (12 Unit) including Electrical rewiring arrangements, Shifting of Pillar box from the power room in the ESI Hospital and Staff Quarters, ESI Hospital, Gorimedu, Puducherry

Notice inviting e-tender

Digitally Sealed e-tenders under (two bid system) in the prescribed format are invited from Registered/enlisted contractors for Special repairs to (Civil & Electrical) works at ESI Hospital and Staff Quarters, ESI Hospital, Gorimedu, Puducherry

Schedule of e- tender Details of e-tender

1. Mode of tendering Online bidding system through https://esictenders.eproc.in 2. Type of tender Two bid system 3. Value put to tender `90,70,991/- 4. EMD `1,81,500/-

Time schedule of e-tender :

S.No. Particulars Date Time 1. Date of publishing e-tender 01/03/2019 10.00 am

2. Last date of online bid submission 26/03/2019 10.30 am

3. Last date for submission of EMD with hard copy of scanned e-tender document

26/03/2019 11.00 am

4. Due date of opening of e-Tender (Technical Bid)

26/03/2019 11.00 am

Bidder should carefully read all the terms & conditions before submitting their tender. The invitation to e-tender is subject to fulfillment of instructions and conditions as per schedules below: Chapter I Instruction regarding e-tendering Chapter II Instructions and Tender conditions Any change in the tender shall be uploaded in the below mentioned website only and further notification shall not be issued in the newspaper. Hence the tenderers may visit the site regularly

REGIONAL DIRECTOR & ADDITIONAL COMMISSIONER

https://esictenders.eproc.in

of 51

Chapter 1

Important Instructions for Bidders regarding Online Payment All bidders/contractors are required to procure Class-IIIB Digital Signature Certificate (DSC) with Both DSC Components i.e. Signing & Encryption to participate in the ETenders. Bidders should get Registered at https://esictenders.eproc.in. Bidders should add the below mentioned sites under Internet Explorer - Tools - Internet Options - Security - Trusted Sites - Sites of Internet Explorer : https://esictenders.eproc.in https://www.tpsl-india.in https://www4.ipg-online.com Also, Bidders need to select “Use TLS 1.1 and Use TLS 1.2” under Internet Explorer - Tools - Internet Options - Advanced Tab - Security. Bidder needs to submit Bid Processing Fee charges of Rs. 2495/- (non-refundable) in favour of M/s. C1 India Pvt. Ltd., payable at New Delhi via Online Payment Modes such as Debit Card, Credit Card or NetBanking for participating in the Tender. Bidders can contact our Helpdesk at https://esictenders.eproc.in/html/Support.asp



https://www.tpsl-india.in

https://www4.ipg-online.com

https://esictenders.eproc.in/html/Support.asp

of 51

Chapter - II INSTRUCTIONS AND TENDER CONDTIONS

1. The interested bidders should submit the tender documents through online only at e-procurement portal https://esictenders.eproc.in from 04/03/2019 to 26/03/2019 upto 10.30 am.

2. The tender documents can be obtained by downloading it which is in pdf format from www.esicpondicherry.com and Central Public Procurement Portal: www.eprocure.gov.in (epublishing)

i. In addition to e-tender which has to be filed through online, the bidders also shall be required to file hard copies of Tender documents duly completed along with Earnest Money Deposit (EMD) and supported by requisite documents and the forms, as mentioned in the tender document which should be submitted with covering letter in a sealed envelope duly super-scribed with the name of work and should be dropped in the tender box latest by 10.30 am on 26/03/2019.

ii. Date and time of opening of tender is 26/03/2019 at 11.00 am. The tender shall be opened in presence of Tenderer/Authorised Representatives who choose to be present.

3. For all practical purposes, the e-tender shall be considered for evaluation, however in case of any dispute, the physical documents would be scrutinized. The rates quoted in e-tender only will be considered for evaluation.

4. The amount of Earnest Money Deposit (EMD) is `1,81,500/- (Rupees One lakh Eighty One thousand and Five hundred only ) and should be paid in the form of DD/Pay Order, drawn in favour of ESI Fund A/c No. 1 payable at Pudhucherry.

5. Tender form shall be duly filled up and completed in all respects. Incomplete tenders or tenders without EMD shall be treated as invalid.

6. Each and every page of the tender documents should bear stamp and signature of the authorized representative/quoting firm. Format I & II enclosed shall be filled without exception. The tenderer shall also enclose the copies of documents in support of details about the firm besides latest Income Tax returns, ESI & EPF Registration, GST Registration and work completion certificates etc. All these documents shall be kept inside the Technical Bid cover.

7. Rates quoted through on line shall be firm, fixed and are inclusive of cost of manpower, material, machinery, tools & plant etc., duties & levies, insurance etc. and statutory taxes such as Labour Welfare Cess & Goods and Services Tax etc. No escalation of whatsoever shall be payable later on. However, the responsibility towards payment of GST lies with the contractor only.

8. The envelope containing scanned tender document shall be sealed and bear the name of work and the name and address of the tenderer.

9. Conditional tenders are liable to be rejected.


http://www.esicpondicherry.com

http://www.eprocure.gov.in

of 51

10. The site for the work can be inspected on any working day during office hours by contacting the ESIC Engineers

11. The tender for the work shall remain open for acceptance for a period of 90 days from the date of opening of tender.

12. The Competent Authority of ESIC, reserves the right to accept or reject any tender or all tenders without assigning any reason.

13. The EMD of unsuccessful tenderers shall be refunded within one month after the award of work to the successful tenderer.

14. Contractor to whom the work is awarded shall execute the work himself / agency and they should not be allowed to sublet the work to any other agency and if any comes to the notice of ESIC at any point of time during execution of subletting then the contractor shall not be allowed to participate in further any tender in ESIC of Concern Region and also action will be taken for cancellation of existing contract.

15. Eligibility criteria: 1. Registration / Enlisted from any State PWD / CPWD / Public Sector and

Government Undertakings with current validity for both Civil and Electrical works with appropriate class

2. The tenderer should have minimum three years experience as on tender opening date in works of similar nature from Central or State Government organization / Public Sector / Government Undertakings and documentary evidence with copies of work orders, agreement copy and completion certificate from the client department alongwith work value shall be enclosed in the formats I & II as annexed in Part ‘A’

3. The tenderer should have successfully completed the following value of similar nature of works in the last 7 years as on tender opening date. i. One Special Repair (Civil & Electrical) works of value not less than `72,56,793/-

or ii. Two Special Repair (Civil & Electrical) works of value each not less than

`45,35,500/- or

iii. Three Special Repair (Civil & Electrical) works of value each not less than `36,28,400/-

iv. Average Annual financial turnover during the last three financial (2015-16, 2016-17, 2017-18) years should be at least `27,21,300/- and statement to be authenticated by Chartered Accountant.

4. The tenderer must be registered in GST, ESI, EPFO and also shall furnish the self attested copies of remitted challan for latest six months as mentioned below.

(i) ESI, EPFO, GST. (ii) Any other registration which is mandatory for such agencies stipulated

by concerned authorities from time to time.

of 51

5. The following documents must be submitted along with the Tender documents: (i) Income Tax returns for last three financial years (2015-16, 2016-17, 2017-18). (ii) Audited Balance Sheet of Last three financial years (2015-16, 2016-17, 2017-

18) along with Income and Expenditure Statement (P&L Account & Audit Reports signed by Chartered Accountant to be submitted)

6. The tenderer must have Electrical Licence in the name of company which is not less than “EA” i.e Grade ‘A’ issued by Electrical Licensing Board.

16. Submission of bids: Bidders should submit the tender through online only at https://esictenders.eproc.in, hard copy of the same proposals should be submitted in separate envelopes namely, “EMD” and “Technical Bid” (Part A) and “Financial Bid” (Part B) are duly sealed in two separate envelopes and these two envelopes must be kept inside a separate big size third envelope and clearly superscribed as “Special repairs to (Civil & Electrical) works at ESI Hospital and Staff Quarters, ESI Hospital, Gorimedu, Puducherry” The envelope should be clearly marked as “Technical Bid & EMD” (Envelope-I) and “Financial Bid” (Envelope-II).

17. Verification of EMD : The Technical Bids dropped in the tender box will be opened first and Demand Draft for the EMD will be verified and after satisfying the EMD conditions the tender will be considered for evaluation of Technical Bid.

18. Evaluation of Technical Bids : After satisfying EMD, the technical bids will be evaluated by the committee to ascertain the qualifying criterion i.e. works experience, eligibility criteria, financial background etc.. The tenders will be evaluated based on the information sought for in the prescribed formats I & II of part A‟. All documents in support of details and work completion certificates etc., should bear the stamp and signature of the authorized representative / quoting firm and shall be enclosed with the Technical Bid.

19. Financial bid : The financial bid of the tenderers, whose Technical Bid is qualified, the qualified tenderers as per eligibility criteria and same will be opened in the presence of the tenderer, who choose to attend the opening of financial bid. Minimum one day notice will be given to the tenderer for this purpose.

20. Duly filled scanned tender document should be dropped in the tender box available at following address on or before 26/03/2019 upto 10.30 am.

The Regional Director Regional Office Employees’ State Insurance Corporation R.S. No. 89/2, Bouvankare Street, Esic Complex, Mudaliarpet, Puducherry - 605 004

21. Delay / Late tenders for whatever be the reason will be summarily rejected. 22. Award of work : The selection of the agency will be at the sole discretion of the ESIC

who reserves its right to accepts or reject any or all the proposals without assigning any reason.

23. These instructions shall form a part of the contract document.


of 51

ANNEXURE – ‘B’

GENERAL CONDITIONS OF CONTRACT Definitions and interpretation

Definitions

(a) In the contract (as hereinafter defined) the following works and expressions shall have the meanings hereby assigned to them except where the context otherwise requires:

i) Employer” means the ESIC and the legal successors in title to ESIC.

ii) “Engineer” means the person appointed by ESIC to act as Engineer for the purposes of the Contract.

iii) “Contractor” means an individual or firms (proprietary or partnership) whether incorporated or not, that has entered into contract (with the employer) and shall include his/its heirs, legal representatives, successors and assigns. Changes in the constitution of the firm, if any shall be immediately notified to the employer, in writing and approval obtained for continued performance of the contract.

