punjab & sind bank zonal office mumbai€¦ · fort mumbai - 400023 tel: 022-22626055-58...
TRANSCRIPT
PUNJAB & SIND BANK
Zonal Office
MUMBAI
APPLICATIONFOREMPANELMENTOFINTERIOR FURNISHERS
Application reference no: - PSB/ZO/MUM/EF/01/2018
LAST DATE OF SUBMISSION: 26.09.2018 by 17.00 hrs
ZONAL OFFICE
27/29, AMBALAL DOSHI MARG
HAMAM STREET, FORT,
MUMBAI - 400023
Ph. No. 022-22626055-58
E-mail: [email protected]
PUNJAB & SIND BANK
(ZONALOFFICE, MUMBAI)
1 Application for Empanelment of Interior Furnishers for Punjab &Sind Bank
1. EMPANELMENTOFINTERIOR FURNISHERSD
Punjab & Sind Bank, Zonal Office is in the process of empanelling Interior Furnishers for
renovation of Branches / Offices / Residences; furnishing & interior decoration, etc and similar
projects in the Mumbai Zone.
2. INSTRUCTIONS TO APPLICANTS
a) The empanelment of a contractor/Furnisher in Bank shall not confer any right on him
either to be necessarily issued the tender papers or for award of work.
b) The details of the applicants and their experience shall be submitted in the Bank’s
prescribed “Application Format” only.
c) The applicant should ensure that the application is hand delivered at the given address
within the prescribed date and time as mentioned in the advertisement. The application
shall not be accepted by post/courier.
d) No costs incurred by the applicant in applying, in providing necessary clarifications
or attending discussions, conferences or site visits will be reimbursed by the Bank.
e) The applicant should furnish documentary proof with respect to the eligibility criteria
along with the completed application form. Incomplete applications or applications
without proper proofs for establishing their credentials will be liable for rejection and no
correspondence will be entertained in this regard.
f) If necessary, the categories/value/class/limits for which the Interior Furnishers are
empanelled should be specified.
g) The applicant should enclose demand draft (non-refundable) forRs.1,000/-in favour of
Punjab & Sind Bank and payable at Mumbai.
3. EVALUATION OF THE APPLICATIONS
a) Experience and reputation of the firm
b) Empanelment with other Banks, PSUs, Govt. Institutions etc.
c) Manpower & logistical support of the firm
d) Quality consciousness,
e) Registration with statutory tax authorities like IT, GST etc., as applicable.
4. If found necessary, Bank may also consider inspecting the works undertaken by
the applicants, for which necessary co-ordination shall be made by them. Based on the
details furnished in acceptable format, inspection of works and eligibility criteria, the
applicants will be empanelled.
5. Decision of the Bank regarding selection / rejection for empanelment will be
final and binding and no further correspondence will be entertained. The empanelled
contractors will only be informed by post.
6. If, information and details furnished by applicants are found to be false at any time in
future or any information withheld, which comes to the notice of the Bank at a later
date, the empanelment of such applicant will be cancelled immediately.
7. Applications received after the due date and time is liable to be rejected.
PUNJAB & SIND BANK
(ZONALOFFICE, MUMBAI)
2 Application for Empanelment of Interior Furnishers for Punjab &Sind Bank
8. The empanelment shall be valid for a period of three years from the date of intimation
letter to the short listed consultants / contractors/suppliers/vendors.
9. The present empanelment is mainly for works for value upto the limits
mentioned in respective categories. In case of any high value works, Bank may
undertake the works by project specific pre-qualification exercise.
10. All the applicants should clearly mention the Class details on the envelop cover.
11. Completed empanelment document shall be submitted up to the last date given in
advertisement, during office hours to the office of: -
The Zonal Manager
Punjab & Sind Bank
Zonal Office, 27/29, Ambalal Doshi Marg,
Fort Mumbai - 400023
Tel: 022-22626055-58
E-mail: [email protected]
12. SCOPE OF EMPANELMENT
The scope of work of Contractors for Interior Furnishing Works broadly is to undertake original
interior furnishing works, alterations and renovations involving erection of partitions, cabins,
work stations, false ceiling, flooring, counters, paneling, storage units, furniture, blinds etc.
For Class-A, Class-B contractors, the applicant/ firm/company shall be registered with ESI, EPF
etc., as per extant labour laws. Class-A and Class-B contractors who will be required to
undertake comprehensive works covering civil, interior and electrical works shall submit
necessary documentary evidence for carrying out electrical works, at the tender stage.