(b) (i) “Contract” means these conditions, the Specification, the Bill of Quantities, the Tender, the Letter of acceptance, the Contract Agreement (if completed) and such further documents as may be expressly incorporated in the Letter of Acceptance or Contract Agreement (if completed).

(ii) “Specification” means the specification of the works included in the Contract and any modification thereof.

(iii) “Drawings” means all the completion drawings, calculations and technical information of a like nature provided by the Engineer to the Contractor under the Contract and all drawings, calculations, samples, patterns, models and other technical information of a like nature submitted by the Contractor and approved by the Engineer.

(iv) “Bill of Quantities” means the priced and competed bill of quantities forming part of the Tender.

(v) “Tender” means the Contractor’s priced offer to the Employer for the execution and completion of the works and the remedying of any defects therein accordance with the provisions of the Contract, as accepted by the Letter of Acceptance. The word tender is synonymous with “Bid” and the words “Tender Documents” with “Bidding Documents”.

(vi) “Letter of Acceptance” means the formal acceptance of the tender by ESIC.

of 51

(vii) “Contract Agreement” means the contract agreement (if any) referred to in (b) (i) above.

(viii) “Appendix to Tender” means the appendix comprised in the form of Tender annexed to these Conditions.

(c) (i) “Commencement Date” means the date upon which the Contractor is handed over with the site.

(ii) “Time for Completion” means the time period for which the contract of Special Repairs has been awarded by the employer to the contractor.

(d) (i) “Taking over Certificate” means a certificate issued by employer evidencing successful completion of the awarded work.

(e) (i) “Contract Price” means the sum stated in the Letter of Acceptance as payable to the Contractor for the execution and completion of the works and remedying of any defects therein in accordance with the provisions of the Contract.

(ii) “Retention Money” means the aggregate of all monies retained by the Employer.

(f) (i) “Works” means the Permanent Works and the Temporary Works or either of them to be executed in accordance with the contract.

(ii) “Site” means the places provided by the Employer Special repairs to (Civil & Electrical) works at ESI Hospital and Staff Quarters, ESI Hospital, Gorimedu, Puducherry

(iii) “Cost” means all expenditure properly incurred or to be incurred, whether on or off the site, including over head and other charges but does not include any allowance for profit.

1. ENGINEER - Engineer‟s Duties and Authority The Engineer shall carry out the duties specified in the Contract

2. Custody and supply of drawings and documents The drawings shall remain the sole custody of the Employer/Engineer, but

copies as required thereof shall be provided to the contractor free solely for the purpose of this contract.

3. Sufficiency of Tender The Contractor shall be deemed to have based his Tender on the data made

available by the Employer and on his own inspection and examination of the site conditions besides all prevailing statutory taxes.

4. Contractors’ Employees

The Contractor shall provide on the Site qualified and experienced technical staff in connection with Special repairs to (Civil & Electrical) works at ESI Hospital and Staff Quarters, ESI Hospital, Gorimedu, Puducherry remedying of any defects therein.

of 51

5. Engineer at Liberty to Object The Engineer shall be at liberty to object and to request the Contractor to

remove forthwith from the works any person provided by the Contractor, who in the opinion of the Engineer, misconducts himself, or is incompetent or negligent in the proper performance of his duties, or whose presence on Site is otherwise considered by the Engineer to be undesirable, and such person shall not be again allowed upon the works without the consent of the Engineer. Any person so removed from the Works shall be replaced as soon as possible by a qualified person approved by the Engineer.

6. Safety, Security and Protection of the Environment

The Contractor shall, throughout the execution and completion of the works and the remedying of any defects therein:

i) Have full regard for the safety of all persons entitled to be upon the site and keep the site (so far as the same is under his control) and the Works (so far as the same are not completed or occupied by the Employer) in an orderly state appropriate to the avoidance of danger to such persons, and

ii) Provide and maintain at his own cost all lights, guards, fencing, warning signs and watching, when and where necessary or required by the Engineer or by any duly constituted authority for the protection of the Works or for the safety and convenience of the public or others, and

iii) Take all reasonable steps to protect the environment on and off the site and to avoid damage or nuisance to persons or to property of the public or others resulting from pollution, noise or other causes arising as a consequence of his methods of work.

7. Procurement of materials :

The Contractor shall procure all the materials required for the work and the materials shall be in accordance with the relevant specifications of CPWD/BIS. The materials shall be got approved by the Engineer-in-charge before it is consumed into works. The contractor shall also arrange all the required plant and machinery.

8. (a) Insurance of work by the Contractor for his liability : The contractor should get necessary insurance cover for the work towards all his liabilities due to the work such as.

(i) Any loss or damage to property and life arising from a cause for which contractor / his employees are responsible, during the period of work.

(ii) Any loss or damage occasioned by the Contractor / his employees in the course of any work carried out by them for the purpose of complying with the obligations of the work.

It shall be the responsibility of contractor to notify the Insurance Company of any change in the nature and extent of the works and to ensure the adequacy of insurance cover all times during the period of contract.

of 51

(b) Damage to Persons and Property

The Contractor shall, except if and so far as the Contract provides otherwise, indemnify the Employer against all losses and claims in respect of:

(a) death of or injury to any person, and (b) loss or damage to any property

Which may arise out of or in consequence of the works and the remedying of any defects therein, and against all claims, proceedings, damages, costs, charges and expenses whatsoever in respect thereof.

9. Evidence and Terms of Insurance

The Contractor shall take out appropriate insurance to cover his work and workers and staff employed him fully. The contractor shall provide evidence to the Engineer/Employer as soon as practicable after the respective insurance has been taken out but in any case prior to start of work at the site that insurance required under Contract have been effected.

10. Accident or injury to Workmen

The Employer shall not be liable for or in respect of any damages or compensation payable to any workman for death or injury resulting from any act or default of the contractor. The contractor shall indemnify and keep indemnified the Employer against all such damages and compensation and expenses whatsoever in respect thereof or in relation thereto.

11. Compliance with Statutes, Regulations

The Contractor shall conform in all respects, including by giving of all notices and the paying of all fees, with the provision of :

(a) Any National or State Statute, Ordinance, or other Law, or any regulation, or bye-law of any local or other duly constituted authority in relation to the execution and completion of the Works and the remedying of any defects therein, and

(b) The rules and regulations of all public bodies and companies whose property or rights are affected or may be affected in any way by the Works, and the Contractor shall keep the Employer indemnified against all penalties and liability of every kind for breach of any such provision.

(c) Any changes required for approval due to revision of the local laws.

12. Compliance with labour laws

The contractor shall be responsible for ensuring compliance with the labour laws that may be in force from time to time. All liabilities on account of the same shall be met by the Contractor.

13. Default of contractor in compliance

In case of default on the Contractor in carrying out such instruction within the time specified therein or, in none, within a reasonable time, the Employer shall be entitled to employ and pay other persons to carry out the same and all costs

of 51

consequent thereon or incidental thereto shall, be determined by the Engineer and shall be recoverable from the Contractor by the Employer, and may be deducted by the Employer from any monies due or to become due to the Contractor and the Engineer shall notify the Contractor accordingly.

14. Time for Completion

Special repairs to (Civil & Electrical) works at ESI Hospital and Staff Quarters, ESI Hospital, Gorimedu, Puducherry should be completed within the period of 150 days from the date of issue of the work order. If the Contractor fails to complete the work in time liquidated damages at 1.25% of total value of work under measurable items of work above shall be recovered subject to maximum of 5% of the above total value.

15. Extension of Time for Completion

Special repairs to (Civil & Electrical) works at ESI Hospital and Staff Quarters, ESI Hospital, Gorimedu, Puducherry should be completed within the period specified in the terms and condition. However, extension of time will be given, if the work is delayed due to administrative reasons or due to natural calamities for which necessary requests to be given by the contractor to the authorities for granting extension of time.

16. Defect liability period Defect liability period shall be 12 months from the date of completion of work under BOQ measurable works. The contractor shall rectify at his own expenses any defect in the work carried out by him during this period. On failure of the contractor to do so, the same shall be completed by the employer at the risk and cost of the contractor.

17. Contractor’s failure to carry out Instructions In case of default on the part of the Contractor in carrying out defect rectification works, the Employer/Engineer shall be entitled to employ and pay other persons to carry out the same and if such work, in the opinion of the Engineer, the Contractor was liable to do at his own cost under the Contract, then all costs consequent thereon or incidental thereto shall be determined by the Engineer and shall be recoverable from the Contractor by the Employer, and may be deducted by the Employer from any monies due or to become due to the Contractor.

18. Instruction for Variations

Quantities given in the BOQ are estimated quantities. The quantity of any particular item may vary to any extent during execution, if found necessary. Variation in quantity in particular items or overall cost, does not entitle contractor to claim any extra cost.

MEASUREMENT

19. Works to be measured for BOQ items

The Engineer shall determine by measurement of the value of actual work done in accordance with the Contract and the Contractor shall be paid proportionately. Part rate shall be made for any part of BOQ items not fully

of 51

executed. Engineer shall be at liberty to decide the break up of Lump Sum items and to decide the part rate for any particular item.

20. Method of Measurement

The works shall be measured net, notwithstanding any general or local custom, except where otherwise provided in the Contract.

21. Deduction of Statutory Taxes

The TDS amount to be deducted towards the advance income tax and GST shall be at the rates applicable. Further, recoveries towards statutory Taxes such as Labour Welfare Cess etc due to the contractors’ will be deducted from the contractors’ payment as per prevailing norms. The GST shall be paid by the contractor to the concerned department as per the rules prevailing at the time of completion of works.

22. EMD The EMD of the unsuccessful tenders will be returned within 30 (thirty) days

of the award of contract. In case of the successful tenderer, the EMD shall be adjusted against Security Deposit to be retained by the Corporation.

23. Performance Guarantee

The contractor is to submit Performance Guarantee for a value of 5% of the Tender value in the form of bank guarantee within two weeks from the date of acceptance letter. The work order will be issued only after submission of Performance Guarantee. Performance Guarantee shall be valid for the duration of contract period plus 60 days.

24. Security Deposit

Security deposit at 5% shall be deducted from each bill due to the contractor which shall be refunded after expiry of defect liability period of one year from the date of completion of work. The defect noticed within the period should be rectified by the contractor to the satisfaction of ESIC. If the contractor fails to rectify any such defect within 15 days from the date of intimation, the ESIC is at liberty to get it done through other means and the expenditure towards it inclusive of incidental and miscellaneous charges will be recovered from the Security Deposit.

25. Default of Contractor

If the performance of the contract is not satisfactory and not corrected within 15 days of receiving notice, then employer shall be at liberty to terminate the contract and get the work executed through other means at the risk and cost of the Contractor.

26. Amicable Settlement of Dispute

The party shall use their best efforts to settle amicably all disputes arising out of or in connection this contract or the interpretation thereof.

26.1 Arbitration.

Any dispute and differences relating to the meaning of the specifications, design, drawings and instructions herein before mentioned

of 51

and as to the quality of workmanship of materials used in the work or as to any other question, claim, right, matter of thing whatsoever in any way arising out of or relating to the contract, designs, drawings, specifications, estimates, instructions or these conditions or otherwise concerning the works or the execution or failure to execute the same whether arising during the progress of the work or after the completion or abandonment thereof in respect of which :- Amicable settlement has not been reached, shall be referred to the Sole Arbitration of the Chief Engineer, ESIC who shall proceed as per the Arbitration Act, 1996.

26.2 The work under the contract shall continue, during the Arbitration proceedings.

26.3 The award of the Arbitrator shall be final, conclusive and binding on both the parties.

27. Payment on termination ; In the event of termination of the contract, employer shall be at liberty to get balance work done at the risk and cost of the contractor and due payment of the contractor, if any, shall be released after the completion of whole of the works.

28. The Contractor shall procure all the materials required for the work and the materials shall be in accordance with the relevant specifications of CPWD/IS specification/manufacturers specifications. The materials shall be got approved by the ESIC Engineer before it is consumed into works. The contractor shall also arrange all the required plant and machinery.

29. The contractor shall also be responsible for proper handing over of the dismantled materials to ESIC Engineer along with details of the same in writing.

30. Disposal of building rubbish/malba/ similar unserviceable, dismantled or waste materials by mechanical means, including loading, transporting, unloading at the approved municipal dumping ground.

of 51

ANNEXURE – ‘C’ PARTICULAR CONDITIONS OF CONTRACT

§ CPWD specifications shall be followed. Where not available, BIS/Engineering practice as directed by the Engineer shall be followed.

§ As the work will have to be carried out in building and area in use the contractor shall ensure :

a) That the normal functioning of ESIC activity is not affected as far as possible.

b) That the work is carried out in an orderly manner without noise and obstruction to flow of traffic.

c) That all rubbish etc. is disposed off at the earliest and place is left clean and orderly at the end of each day’s work.

d) The contractor shall ensure that the staff for the work of Special repairs to (Civil & Electrical) works at ESI Hospital and Staff Quarters, ESI Hospital, Gorimedu, Puducherry are qualified in Civil and licensed in Electrical and all are shall be responsible for their conduct. The staff should behave in a courteous manner. The contractor shall be held responsible for any loss or damage to ESIC property during execution.

e) The contractor shall ensure safety of his workers and others at site of work and shall be responsible for any consequence arising out of execution of work.

f) The contractor shall be responsible for proper handing over of the valuable / reasonable dismantled materials, if any, to ESIC in-charge along with details of the same in writing. Further, the contractor shall also ensure proper record keeping and storing of irreparable/dismantled materials, when instructed to do so.

g) The contractor has to make his own arrangement for water supply and electricity for use of the same including drawing temporary lines etc. The responsibility for following relevant rules, regulations and loss in the regard shall be entirely that of the contractor.

h) Formats of Performance Guarantee and Contract Agreement are at enclosed as Enclosure I and II respectively.

of 51

ANNEXURE-E

(TO BE TYPED ON BIDDER'S LETTER HEAD)

UNDERTAKING

To,

The Regional Director

Regional Office, ESI Corporation,

R.S. No. 89/2, Bouvankare Street,

Mudaliarpet, Puducherry - 605 004

Sub: Tender for Special repairs to (Civil & Electrical) works at ESI Hospital and Staff Quarters, ESI Hospital, Gorimedu, Puducherry - Reg

Sir,

1. I/We hereby agree to abide by all the terms and conditions laid down in tender document.

2. This is to certify that I/We before signing this bid have read and fully understood all the terms and conditions and instructions contained therein and undertake myself/ourselves abide by the said terms and conditions.

3. I/We shall deploy only physically and mentally fit personnel.

Signature

Name

Seal

of 51

ANNEXURE - F

Check list of the documents to be submitted with the tender Confirm the enclosure of all the below listed documents without which tenderer may not be eligible to participate in the tender.

S.No Items Yes/No

1. EMD

2. Tender form with complete technical bid with all pages serially numbered, signed and stamped on each page

3. Audited Balance sheet of last three financial years 2015-16, 2016-17, 2017-18 with details of annual turnover, profit/loss account etc.

4. Income tax statement of last three financial years (2014-15, 2015-16, 2016-17) and paid acknowledgment.

5. Attested Photo copy of PAN Card

6. ESI Registration certificate copy with payment details with last six months

7. EPFO Registration certificate copy with latest payment detail for last six months

8. GST Registration as per latest directives and latest payment detail for last six months

9 Documents in support of contracts fulfilled in last 3 years along with their values in support of the experience and financial credibility with TDS (Form-26 A) Certificate

10 Satisfactory completion of contract certificate from previous organizations

11 Copy of Registration/enlistment with any Central/State PWD /PSU/Autonomous Bodies for civil and electrical with current validity.

12 Contractors Employees qualifying certificates as required for financial bid.

13 Copy of the Electrical Licence of the company (not less than “EA” – Grade ‘A’)

14 Any other details

of 51

PART-A

(Technical Bid)

Format - I

BRIEF DESCRIPTION OF THE FIRM

(All the columns should be filled up properly. Otherwise the bid submitted will be considered as incomplete)

a. BRIEF DESCRIPTION OF THE FIRM

(With an outline of the experience of the firm for similar works during last three years)

1 NAME OF TENDERING COMPANY / FIRM / TENDERER

:

2 NAME OF OWNER / DIRECTORS :

3 FULL PARTICULARS OF OFFICE

a) Address

:

b) Telephone No :

c) Fax No :

d) E-Mail Address :

4 FULL PARTICULARS OF THE BANKERS OF COMPANY / FIRM /.

a) Name of the Bank :

b) Address of the Bank :

c) Type of Account and Account No. :

d) MICR/IFSC code :

5 REGISTRATION DETAILS

a) PAN / GIR No. :

b) GST Registration No. :

6 DETAILS OF EARNEST MONEY DEPOSIT

of 51

a) Amount (Rs.) :

b) D.D. No. and Date :

c) Drawn on Bank :

d) Valid up to :

8 WHETHER THE AGENCY IS BLACK LISTEDBY ANY STATE/CENTRAL GOVT

:

9 TURN OVER OF THE FIRM FOR THE FINANCIAL YEAR

a) 2015-16 :

b) 2016-17 :

c) 2017-18 :

Note :-

§ Provide documents in support of the details provided in above format, failing which the authenticity of the information may not be accepted.

of 51

Format II

EXPERIENCE OF COMPANY

(All the columns should be filled up properly. Otherwise the bid submitted will be considered incomplete)

Experience in works of similar nature, completed during last seven years as on date of tender opening.

(Works executed for the Public Sector & Government undertakings & Government Departments like PWD, CPWD etc only will be taken for consideration)

1. No. of similar works completed in the last 7 years (Nos. only may be noted)

i. Works of value more than `68,84,100/-

ii. Works of value more than `43,02,600/-

iii. Works of value more than `34,42,100/-

2. Describe area of Participation (Specific work done by the applicant)

3. Details of on going works - Date of start of the work and the present status

4. Any other details regarding works

Note :-

§ Supporting documents like work completion certificates from the client in support of each of the above work is to be furnished.

of 51

Enclosure I

FORM OF PERFORMANCE SECURITY BANK GUARANTEE BOND

In consideration of the ESIC having agreed under the terms and conditions of the Agreement No._____ dated ________ made between ESIC and Second Party (herein after called the said Construction Agency) ______________ for the work Special repairs to (Civil & Electrical) works at ESI Hospital and Staff Quarters, ESI Hospital, Gorimedu, Puducherry hereinafter called the said agreement) to production of irrevocable bank guarantee for Rs. _______________ (Rupees_________________________________________ ____________________________________________________________ only) as a security/Guarantee from the Construction Agency for compliance of his obligations in accordance with the terms and conditions in the said agreement, We___________________________________(hereinafter referred as to “the Bank” hereby) (indicate the name of the bank) Undertake to pay to the ESIC an amount not exceeding Rs. ___________________ (Rupees ______________________________________ only) on demand by the ESIC. 2. We _____________________ do hereby undertake to pay the amounts due and payable under this Guarantee without any demure, merely on a demand from the ESIC stating that the amount claimed is required to meet the recoveries due or likely to be due from the Construction agency. Any such demand made on the Bank shall be conclusive as regards the amount due and payable by the bank under this Guarantee. However, our liability under this guarantee shall be restricted to an amount not exceeding Rs.___________ (Rupees _________________________ only). 3. We, __________________further undertake to pay to the ESIC any money that is demanded notwithstanding any dispute or disputes raised by the Construction agency in any suit or proceeding pending before any court or Tribunal relating thereto, a liability under this present being absolute and unequivocal. The payment so made by us under this bond shall be a valid discharge of a liability for payment there under and the Construction agency shall have no claim against us making such payment. 4. We __________________________ further agree that the guarantee herein contained shall remain in full force and effect during the period that would taken for the performance of the said agreement and that it shall continue to enforceable till all the dues of the ESIC under or by virtue of the said agreement have been fully paid and its claims satisfied or

of 51

discharged or Engineer-in-Charge on behalf of the ESIC certified that the terms and conditions of the said agreement have been fully and properly carried out by the Construction agency and accordingly discharges this guarantee. 5. We __________________________ further agree with the ESIC that, the ESIC shall have the fullest liberty without our consent and without effecting in any manner our obligations hereunder to vary any of the terms and conditions of the said agreement or to extend time of performance by the said contractor(s) from time to time or to postpone for any time or form time to time any of the powers exercisable by the ESIC against the said Construction agency and to bear or enforce any of the terms and conditions relating to the said agreement and we shall not be relieved from our liability by reasons of any such variation, or extension being granted to the said contractor or for any forbearance, act of omission on the part of the ESIC or any indulgence by the ESIC to the said contractors or by any such matter or thing whatsoever which under the law relating to sureties would, but for this provision, have effect of so relieving us. 6. The guarantee will not be discharged due to the change in the constitution of the Bank or the contractor. 7. We_____________________ lastly undertake not to revoke this guarantee except with the previous consent of the ESIC in writing.