Note: -All class of contractors must be registered for Income Tax. The contractors, otherwise
eligible but not registered for Income Tax, will not be considered for empanelment.
Prospective contractors to note that all payments will be made electronically as per
Government guidelines
All contractors and consultants should have been registered with tax authorities. The
contractors, otherwise eligible but not registered for tax, will not be considered for
empanelment.
13. ELIGIBILITY CRITERIA
Empanelment of Contractors is sought for the following categories of works under various cost
limits. The contractors empanelled under lower cost limit will not be eligible for works costing
more than the limit. However the contractors empanelled under the higher class
ofwork/categorycanparticipateevenforworksinlowercostlimits.ThevariousCategories&Cost
limits are furnished below;
PUNJAB & SIND BANK
(ZONALOFFICE, MUMBAI)
3 Application for Empanelment of Interior Furnishers for Punjab &Sind Bank
S.No. Category
VALUE OF THE WORKS UPTO WHICH THE CONTRACTORCAN PARTICIPATE (AMOUNTINLAKHS)
Class -A Class -B
1 INTERIORFURNISHING From 1 Lakh to 50 lakh Upto 1 Lakh
The applicant should have the following minimum eligibility criteria:
a) The applicant should have undertaken works in Government Departments / Public Sector
Undertakings / Central Autonomous Bodies/State Autonomous Bodies / Financial
Institutions and other reputed Private Firms during last 5years.
One work/project costing 80%of the class limit OR
Two works/projects costing 50%ofthe class limit OR
Three works/projectscosting40% of the class limit
b) The applicant should have Income Tax registration number. The applicant should have
registered with statutory authorities for GST, Work Contract Tax etc, as applicable to
them in terms of extant laws. Applicant should submit copy of the income tax PAN, GST
certificate with valid registration number.
c) The applicant shall have the average annual financial turnover of at least 30% the value
of the class limit in the respective category during last 3 years prior to 31-03-2018.
d) Contractors for all classes should have well-established office with adequate engineering
staff and the applicant / firm / company shall be registered with ESI, EPF etc, as per
extant labour laws.
14. TECHNICAL EVALUATION CRITERIA
The Evaluation Committee (EC) shall carry out the entire evaluation process.
The Technical proposal evaluation process would focus on the ability of Interior Furnisher to
satisfy the technical requirements of the assignment, quality assurance procedures and
experience of Interior Furnishing works. Based upon the above pre-qualification criteria, the
technical proposals will be further evaluated on the following criteria and rating will be provided
as below.
S No. DESCRIPTION RATING
1 Experience in Interior Furnishing works
-do- Minimum 5 Years 3
-do- 5 Years and above 5
2 Experience in Interior Furnishing works for Bank branches (applicable for
both Government and Private Banks)
PUNJAB & SIND BANK
(ZONALOFFICE, MUMBAI)
4 Application for Empanelment of Interior Furnishers for Punjab &Sind Bank
-do- Up to 3 Banks 3
-do- More than 3 Banks 5
3
Average annual financial turnover during last 3 years prior to 31-03-
2014.
-do- at least 30% the value of the class limit in the respective category 3
-do- above 30% the value of the class limit in the respective category 5
4 Empanelment with other Public Sector Banks for Interior Furnishing works
-do- Up to 3 Banks 3
-do- More than 3 Banks 5
5
Marking based on Evaluation of the satisfactory certificates provided by
other Clients of the Interior Furnisher. For this the latest/last completed
project will be taken into consideration.
a) If Technical proficiency
i) Is Outstanding 5
ii) Is Very good 4
iii) Is Good 3
iv) Is Satisfactory 2
v) Is Poor 1
b) If Financial soundness
i) Is Outstanding 5
ii) Is Very good 4
iii) Is Good 3
iv) Is Satisfactory 2
v) Is Poor 1
c) If Mobilization of adequate T&P
i) Is Outstanding 5
ii) Is Very good 4
iii) Is Good 3
iv) Is Satisfactory 2
v) Is Poor 1
d) If Mobilization of manpower
i) Is Outstanding 5
ii) Is Very good 4
iii) Is Good 3
iv) Is Satisfactory 2
v) Is Poor 1
e) If General behaviour
i) Is Outstanding 5
ii) Is Very good 4
iii) Is Good 3
iv) Is Satisfactory 2
v) Is Poor 1
PUNJAB & SIND BANK
(ZONALOFFICE, MUMBAI)
5 Application for Empanelment of Interior Furnishers for Punjab &Sind Bank
f) If the deviation in stipulated date of completion and actual date of
completion is
i) Delayed 1
ii) Actual Time 3
iii) Before Time 5
TOTAL SCORE 50
15. EVALUATION CRITERIA
Only the Interior Furnisher who score more than 35 (Thirty Five) marks in Technical Evaluation
process will qualify to be Empanelled with the Bank. Once the evaluation of technical proposals
is completed, the Service Providers who score more than the prescribed cut-off score will only be
short listed. In case, none of the participants or only two of the participating Service
Providers qualify on technical criteria and reach or exceed the cut-off score of 35, then the
Bank, at its sole discretion, may qualify three Interior Furnishers on the basis of the top 3
scores.