8. This guarantee shall be valid upto _______. Unless extended on demand by ESIC. Notwithstanding anything mentioned above, our liability against this guarantee is restricted to Rs.__________(Rupees _______________________________________________only) and unless a claim in writing is lodged with us within six months of the date of expiry of the extended date of expiry of this guarantee all our liabilities under this guarantee shall stand discharged. Dated the _______ day of ____________________ for ______________________________

(indicate the name of bank).

of 51

Enclosure – II

CONTRACT AGREEMENT FORMAT

This CONTRACT (hereinafter called the “Contract”) is made on this ______ day of the

month of ______ 2019 between Office of The Regional Director, Regional Office, ESI

Corporation,

R.S. No. 89/2, Bouvankare Street,

Mudaliarpet, Puducherry - 605 004

on the one hand (hereinafter called the Employer) and on the other hand

_________________________________________________________(hereinafter called the

Contractor)

Whereas

a. the Employer has accepted the offer of the Contractor to provide certain services for carry out Special repairs to (Civil & Electrical) works at ESI Hospital and Staff Quarters, ESI Hospital, Gorimedu, Puducherry .

b. the Contractor, having represented to the Employer that they have the required professional skills, personnel and technical resources, have agreed to provide the services on the terms and conditions set forth in this Contract Agreement.

Now therefore the parties hereto hereby agree as follows: 1.0 The following documents attached hereto shall be deemed to from an integral part of

this contract :

1. Instruction to Tenderers Annexure ‘A’

2. General Conditions of Contract Annexure ‘B’

3. Particular conditions of contract along with Enclosure I, II, III & IV Annexure ‘C’

4. Programme of work other than day to day maintenance (Financial Bid) Annexure ‘D’

5. Undertaking Annexure ‘E’ 6. Checklist of documents submitted with tender Annexure ‘F’

2.0 The mutual rights and obligations of the Employer and the Contractor shall be as set

forth in the contract; in particular:

a. The Contractor shall carry out the services in accordance with the provisions of the contract; and

of 51

b. The Employer shall make payments to the contractor in accordance with the provisions of the contract.

In witness whereof, the parties hereto have caused this contract to be signed in their respective names as of the day and year first above written.

FOR AND ON BEHALF OF FOR AND ON BEHALF OF CONTRACTOR EMPLOYER

The Regional Director Regional Office, ESI Corporation, R.S. No. 89/2, Bouvankare Street,

Mudaliarpet, Puducherry - 605 004 .

of 51

ABSTRACT OF COST Name of Work: Special Repairs (Civil & Electrical) for Ramp, Repairs to Old Quarters (12 Unit) including Electrical re-wiring arrangments, Shifting Pillar Box from the power room in to ESI Hospital Gorimedu at Puducherry Region I - CIVIL WORKS Sl. No. DSR No Description of Works Qty Rate Per Amount DSR ITEMS 1 2.31 Clearing jungle including

uprooting of rank vegetation, grass, brush wood, trees and saplings of girth up to 30 cm measured at a height of 1 m above ground level and removal of rubbish up to a distance of 50 m outside the periphery of the area cleared.

52500.00 7.20 sqm 378000.00

2 2.8.1 Earth work in excavation by mechanical means (Hydraulic excavator) / manual means. All kinds of soil in foundation trenches or drains (not exceeding 1.5 m in width or 10 sqm on plan), including dressing of sides and ramming of bottoms, lift upto 1.5 m, including getting out the excavated soil and disposal of surplus excavated soil as directed, within a lead of 50 m.

190.00 166.40 cum 31615.92

3 4.1.3 Providing and laying in position cement concrete of specified grade excluding the cost of centering and shuttering - All work up to plinth level : 1:2:4 (1 cement : 2 coarse sand (zone-III) : 4 graded stone aggregate 20 mm nominal size)

1.50 5481.95 cum 8217.44

4 4.1.8 Providing and laying in position cement concrete of specified grade excluding the cost of centering and shuttering - All work up to plinth level : 1:4:8 (1 Cement : 4 coarse sand (zone-III) : 8 graded stone aggregate 40 mm nominal size)

40.00 4478.15 cum 179117.04

of 51

5 5.1.2 Providing, hoisting and fixing above plinth level up to floor five level precast reinforced cement concrete work in string courses, bands, copings, bed plates, anchor blocks, plain window sills and the like, including the cost of required centering, shuttering but , excluding cost of reinforcement, with 1:1.5:3 (1 cement: 1.5 coarse sand(zone-III) : 3 graded stone aggregate 20 mm nominal size).

2.50 6215.35 cum 15516.50

6 5.3 Reinforced cement concrete work in beams, suspended floors, roofs having slope up to 15° landings, balconies, shelves, chajjas, lintels, bands, plain window sills, staircases and spiral stair cases above plinth level up to floor five level, excluding the cost of centering, shuttering, finishing and reinforcement, with 1:1.5:3 (1 cement : 1.5 coarse sand (zone-III) : 3 graded stone aggregate 20 mm nominal size).

4.00 7390.80 cum 29563.20

7 5.12 Providing, hoisting and fixing above plinth level up to floor five level precast reinforced cement concrete work in string courses, bands, copings, bed plates, anchor blocks, plain window sills and the like, including the cost of required centering, shuttering but , excluding cost of reinforcement, with 1:1.5:3 (1 cement: 1.5 coarse sand(zone-III) : 3 graded stone aggregate 20 mm nominal size).

3.00 6972.10 cum 20942.24

8 5.13 Providing, hoisting and fixing up to floor five level precast reinforced cement concrete in small lintels not exceeding 1.5m clear span up to floor five level, including the cost of required centering, shuttering but , excluding the cost of reinforcement, with 1:1.5:3 (1 cement : 1.5 coarse sand(zone-III) : 3 graded stone aggregate 20 mm nominal size).

0.50 9330.20 cum 4702.42

of 51

9 5.16 Providing, hoisting and fixing above plinth level up to floor five level precast reinforced cement concrete in shelves, including setting in cement mortar 1:3 (1cement : 3 coarse sand), cost of required centering, shuttering and finishing with neat cement punning on exposed surfaces but , excluding the cost of reinforcement, with 1:1.5:3 (1 cement : 1.5 coarse sand(zone-III) : 3 graded stone aggregate 20 mm nominal size).

0.60 12726.55 cum 7688.87

10 5.9.3 Centering and shuttering including strutting, propping etc. and removal of form for all heights : Suspended floors, roofs, landings, balconies and access platform

67.00 422.30 sqm 28295.79

11 5.9.5 Centering and shuttering including strutting, propping etc. and removal of form for all heights :Lintels, beams, plinth beams, girders, bressumers and cantilevers

18.00 342.09 sqm 6157.96

12 5.22.3 Steel reinforcement for R.C.C. work including straightening, cutting, bending, placing in position and binding all complete upto plinth level. Cold twisted bars

1450.00 56.60 kg 82070.00

13 6.1.1 Brick work with common burnt clay F.P.S. (non modular) bricks of class designation 7.5 in foundation and plinth in:Cement mortar 1:4 (1 cement : 4 coarse sand)

33.00 7970.30 cum 263019.90

14 6.1.2 Brick work with common burnt clay F.P.S. (non modular) bricks of class designation 7.5 in foundation and plinth in: Cement mortar 1:6 (1 cement : 6 coarse sand)

5.00 4751.65 cum 23740.38

15 6.4.2 Brick work with common burnt clay F.P.S. (non modular) bricks of class Cement mortar 1:6 (1 cement : 6 coarse sand) designation 7.5 in superstructure above plinth level up to floor V level in all shapes and sizes in :

7.00 5582.85 cum 39064.32

of 51

16 6.8 Brick work 7 cm thick with common burnt clay F.P.S. (non modular) brick of class designation 7.5 in cement mortar 1:3 (1 cement : 3 coarse sand) in superstructure above plinth level and upto floor five level.

53.00 535.50 sqm 28381.50

17 6.12.2 Half brick masonry with common burnt clay F.P.S. (non modular) bricks of class designation 7.5 in foundations and plinth in :

31.00 593.50 sqm 18398.50

18 6.13.2 Half brick masonry with common burnt clay F.P.S. (non modular) bricks of class designation 7.5 in superstructure above plinth level up to floor V level. Cement mortar 1:4 (1 cement :4 coarse sand)

10.00 684.20 sqm 6842.00

19 9.1.2 Providing wood work in frames of doors, windows, clerestory windows and other frames, wrought framed and fixed in position with hold fast lugs or with dash fasteners of required dia & length ( hold fast lugs or dash fastener shall be paid for separately). Sal wood

0.50 85386.95 cum 42693.48

20 9.21.2 Providing and fixing ISI marked flush door shutters conforming to IS : 2202(Part I) non-decorative type, core of block board construction with frame of 1st class hard wood and well matched commercial 3 ply veneering with vertical grains or cross bands and face veneers on both faces of shutters: 30 mm thick including ISI marked Stainless Steel butt hinges with necessary screws.

32.00 1559.75 sqm 49912.00

21 9.53 Providing 40x5 mm flat iron hold fast 40 cm long including fixing to frame with 10 mm diameter bolts, nuts and wooden plugs and embedding in cement concrete block 30x10x15cm 1:3:6 mix (1 cement : 3 coarse sand : 6 graded stone aggregate 20mm nominal size).

50.00 118.60 esch 5930.00

of 51

22 9.55.1 Providing and fixing ISI marked M.S. pressed butt hinges bright finished with necessary screws etc. complete : 125x65x2.12 mm

60.00 35.10 each 2106.00

23 9.62.1 Providing and fixing ISI marked oxidised M.S. sliding door bolts with nuts and screws etc. complete : 300x16 mm

16.00 154.85 each 2477.60

24 9.63.1 Providing and fixing ISI marked oxidised M.S. tower bolt black finish, (Barrel type) with necessary screws etc. complete : 250x10 mm

32.00 64.00 each 2048.00

25 9.63.2 Providing and fixing ISI marked oxidised M.S. tower bolt black finish, (Barrel type) with necessary screws etc. complete : 200x10 mm

48.00 51.05 each 2450.40

26 9.66.1 Providing and fixing ISI marked oxidised M.S. handles conforming to IS:4992 with necessary screws etc. complete :125 mm

32.00 28.60 each 915.20

27 9.66.2 Providing and fixing ISI marked oxidised M.S. handles conforming to IS:4992 with necessary screws etc. complete : 100 mm

32.00 22.65 each 724.80

28 9.69 Providing and fixing oxidised M.S. Safety chain with necessary fixtures for doors, (weighting not less than 450 gms)

12.00 77.65 each 931.80

of 51

29 9.147.D.1 Providing and fixing factory made uPVC white colour sliding glazed window upto 1.50 m in height dimension comprising of uPVC multi-chambered frame with in-built roller track and sash extruded profiles duly reinforced with 1.60 ±0.2 mm thick galvanized mild steel section made from roll forming process of required length (shape & size according to uPVC profile), appropriate dimension of uPVC extruded glazing beads and uPVC extruded interlocks, EPDM gasket, wool pile, zinc alloy (white powder coated) touch locks with hook, zinc alloy body with single nylon rollers (weight bearing capacity to be 40 kg), G.I fasteners 100 x 8 mm size for fixing frame to finished wall and necessary stainless steel screws etc. Profile of frame & sash shall be mitred cut and fusion welded at all corners, including drilling of holes for fixing hardware's and drainage of water etc. After fixing frame the gap between frame and adjacent finished wall shall be filled with weather proof silicon sealent over backer rod of required size and of approved quality, all complete as per approved drawing & direction of Engineer-in-Charge. (Single / double glass panes, wire mesh and silicon sealent shall be paid separately) Note: For uPVC frame and sash extruded profiles minus 5% tolerance in dimension i.e. in depth & width of profile shall be acceptable. Two track two panels sliding window made of (small series) frame 52 x 44 mm & sash 32 x 60 mm both having wall thickness of 1.9 ± 0.2 mm and single glazing bead of appropriate dimension. (Area of window upto 1.75 sqm)

84.00 5608.60 sqm 471122.40

of 51

30 10.16.2 Steel work in built up tubular (round, square or rectangular hollow tubes etc.) trusses etc., including cutting, hoisting, fixing in position and applying a priming coat of approved steel primer, including welding and bolted with special shaped washers etc. complete.Hot finished seamless type tubes

250.00 93.90 kg 23475.00

31 10.29.2 Providing & fixing fly proof wire gauze to windows, clerestory windows & doors with M.S. Flat 15x3 mm and nuts & bolts complete. Stainless steel (grade 304) wire gauze of 0.5 mm dia wire and 1.4 mm aperture on both sides

84.00 1041.55 sqm 87490.20

32 11.36 Providing and fixing Ist quality ceramic glazed wall tiles conforming to IS: 15622 (thickness to be specified by the manufacturer), of approved make, in all colours, shades except burgundy, bottle green, black of any size as approved by Engineerin- Charge, in skirting, risers of steps and dados, over 12 mm thick bed of cement mortar 1:3 (1 cement : 3 coarse sand) and jointing with grey cement slurry @ 3.3kg per sqm, including pointing in white cement mixed with pigment of matching shade complete.

165.00 744.80 sqm 122892.00

33 11.37 Providing and laying Ceramic glazed floor tiles of size 300x300 mm (thickness to be specified by the manufacturer) of 1st quality conforming to IS : 15622 of approved make in colours such as White, Ivory, Grey, Fume Red Brown, laid on 20 mm thick cement mortar 1:4 (1 Cement : 4 Coarse sand), Jointing with grey cement slurry @ 3.3 kg/sqm including pointing the joints with white cement and matching pigment etc., complete.

290.00 688.35 sqm 199621.50

of 51

34 11.41.2 Providing and laying vitrified floor tiles in different sizes (thickness to be specified by the manufacturer) with water absorption less than 0.08% and conforming to IS: 15622, of approved make, in all colours and shades, laid on 20mm thick cement mortar 1:4 (1 cement : 4 coarse sand), jointing with grey cement slurry @ 3.3kg/sqm including grouting the joints with white cement and matching pigments etc., complete. Size of Tile 600x600 mm

517.00 1119.40 sqm 578729.80

35 12.20 Providing and laying pressed clay tiles (as per approved pattern 20 mm nominal thickness of approved size) on roofs jointed with cement mortar 1:4 (1 cement : 4 coarse sand) mixed with 2% integral water proofing compound, laid over a bed of 20 mm thick cement mortar 1:4 (1 cement : 4 coarse sand) and finished neat complete.

222.00 438.45 sqm 97335.90

36 12.50 Providing and fixing precoated galvanised iron profile sheets (size, shape and pitch of corrugation as approved by Engineer-in-charge) 0.50 mm (+ 0.05 %) total coated thickness with zinc coating 120 grams per sqm as per IS: 277, in 240 mpa steel grade, 5-7 microns epoxy primer on both side of the sheet and polyester top coat 15-18 microns. Sheet should have protective guard film of 25 microns minimum to avoid scratches during transportation and should be supplied in single length upto 12 metre or as desired by Engineer-in-charge. The sheet shall be fixed using self drilling /self tapping screws of size (5.5x 55 mm) with EPDM seal, complete upto any pitch in horizontal/ vertical or curved surfaces, excluding the cost of purlins, rafters and trusses and including cutting to size and shape wherever required.

45.00 550.40 sqm 24768.00

of 51

37 12.41.1 Providing and fixing on wall face unplasticised Rigid PVC rain water pipes conforming to IS : 13592 Type A, including jointing with seal ring conforming to IS : 5382, leaving 10 mm gap for thermal expansion, (i) Single socketed pipes. 110 mm diameter

75.00 148.75 metre 11156.25

38 12.41.2 Providing and fixing on wall face unplasticised Rigid PVC rain water pipes conforming to IS : 13592 Type A, including jointing with seal ring conforming to IS : 5382, leaving 10 mm gap for thermal expansion (i) Single socketed pipes, 12.41.2 110 mm diameter

190.00 236.35 metre 44906.50

39 12.42 Providing and fixing on wall face unplasticised - PVC moulded fittings/ accessories for unplasticised Rigid PVC rain water pipes conforming to IS : 13592 Type A, including jointing with seal ring conforming to IS : 5382, leaving 10 mm gap for thermal expansion.

a 12.42.1.1 Couple 75mm 20.00 64.95 each 1299.00 b 12.42.1.2 110mm 20.00 102.65 each 2053.00 c 12.42.3.1 single tee with door 75x75x75 mm 16.00 121.50 each 1944.00 d 12.42.3.2 Single tee with door 110x110x110

mm 20.00 181.55 each 3631.00

e 12.42.5.1 75mm bend 16.00 76.55 each 1224.80 f 12.42.5.2 110mm bend 16.00 113.10 each 1809.60 g 12.42.6.2 110mm shoe 16.00 98.00 each 1568.00 40 13.2.2 15 mm cement plaster on the rough

side of single or half brick wall of mix : 1:6 (1 cement: 6 fine sand)

276.00 185.20 sqm 51115.11

41 13.4.2 12 mm cement plaster of mix : 1:6 (1 cement: 6 coarse sand)

50.00 168.25 sqm 8412.50

42 13.6.1 20 mm cement plaster of mix : 1:4 (1cement: 4 coarse sand)

91.00 252.40 sqm 22969.01

43 13.41.1 Distempering with oil bound washable distemper of approved brand and manufacture to give an even shade New work (two or more coats) over and including water thinnable priming coat with cement primer

46.00 93.70 sqm 4310.20

of 51

44 13.43.1 Applying one coat of water thinnable cement primer of approved brand and manufacture on wall surface : Water thinnable cement primer

1366.00 36.95 sqm 50473.70

45 13.47.1 13.47 Finishing walls with Premium Acrylic Smooth exterior paint with Silicone additives of required shade: New work (Two or more coats applied @ 1.43 ltr/10 sqm over and including priming coat of exterior primer applied @ 2.20 kg/10 sqm)

1366.00 96.80 sqm 132228.80

46 13.61.1 Painting with synthetic enamel paint of approved brand and manufacture to give an even shade Two or more coats on new work

79.00 78.40 sqm 6193.60

47 13.83.2 Wall painting with acrylic emulsion paint, having VOC (Volatile Organic Compound ) content less than 50 grams/ litre, of approved brand and manufacture, including applying additional coats wherever required, to achieve even shade and colour. Two coats

2365.00 71.00 sqm 167915.00

48 13.85.1 Applying priming coats with primer of approved brand and manufacture, having low VOC (Volatile Organic Compound) content. With ready mixed pink or grey primer on wood work (hard and soft wood) having VOC content less than 50 grams/ litre

79.00 38.45 sqm 3037.55

49 14.1.1 Repairs to plaster of thickness 12 mm to 20 mm in patches of area 2.5 sq. meters and under, including cutting the patch in proper shape, raking out joints and preparing and plastering the surface of the walls complete, including disposal of rubbish to the dumping ground, all complete as per directions of Engineer-In-Charge. 14.1.1 With cement mortar 1:4 (1 cement : 4 fine sand) block I to IV(12 units)

210.00 264.80 sqm 55608.00

50 14.43 Removing white or colour wash by scrapping and sand papering and preparing the surface smooth including necessary repairs to scratches etc. complete

3735.00 8.35 sqm 31187.25

of 51

51 14.54.1 Wall painting with plastic emulsion paint of approved brand and manufacture to give an even shade: One or more coats on old work

205.00 51.30 sqm 10516.50

52 14.67.2 Finishing walls with premium acrylic smooth exterior paint old work (one or more coats applied for old staff qtrs) for I to IV block

100.00 47.25 sqm 4725.00

53 14.82 Dismantling W.C. Pan of all sizes including disposal of dismantled materials i/c malba all complete as per directions of Engineer-in- Charge.