The technically short listed Interior Furnishers will have to match the bank’s fixed rate and
payments will be made accordingly.
16. APPLICANT OBLIGATIONS
1) The applicant should intimate change of address to the Bank. Failure to do so may result in
removal of his name from the empanelled list.
2) The registration with various authorities like Electrical license, Council of Architecture,
Tax, etc shall be possessed during the empanelment period.
3) The applicant should not indulge in unethical practices.
4) The applicant should execute the works awarded to him strictly as per the terms and
conditions of the contract and specifications.
5) The applicant should co-ordinate with Bank Officials/Architects / Consultants/ Contractors,
if any, for smooth completion of the works.
6) Any Change in Constitution of firm without prior approval will render the applicant to be
removed from the panel. In case of conversion of a firm into two or more firms, fresh
empanelment is essential.
17. DISCIPLINARYACTIONS
The Interior Furnisher shall have to abide by all the rules of empanelment and also by the terms
and conditions of the agreement/MoU. He shall have to execute the works as per contract on time
and with good quality.PSB shall have the right to suspend business with him for any period,
debarred or remove the name from the approved list of Interior Furnishers indefinitely or for a
period as decided by PSB after issue of a show cause notice. Decision of PSB shall be final and
binding on the Interior Furnishers.
PUNJAB & SIND BANK
(ZONALOFFICE, MUMBAI)
6 Application for Empanelment of Interior Furnishers for Punjab &Sind Bank
The name of the contractor may be removed from the approved list of contractors /Interior
Furnishers by the Bank if he:
1. Fails to execute a contract or has executed it unsatisfactorily or
2. Persistently violates any important conditions of contract: or
3. Furnishes false particulars at the time of empanelment: or
4. Indulges in any type of forgery or falsification of records: or
5. Defaults in tax dues like Income Tax, Work Contract Tax, GST etc.
18. REVISION OF ABOVE RULES OF EMPANELMENT:
Bank may modify, add, delete and / or change any of the above rules and the same shall be
binding on all the empanelled Contractors / Consultants. Bank reserves its right to reject any /
or all the applications without assigning any reasons whatsoever.
GUIDELINESFORSUBMISSIONOFAPPLICATIONFORMFOREMPANELMENTO
FARCHITECT/ ARCHITECTURAL FIRM
1. Application form for empanelment shall be submitted in sealed envelope superscribing
‘Application for Empanelment as Interior Furnishers – Class A/B”.
2. Theapplicationshallbesubmittedstrictlyintheformatasmentionedalongwiththe supporting
documents.
3. Theapplicationshallbesignedbytheperson/sonbehalfoftheorganizationhaving necessary
Authority/Power of Attorney to do so. Each page of the application shall be signed and
copy of Power of Attorney / Memorandum of association (Wherever applicable) shall be
furnished along with application.
4. If the space in Performa is insufficient for furnishing full details, such information may
be supplemented on separate sheet stating therein the part of Performa and serial
number. Separate sheets may be used for each part of application. While filling up the
application with regard to list of important projects completed or on hand the applicant
shall only include major works handled by the firm.
5. The applicant should ensure that the application is hand delivered at the given address
within prescribed date and time as mentioned in the advertisement. The application shall
not be accepted by post/courier.
6. Application containing false and/or incomplete information is liable for rejection.
7. The applicant should enclosed draft (non - refundable) for Rs.1,000/-payable to Punjab
& Sind Bank, Mumbai.
8. The bank reserves right to accept or reject any or all the application.
PUNJAB & SIND BANK
(ZONALOFFICE, MUMBAI)
7 Application for Empanelment of Interior Furnishers for Punjab &Sind Bank
9. Last date and time to accept the application is the last date given in advertisement,
during office hours.