12.00 55.45 each 665.40

54 15.2.2 Demolishing cement concrete manually/ by mechanical means including disposal of material within 50 metres lead as per direction of Engineer - in - charge. ominal concrete 1:4:8 or leaner mix (i/c equivalent design mix

13.00 615.15 cum 7996.95

55 15.13.1 Taking out doors, windows and clerestory window shutters (steel or wood) including stacking within 50 metres lead : 15.13.1 Of area 3 sq. metres and below

10.00 61.25 each 612.50

56 15.60 Disposal of building rubbish / malba / similar unserviceable, dismantled or waste materials by mechanical means, including loading, transporting, unloading to approved municipal dumping ground or as approved by Engineer-in-charge, beyond 50 m initial lead, for all leads including all lifts involved.

90.00 120.55 cum 10849.50

57 17.2.2 Providing and fixing white vitreous china pedestal type water closet (European type W.C. pan) with seat and lid, 10 litre low level white P.V.C. flushing cistern, including flush pipe, with manually controlled device (handle lever), conforming to IS : 7231, with all fittings and fixtures complete, including cutting and making good the walls and floors wherever required. W.C. pan with ISI marked black solid plastic seat and lid

5.00 3395.45 each 16977.25

of 51

58 17.7.2 Providing and fixing wash basin with C.I. brackets, 15 mm C.P. brass pillar taps, 32 mm C.P. brass waste of standard pattern, including painting of fittings and brackets, cutting and making good the walls wherever require: White Vitreous China Wash basin size 630x450 mm with a single 15 mm C.P. brass pillar tap

12.00 2020.60 each 24247.20

59 17.10.1.1 Providing and fixing Stainless Steel A ISi 304 (18/8) kitchen sink as per IS: 13983 with C.I. brackets and stainless steel plug 40 mm, including painting of fittings and brackets, cutting and making good the walls wherever required : Kitchen sink with drain board 510x1040 mm bowl depth 200 mm

12.00 4120.80 each 49449.60

60 17.13.2 Providing and fixing white vitreous china water closet squatting pan (Indian type) :Orissa pattern W.C. pan of size 580x440 mm

8.00 1456.60 each 11652.80

61 17.18.2 Providing and fixing P.V.C. low level flushing cistern with manually controlled device (handle lever) conforming to IS : 7231, with all fittings and fixtures complete. 10 litre capacity - coloured controlled device (handle lever) conforming to IS : 7231, with all fittings and fixtures complete. 10 litre capacity - coloured

8.00 765.45 each 6123.60

62 17.31 Providing and fixing 600x450 mm beveled edge mirror of superior glass (of approved quality) complete with 6 mm thick hard board ground fixed to wooden cleats with C.P. brass screws and washers complete.

12.00 817.95 each 9815.40

63 17.69.2 Providing and fixing PTMT Waste Coupling for wash basin and sink, of approved quality and colour. Waste coupling 38 mm dia of 83 mm length and 77mm breadth, weighing not less than 60 gms

24.00 98.80 each 2371.20

of 51

64 18.8.1 Providing and fixing Chlorinated Polyvinyl Chloride (CPVC) pipes, having thermal stability for hot & cold water supply, including all CPVC plain & brass threaded fittings, i/c fixing the pipe with clamps at 1.00 m spacing. This includes jointing of pipes & fittings with one step CPVC solvent cement and the cost of cutting chases and making good the same including testing of joints complete as per direction of Engineer in Charge. Concealed work, including cutting chases and making good the walls etc. 15 mm nominal outer dia Pipes

60.00 246.20 metre 14772.00

65 18.8.2 Providing and fixing Chlorinated Polyvinyl Chloride (CPVC) pipes, having thermal stability for hot & cold water supply, including all CPVC plain & brass threaded fittings, i/c fixing the pipe with clamps at 1.00 m spacing. This includes jointing of pipes & fittings with one step CPVC solvent cement and the cost of cutting chases and making good the same including testing of joints complete as per direction of Engineer in Charge. Concealed work, including cutting chases and making good the walls etc. 20mm nominal outer dia pipes for 12 units

60.00 284.85 metre 17091.00

66 18.15.1 Providing and fixing brass bib cock of approved quality : 15 mm nominal bore

48.00 260.10 each 12484.80

67 18.16.2 Providing and fixing brass stop cock of approved quality : 20 mm nominal bore

12.00 280.40 each 3364.80

68 18.18.2 Providing and fixing ball valve (brass) of approved quality, High or low pressure, with plastic floats complete 20 mm nominal bore

2.00 327.05 each 654.10

69 18.21.2.2 Providing and fixing uplasticised PVC connection pipe with brass unions.45cm length 20 mm nominal bore

24.00 82.90 each 1989.60

of 51

70 18.48A Providing and placing on terrace (at all floor levels) polyethylene water storage tank, IS : 12701 marked, with cover and suitable locking arrangement and making necessary holes for inlet, outlet and overflow pipes but without fittings and the base support for tank.Circular tank.

4000.00 7.25 litre 29000.00

71 18.51.1 Providing and fixing C.P. brass long body bib cock of approved quality conforming to IS standards and weighing not less than 690 gms. 15 mm nominal bore

12.00 492.55 each 5910.60

72 18.54.2 Providing and fixing PTMT bib cock of approved quality and colour. 15 mm nominal bore, 122mm long, weighing not less than 99 gms

12.00 143.95 each 1727.40

73 18.65 Providing and fixing PTMT soap Dish Holder having length of 138mm, breadth 102mm, height of 75mm with concealed fitting arrangements, weighing not less than 106 gms.

12.00 112.30 each 1347.60

74 19.32.1 Making soak pit 2.5 m diameter 3.0 metre deep with 45 x 45 cm dry brick honey comb shaft with bricks and S.W. drain pipe 100 mm diameter, 1.8 m long complete as per standard design. 19.32.1 With common burnt clay F.P.S. (non modular) bricks of class designation 7.5

2.00 20681.55 each 41363.10

75 26.28.2 Chipping of unsound/weak concrete material from slabs, beams, columns etc. with manual Chisel and/ or by standard power driven percussion type or of approved make including tapering of all edges, making square shoulders of cavities including cleaning the exposed concrete surface and reinforcement with wire brushes etc. and disposal of debris for all lead and lifts all complete as per direction of Engineer-In-Charge. 50mm average thickness

315.00 111.55 sqm 35138.25

of 51

76 26.29.1 Cleaning of reinforcement from rust from the reinforcing bars to give it a total rust free steel surface by using alkaline chemical rust remover of approved make with paint brush and removing loose particles after 24 hours of its application with wire brush and thoroughly washing with water and allowing it to dry, all complete as per direction of Engineer-In-Charge. Bars upto 12 mm diameter

160.00 4.15 metre 664.00

77 26.30.1 Drilling suitable holes in reinforced or plain cement concrete with power driven drill machine to a minimum depth of 100mm upto 200mm in RCC beams, lintels, columns and slabs to introduce steel bars for sunshades/balconies including fixing the steel bars in position using epoxy resin anchor grout of approved make but excluding the cost of reinforcement, all complete as per direction of Engineer-In- Charge. Upto and including 12mm dia.

200.00 71.15 each 14230.00

78 26.31.1 Providing, mixing and applying bonding coat of approved adhesive on chipped portion of RCC as per specifications and direction of Engineer-In-charge complete in all respect. SBR Polymer (@10% of cement weight) modified cementitious bond coat @2.2 kg cement per sqm of surface area mixed with specified proportion of approved polymer

315.00 87.55 sqm 27578.25

of 51

79 26.32.1 Providing, mixing and applying SBR polymer (of approved make) modified Cement mortar in proportion of 1:4 (1 cement: 4 graded coarse sand with polymer minimum 2% by wt. of cement used) as per specifications and directions of Engineer-in-charge. Note: Measurement and payment: The pre measurement of thickness shall be done just after the surface preparation is completed and Payment under this item shall be made only after proper wet curing has been done and surface has been satisfactorily evaluated by sounding / tapping with a blunt metal instrument and/or the 75mm size cube crushing strength at the end of 28 days to be not less than 30 N/ mm2). 12 mm average thickness.

167.00 203.85 sqm 34042.95

Total for DSR Civil 3887362.27 80 PSR

11.52 Providing and fixing PVC corner beading of required size to suit the thickness of the wall tile at the corner joints of dado works

50.00 118.55 metre 5927.50

81 PSR 18.9.11

Providing and fixing ASTM pipes including all ASTM plain & brass threaded fittings i/c fixing the pipe with clamps at 1.00m spacing. This includes jointing of pipes & fitting with one step ASTM solvent cement and testing of joints complete (Internal work exposed on wall) - 20mm nominal outer dia pipes

240.00 141.42 metre 33940.80

82 PSR 18.9.12

Providing and fixing ASTM pipes including all ASTM plain & brass threaded fittings i/c fixing the pipe with clamps at 1.00m spacing. This includes jointing of pipes & fitting with one step ASTM solvent cement and testing of joints complete (Internal work exposed on wall) - 25mm nominal outer dia pipes

180.00 161.79 metre 29122.20

of 51

83 PSR 18.9.32

Providing and fixing ASTM pipes including all ASTM plain & brass threaded fittings this included jointing of pipes & fittings with one step ASTM solvent cement, trenching refilling & testing of joints Complete (External work) - 25mm nominal outer dia pipes

50.00 128.91 metre 6445.50

Total for PSS & MR 75436.00 Electrical Part 84 1.1 Wiring for light point/ fan point/

exhaust fan point/ call bell point with 1.5 sq.mm FRLS PVC insulated copper conductor single core cable in surface / recessed steel conduit, with piano type switch, phenolic laminated sheet, suitable size MS box and earthing the point with 1.5 sq.mm FRLS PVC insulated copper conductor single core cable etc. as required.

a 1.1.1 Group A 36.00 821.00 point 29556.00 b 1.1.2 Group B 36.00 937.00 point 33732.00 85 1.5 Wiring for light/ power plug with

2X4 sq. mm FRLS PVC insulated copper conductor single core cable in surface/ recessed steel conduit alongwith 1 No. 4 sq. mm FRLS PVC insulated copper conductor single core cable for loop earthing as required.

360.00 265.00 metre 95400.00

86 1.7 Wiring for circuit/ submain wiring alongwith earth wire with the following sizes of FRLS PVC insulated copper conductor, single core cable in surface/ recessed steel conduit as required.

a 1.7.1 2*1.5 sqmm + 1*1.5 sqmm 360.00 208.00 metre 74880.00 b 1.7.2 2*2.5sqmm + 1 * 2.5 sqmm

earthwire 360.00 229.00 metre 82440.00

c 1.7.3 2*4 sqmm + 1*4 sqmm earthwire 300.00 263.00 metre 78900.00 87 1.14 Wiring for circuit/ submain wiring

alongwith earth wire with the following sizes of FRLS PVC insulated copper conductor, single core cable in surface/ recessed medium class PVC conduit as required.

of 51

a 1.14.1 2*1.5 sqm +1*1.5 sqm earthwire 790.00 146.00 metre 115340.00 b 1.14.2 2*2.5 sqm + 1*2.5 sqm earthwire 620.00 167.00 metre 103540.00 c 1.14.3 2*4 sqm + 1*4 sqm earthwire 510.00 200.00 metre 102000.00 89 1.17 Supplying and drawing following

sizes of FRLS PVC insulated copper conductor, single core cable in the existing surface/ recessed steel/ PVC conduit as required.

a 1.17.1 1*1.5sqm 300.00 29.00 metre 8700.00 b 1.17.2 2*1.5 sqm 300.00 41.00 metre 12300.00 c 1.17.3 3*1.5 sqm 300.00 54.00 metre 16200.00 d 1.17.11 2*2.5 sqm 240.00 55.00 metre 13200.00 e 1.17.12 3*2.5 sqm 240.00 75.00 metre 18000.00 f 1.17.20 2*4sqm 360.00 86.00 metre 30960.00 89 1.18.1 Supplying and drawing following

pair 0.5 mm dia FRLS PVCinsulated annealed copper conductor, unarmored telephone cable in the existing surface/ recessed steel/ PVC conduit as required. 1 pair

120.00 19.00 metre 2280.00

90 1.19 Supplying and drawing co-axial TV cable RG-6 grade, 0.7 mm solid copper conductor PE insulated, shielded with fine tinned copper braid and protected with PVC sheath in the existing surface/ recessed steel/ PVC conduit as required.

60.00 33.00 metre 1980.00

91 1.21 Supplying and fixing of following sizes of medium class PVC conduit along with accessories in surface/recess including cutting the wall and making good the same in case of recessed conduit as required.

a 1.21.1 20mm 600.00 84.00 metre 50400.00 b 1.21.2 25mm 300.00 90.00 metre 27000.00 92 1.22 Supplying and fixing metal box of

following sizes (nominal size) on surface or in recess with suitable size of phenolic laminated sheet cover in front including painting etc. as required.

a 1.22.1 75*75*60mm deep 48.00 140.00 each 6720.00 b 1.22.2 100 mm X 100 mm X 60 mm deep 60.00 160.00 each 9600.00 c 1.22.4 150 mm X 150 mm X 60 mm deep 36.00 232.00 each 8352.00

of 51

d 1.22.14 200 mm X 300 mm X 100 mm deep 36.00 403.00 each 14508.00 93 1.23 Supplying and fixing following

piano type switch/ socket on the existing switch box/ cover including connections etc. as required.

a 1.23.1 5/6 A Switch 60.00 45.00 each 2700.00 b 1.23.2 2 way 5/6A switch 24.00 54.00 each 1296.00 c 1.23.3 15/16A switch 36.00 110.00 each 3960.00 d 1.23.4 3 pin 5/6A socket outlet 72.00 58.00 each 4176.00 e 1.23.5 6 pin 15/16A socket outlet 24.00 128.00 each 3072.00 f 1.23.6 Telephone socket outlet 12.00 75.00 each 900.00 g 1.23.7 T.V antana socket outlet 12.00 76.00 each 912.00 94 1.24 Supplying and fixing following

modular switch/ socket on the existing modular plate & switch box including connections but excluding modular plate etc. as required.

1.24.2 2 way 5/6 A switch 81.00 123.00 each 9963.00 1.24.5 6 pin 15/16 A socket outlet 81.00 175.00 each 14175.00 95 1.27 Supplying and fixing following

size/ modules, GI box alongwith modular base & cover plate for modular switches in recess etc. as required

1.27.2 3 Module (100mmX75mm) 81.00 267.00 each 21627.00 96 1.33 Supplying and fixing 3 pin, 5 A

ceiling rose on the existing junction box/ wooden block including connections etc. as required.

60.00 65.00 each 3900.00

97 1.34 Supplying and fixing brass batten/ angle holder including connections etc. as required

48.00 117.00 each 5616.00

98 2.3 Supplying and fixing following way, single pole and neutral, sheet steel, MCB distribution board, 240 V, on surface/ recess, complete with tinned copper bus bar, neutral bus bar, earth bar, din bar, interconnections, powder painted including earthing etc. as required. (But without MCB/RCCB/Isolator)

a 2.3.1 6 way, Double door 12.00 1661.00 each 19932.00 b 2.3.3 12 Way Double door 3.00 2053.00 each 6159.00 c 2.3.4 16 Way Double door 8.00 2453.00 each 19624.00

of 51

99 2.4 Supplying and fixing following way, horizontal type three pole and neutral, sheet steel TPN MCB distribution board, 415 V, on surface/recess, complete with tinned copper bus bar, neutral bus bar, din bar, interconnections, powder painted including earthing etc. as required (But without MCB/RCCB/Isolator)

a 2.4.1 4way (4+12), Double door 2.00 3068.00 each 6136.00 100 2.4.2 Supply and fixing following way,

horizontal type three pole and neutral, sheet steel TPN MCB distribution board, 415 V, on surface/recess , complete with tinned copper bus bar, neutral bus bar, earth bar, din bar, interconnections, powder painted including earthing etc. as required. (But without MCB/RCCB/Isolator). 6way (4+18), Double door

4.00 3693.00 each 14772.00

101 2.5.3 Supplying and fixing of following ways surface/ recess mounting, vertical type, 415 V, TPN MCB distribution board of sheet steel, dust protected, duly powder painted, inclusive of 200 A, tinned copper bus bar, common neutral link, earth bar, din bar for mounting MCBs (but without MCBs and incomer) as required. (Note : Vertical type MCB TPDB is normally used where 3 phase outlets are required.) 12 way (4 + 36), Double door

3.00 9828.00 each 29484.00

102 2.10 Supplying and fixing 5 A to 32 A rating, 240/415 V, 10 kA, “C” curve, miniature circuit breaker suitable for inductive load of following poles in the existing MCB DB complete with connections, testing and commissioning etc. as required.

a 2.10.2 single pole and neutral 235.00 544.00 each 127840.00 b 2.10.3 double pole 25.00 556.00 each 13900.00 c 2.10.4 triple pole 12.00 826.00 each 9912.00

of 51

103 2.16 Supplying and fixing DP sheet steel enclosure on surface/recess along with 25/32 A 240 V “C” curve DP MCB complete with connections, testing and commissioning etc. as required

6.00 848.00 each 5088.00

104 2.17 Supplying and fixing TP sheet steel enclosure on surface/recess along with 16/25/32A 415 V “C” curve TP MCB complete with connections, testing and commissioning etc. as required

8.00 1146.00 each 9168.00

105 5.2 Earthing with G.I. earth pipe 4.5 meter long, 40 mm dia including accessories, and providing masonry enclosure with cover plate having locking arrangement and watering pipe etc. with charcoal/ coke and salt as required.

14.00 5308.00 each 74312.00

106 5.6 Earthing with copper earth plate 600mmx600mmx3mm thick including accessories, and providing masonry enclosure with cover plate having locking arrangement and watering pipe of 2.7 meter long etc. with charcoal/coke and salt as required.

2.00 11794.00 set 23588.00

107 5.14 Providing and fixing 25mm x 5mm copper strip on surface or in recess for connections etc. as required.

50.00 1009.00 metre 50450.00

108 5.15 Providing and fixing 25mm x 5mm G.I strip on surface or in recess for connections etc. as required.

400.00 206.00 metre 82400.00

109 5.16 Providing and fixing 6 SWG dia G.I. Wire on surface or in recess for loop earthing as required

470.00 57.00 metre 26790.00

110 7.1 Laying of one number PVC insulated and PVC sheathed I XLPE power cable of 1.1 kV grade of following size direct in ground including excavation, sand cushioning, protective covering and refilling the trench etc. as required.

a 7.1.1 Upto 35sq.mm 670.00 323.00 metre 216410.00 b 7.1.2 Above 35 sq.mm and Upto 95

sq.mm 280.00 338.00 metre 94640.00

c 7.1.3 Above 95 sq.mm and upto 185 sq.mm 145.00 352.00 metre 51040.00

of 51

d 7.1.4 Above 185 sq.mm and upto 400 sq.mm

220.00 396.00 metre 87120.00

111 9.1 Supply and making end termination with brass compression gland and aluminium lugs for following size of PVC insulated and PVC sheathed/XLPE aluminium conductor cable of 1.1 kV grade as required.

a 9.1.21 3½ x 35 sq. mm (32mm) 4.00 300.00 each 1200.00 b 9.1.22 3½ x 50 sq. mm (35 mm) 2.00 329.00 each 658.00 c 9.1.25 3½ x 120 sq. mm (45mm) 2.00 489.00 each 978.00 d 9.1.27 3½ x 185 sq. mm (57mm) 8.00 702.00 each 5616.00 e 9.1.29 3½ x 240 sq. mm (62mm) 2.00 809.00 each 1618.00 f 9.1.32 4 x 10 sq. mm (25mm) 8.00 219.00 each 1752.00 g 9.1.33 4 x 16 sq. mm (28mm) 26.00 250.00 each 6500.00 112 1101 1.5 sq. mm ISI marked FRLs PVC

insulated single case copper conductor cable

100.00 9.00 metre 900.00

113 1102 2.5 sq. mm ISI marked FRLs PVC insulated single case copper conductor cable