PUNJAB & SIND BANK
(ZONALOFFICE, MUMBAI)
8 Application for Empanelment of Interior Furnishers for Punjab &Sind Bank
To, Deputy General Manager,
Punjab & Sind Bank,
ZO Mumbai
27/29, Ambalal Doshi Marg
Fort, Mumbai - 400023
Ref: Application for empanelment as Interior Furnisher.
Dear Sir, I / we have read and understood the instructions and the Terms & Conditions mentioned in
the application form. I / we do hereby declare that the information furnished in the
application and the supplementary sheets are correct to the best of my knowledge and
belief.
I / we authorize Bank to approach our employers, clients, corporation organization etc. to
verify the facts submitted by us.
Signature of applicant with seal
Name:
Designation:
Address:
Place
Date:
PUNJAB & SIND BANK
(ZONALOFFICE, MUMBAI)
9 Application for Empanelment of Interior Furnishers for Punjab &Sind Bank
INFORMATIONTOBEFURNISHEDBYTHEAPPLICANTS
1 Name of the organization
2 Registered Address
Postal address
Telephone nos
E-mail address
3 Address for
Communication
Postal address
Telephone nos
E-mail address
4 Year of establishment
5 Status of the firm (Enclose copy)
o Company
o Partnership
o Proprietor Firm
o Individual
(attach proof)
6 Name of Directors/ Partners? Proprietor
i)
ii)
iii)
7
Registration Details Companies/Firm Registration Number & date Sales Tax Registration No: Income Tax Number: Pan Number TIN: Value Added Tax No: Service Tax No: Electrical Contractor License No: Others If any:
8 Name and address of Bankers. Enclose Solvency Certificate
PUNJAB & SIND BANK
(ZONALOFFICE, MUMBAI)
10 Application for Empanelment of Interior Furnishers for Punjab &Sind Bank
9
Important major projects on which
the firm was engaged in the last 5
years and their estimated cost, stage
of work viz. planning and
construction, the full address of
clients shall be indicated against
each project. (Details to be furnished
in Performa 1)
o YES o NO
10 Specify the maximum value of work
done in a year
Year Value of Work
2015-16
2016-17
2017-18
11
Important major projects on which
the firm is engaged at present and
their estimated cost, stage of work
viz. planning and construction, the
full address of clients shall be
indicated against each project.
(Details to be furnished in Performa
2)
o YES o NO
12
Whether an assessor of income tax, if
so, mention permanent account
number furnish copies of Income Tax
Clearance Certificate.
o YES o NO
13
Furnish copies of audited Balance
Sheet and Profit & loss account
(audited) for the last three years.( FY
2015-16, 2016-17,2017-18)
o YES o NO
14
If you are registered in panel of
other organization / Statutory bodies
such CPWD, PWD, MES, Banks,
etc, furnish their name, Category
and date of registration.( furnish
proof)
i)
ii)
iii)
iv)
PUNJAB & SIND BANK
(ZONALOFFICE, MUMBAI)
11 Application for Empanelment of Interior Furnishers for Punjab &Sind Bank
15
Details of three responsible
clients/persons to whom the major
works carried out by the applicant
with address and telephone number
who will be in a position to certify
about the quality as well as past
performance of your organization
1.
2.
3.
16
Details of Application Fee DD No. :
Date: Issuing Bank/ Branch:
17
Furnish copies of Satisfactory Certificate
only from PSU Clients (Minimum 3
Nos) as per Performa 4. (The completion
of the projects considered for this
satisfactory completion should not be
later than 1 year from the date of the
application).
o YES o NO
PUNJAB & SIND BANK
(ZONALOFFICE, MUMBAI)
12 Application for Empanelment of Interior Furnishers for Punjab &Sind Bank
PERFORMA–1
PARTICULARSINRESPECTOFWORKEXECUTED
Name of the Bidder:
List of Important Works Executed by the Agency during the Last Five Years (Separate sheet can also be enclosed if required)
Sr.
No
Name of the work/
Project
executed
with
address
Short
Description
of work
executed
Name and
Address
of owner
Value of
work
executed
Stipulated
Time of
completion
Date of
commencement
Date of
completion
If the work was delayed beyond stipulated date of completion, give reasons for the delay
Whether work was left incomplete or contract was terminated from either side, Give Details
Any other
relevant
information
1
2
3
4
Note:-Copies of the Agreement/MoU/Completion Certificate to be enclosed Place: Date:
Signature of the Applicant
PUNJAB & SIND BANK
(ZONALOFFICE, MUMBAI)
13 Application for Empanelment of Interior Furnishers for Punjab &Sind Bank
PERFORMA-2
PARTICULARSINRESPECTOFWORKINHAND
List of Important Works in Hand/ in Progress
Sr.