100.00 14.00 metre 1400.00

114 1103 4 sq.mm ISI marked FRLs PVC insulated single case copper conductor cable

50.00 22.00 metre 1100.00

115 1224 20mm dia ISI marked PVC conduit 50.00 10.44 metre 522.00 116 1225 25mm dia ISI marked PVC conduit 1400.00 14.00 metre 19600.00 117 1226 32 mm dia ISI marked PVC conduit 325.00 12.79 metre 4156.75 118 1229 20mm PVC bends 75.00 4.71 each 353.25 119 1230 25mm PVC bends 175.00 6.40 each 1120.00 120 1231 32 mm PVC Bend 20.00 9.00 each 180.00 121 1239 20mm PVC junction box one way 85.00 10.00 each 850.00 122 1240 20mm PVC junction box two way 275.00 11.00 each 3025.00 123 1760 MCB’S,ISOLATORS,RCCB’S AND

MCB DB’S 4 way (4+12), TPN, vertical type, MCB DB, double door

2.00 3955.00 each 7910.00

124 1706 MCB’S,ISOLATORS,RCCB’S AND MCB DB’S 6A to 32A ratings , SP MCB, "C" curve, 10 kA breaking capacity

48.00 102.00 each 4896.00

125 1401 Ceiling nose 3 pin, 5A ISI for 4 block

30.00 12.00 each 360.00

126 1431 S.P 5/6A one way switch piano type ISI marked

20.00 10.00 each 200.00

127 1432 S.P 5/6A two way switch piano type ISI marked

20.00 16.80 each 336.00

of 51

128 1433 S.P 15/6A one way switch piano type ISI marked

12.00 46.80 each 561.60

129 1434 3Pin 5/6A socket outlet piano type ISI marked

36.00 19.20 each 691.20

130 1435 6Pin 15/6A and 5/6A socket outlet piano type ISI marked

24.00 60.00 each 1440.00

131 1441 Brass pandant holder 36.00 34.00 each 1224.00 132 2815 Supply and providing of

100mmx50mm x6mm channel iron(9.56kg/m)

120.00 33.00 kg 3960.00

133 2867 16 mmx50 mm bolts and nuts with washers

24.00 6.25 set 150.00

134 2936 Painting with primer and finish paint

1.00 4.20 L.S 4.20

Total for Electrical DSR 2050312.00 135 SD106 Supply and fixing of 1200mm(48'')

sweep A.C ceiling fan complete with stepped electric 300W regulator, with 1m dowm rod with fan clamp with side plates and arm of size 450mm(18")

24.00 2146.00 each 51504.00

136 SD88 Supply and fixing of single box type 4, 40W fitting complete with copper choke and condenser with TW round block or ceiling flu tube with PVC unshethered copper leads from terminal to the fittings.

24.00 565.00 each 13560.00

137 SD 230 Supply of PVC insulated and PVC sheathed/ XLPE power cable of 1.1Kv grade of following size direct in ground including excavation , sand cushioning , protective covering and refilling the trench , with necessary clamps , cable ties , fasteners , etc...3.5C *240 Sq.mm Al.Ar XLPE Cable.

220.00 1223.00 metre 269060.00

138 SD 229 3.5C*185 Sq.mm AI. Ar* XLPE Cable

65.00 994.00 metre 64610.00

139 SD Supply of LT Cable :Supply of the following sizes of XLPE 1.1 kv grade AI/CU conductor, armoured U.G cables on trenches, trays and walls including necessary clamps, cables ties, fasteners as required

a 203 4C*16 Sq.mm Al. Ar Cable 300.00 332.00 metre 99600.00 b 202 4C*10 sq.mm cu. Ar Cable 280.00 294.00 metre 82320.00 Total for SD & SSR 580654.00

of 51

140 PSR 31.259.1B

Supplying of 3.5/4x50 sqmm underground cable (Paragon/suncab/Empire) complete.-suitable for (30HP to 40HP pumpset)/(upto 40KVA Genset).

370.00 407.51 metre 150778.70

141 MR Supply and erection of 6way 630A SS feeder pillar box, As per PED standard. The pillar shall be of above rating, floor mounting type totally enclosed weather proof, incorporating phenolic moulded fuse dittings with high repturing capacity fuse links and suitable for use in the medium voltage of Hz., A.C neutral solidly earthed distribution system

1.00 85849.00 each 85849.00

142 MR Charges for removing of existing SS feeder pillar box

1.00 6558.00 each 6558.00

143 MR LT PANEL BOARDS The panel shall be compartmentalised, finished with powder coated paint of approved shade after duly treated for rust prevention and applying two coats of metal primer. The panel shall be fabricated as per relevant IS. The panel shall be provided with Danger/warning labels, feeder designation and all other provisions as may be required whether or not all items have been brought in this bill of quantities. The feeder arrangement shall be made to suit site condition and to avoid cross over of cables / bus duct. For Aluminium busbar current density taken as 0.8/Sq.mm

a MR LT CT Metering panel : Supply and erection of LT CT metering panel board made by using CRCA Sheet with siemens grey p[owder coating as per TNED norms.Space for fixing 1. No. CT operated Meter on sheet steel/ angle iron frame.1 Set of interconnection betweeen Meter and cutout shall be made with suitable size of copper

2.00 33257.00 each 66514.00

of 51

busbars. This shall also be made between Fuse Switch Units and Meter.

144 MR Supply and Erection of DG Auto Start Panel made up of 16 SWG C.R. Sheet Coated with siemens grey colour RAL 7032 powder coating with all its panel necessary locking accessories including control wiring with muli core armoured cables as per the drawing Specifications. (500H*350*300D*1.6mm thk.)- Panel consisting of 1) MCB , Lamp, Contactor, LVM-L&T. 2) Timer -Selec. 3) selector Switch - Salzer.

1.00 42408.00 each 42408.00

145 MR DG Power Distribution Panel Supply of DG Power distribution Panel consisting the following technical specification. Panel Shell made up of 14/16 SWG CRCA sheet with Siemens grey powder coating

1.00 48005.00 each 48005.00

INCOMER 1 NO-160A, 25kA TP MCCB with

TM based OC, SC, Metering Arrangements Incomer Feeder Consists of the

following 1 Set - RYB, on, off, trip, Indication

lamp with Control MCB's 1No-Multifunction meter with

ssuitable CT Outgoing feeders 2Nos-125A, 25Ka, TP, MCCB with

TM based OC,SC release Busbar:

160A TPN Aluminium bus bars, alumimium interconnections and earthing with 25*6 mm Al flar and with colour coded heat shrinkable sleeves andSMVBus bar supports

of 51

146 MR Main Sub panel-1 : Main Sub panel-1Supply of Main Sub Panel consisting the following technical specification. Panel Shell made up of 14/16 SWG CRCA sheet with Siemens grey powder coating.

1.00 247850.00 each 247850.00

Incomer 1No-250-A,4P ATS 1No-250A, 36KA 4P MCCB with

TM based OC, SC, Metering Arrangements Incomer Feeder Consists of the

following 1 Set - RYB, on, off, TRIP Indication

lamp with Control MCB's 1 Nos- Multifunction meter with

suitable CT Outgoing feeders 1Nos-125A, TP, MCCB with TM

Bsed OC,SC release 4Nos-100A, 25kA, TP, MCCB with

TM Based OC, SC release 2Nos-63A, 25kA,TP, MCCB with

TM Based OC, SC release 2Nos-32A, 25kA, TP, MCCB with

TM Based OC,SC release Busbar:

250A TPN Aluminium bus bars, aluminium interconnections and earthing with 25*6 mmAI flat and with colour coded heat shrinkable sleeves and SMC Bus bar supports

147 MR Main Sub Panel-2 : Supply of Main Sub Panel consisting the following technical specification. Panel Shell made up of 14/16 SWG CRCA sheet with Ssiemens grey powder coating.

1.00 221754.00 each 221754.00

Incomer 1Nos-250A, 36kA 4P MCCB with

TM Based OC,SC, Metering Arrangements Incomer Feeder Consists of the

following 1 Set - Mryb, on,off, trip Indication

lamp with Contorl MCB's 1No- Multifunction meter with suitable CT

of 51

Outgoing feeders 1Nos-100A, 25kA,TP,

MCCBwithTM based OC,SC release

2Nos-63A,25kA,TP, MCCB with TM Based OC,SC release

3Nos-32A, 25kA, TP, MCCB with TM Based OC,SC release

Busbar: 250A TPN Aluminium bus bars, aluminium interconnections and earthing with 25*6mm AI flat and with colour coded heat shrinkable sleeves and SMC Bus bar supports.

148 MR 40 KVAR Capacitor Panel : Incomer:

2.00 92052.00 each 184104.00

1No-125A 25KA TP MCCB with TM based OCSC release

1Set-RYB Indicators 1No-6 Stage APFC Relay Outgoings:- 3Set-10KVARCapacitor, capacitor

duty contactor with 63A,TP, MCB & On/Off Illuminated push button

1set-5KVAR Capacitor, capacitor duty contactor with 25A,TP,MCB &On/off Illuninated push button

1 Set -3KVAR Capacitor, capacitor duty contactor with 25, TP,MCB & On/Off Illuminated push button

1 Set-2KVAR Capacitor, capacitor duty contactor with 20A,TP, MCB & On/Off Illuminated push button

149 MR 200mm Dia GI Pipe (Hevy Duty) for road crossing

10.00 2521.00 metre 25210.00

150 MR 40 A to 63 A, ratings, TP MCB, “C” curve, 10 kA breaking capacity

20.00 1669.00 each 33380.00

151 MR 40 A to 63 A, ratings, FP MCB, “C” curve, 10 kA breaking capacity

25.00 1230.00 each 30750.00

152 MR 100 A , ratings, FP MCB, “C” curve, 10 kA breaking capacity

4.00 8924.00 each 35696.00

153 MR 125 A ratings, FP MCB, “C” curve, 10 kA breaking capacity

3.00 9903.00 each 29709.00

154 MR 125 A ratings, TP MCB, “C” curve, 10 kA breaking capacity

2.00 10029.00 each 20058.00

of 51

155 MR Supply of LED PLL 4 Pin 18 W Class 865 Essential (Crompton greves)

24.00 918.00 each 22032.00

Total for PSR & MR 1250655.70