No Name of the
work/project
executed with
address
Short
description
of work
executed
Name and
address of
owner
Value of
work
executed
Stipulated
time of
completion
Status Of
Work
If the work was
delayed beyond
stipulated date
of completion,
give reasons
for the delay
Any other
relevant
information
1
2
3
4
Note:-Copies of the Agreement/MoU to be enclosed Place: Date:
Signature of the Applicant
PUNJAB & SIND BANK
(ZONALOFFICE, MUMBAI)
14 Application for Empanelment of Interior Furnishers for Punjab &Sind Bank
PERFORMA–3 LISTOFKEYPERSONALPERMANANTLYEMPLOYED
SR.
No.
Name
Designation
Qualification
Experience
Years with the
Firm
Any other
information
Place: Date:
Signature of the Applicant
15 Application for Empanelment of Interior Furnishers for Punjab &Sind Bank
PERFORMA – 4
CLIENT’S CERTIFICATE REGARDING PERFORMANCE OF CONTRACTOR
Name & Address of the Client: …………………………
Name of the Interior Furnisher
1. Name of work with brief particulars
2. Agreement No. and date
3. Agreement amount
4 Date of commencement of work
5 Stipulated date of completion
6 Actual date of completion
7. Details of penalty levied for delay(indicate amount),if any
8. Gross amount of the work completed and paid
9. Name and address of the authority under whom works executed
10 Whether the contract employed qualified Engineer/Oversee during execution of work?
11 i)Quality of work Outstanding/Very good/Good/
Satisfactory/Poor
ii) Amount of work paid on reduced rates, if any
12 i)Did the contractor go for arbitration?
ii)If yes, total amount of claim
iii) Total amount awarded
13 Comments on the capabilities of the contractor
a) Technical proficiency Outstanding/Very good/Good/
Satisfactory/Poor
b) Financial soundness Outstanding/Very good/Good/
Satisfactory/Poor
c) Mobilization of adequate T&P Outstanding/Very good/Good/
Satisfactory/Poor
d) Mobilization of manpower Outstanding/Very good/Good/ Satisfactory/Poor
e) General behavior Outstanding/Very good/Good/
Satisfactory/Poor
Note: All columns should be filled in properly
Place : SIGNATURE OF THE CLIENT
Date : NAME & DESIGNATION
SEAL OF ORGANISATION
16 Application for Empanelment of Interior Furnishers for Punjab &Sind Bank
DECLARATION
1. All the information furnished by me/us here above is correct to the best of my knowledge
and belief.
2. I/we have no objection if enquiries are made about the work listed by me/us in the
accompanying sheets/ Annexures.
3. I / We agree that the decision of Bank in selection of contractors will be final and binding
tome/ us.
4. I / We have read the instructions and I / we understand that if any false information is
detected at a later date the empanelment shall be cancelled at the discretion of the Bank.
Place : SIGNATURE OF THE APPLICANT Date : NAME&DESIGNATION
SEAL OF ORGANISATION
Note: Where copies are to be furnished, they have to be certified copies preferably by the concerned
agencies or a Government Officer.
17 Application for Empanelment of Interior Furnishers for Punjab &Sind Bank
:
Checklist
(To be filled by Applicants)
1. Have you mentioned the class for which you have applied in the application form?
Yes/No
2. Have you signed in all the sheets? Yes/No
3. Whether copy of PAN/GST/Tax Registration copy is Yes/No
Enclosed ?
4. Whether requisite application fee by cash/DD is paid? Yes/No
5. Whether enclosed valid Electrical License in case of Electrical Yes/No
Contractor?
6. Whether enclosed proof for year of establishment? Yes/No
7. Whether proof for average annual financial turnover enclosed? Yes/No
8. Whether Performa –1, Performa –2 and Performa -3 filled up? Yes/No
9. Whether documentary proofs for having satisfactorily undertaken the works(as detailedinPerforma1 and 2)are enclosed?
Yes/No
If yes, number of certificates enclosed: For Performa 1
For Performa 2
Name of the Applicant/Firm /Company :
Class Applied For:
For Office Use Only:
1. Whether the applicant satisfies relevant work experience for the Yes/No specific
category?
2. Whether the applicant possesses PAN/GST - Yes/No
Council of Architecture / Electrical License Certificate, as applicable?
3. Whether the applicant satisfies the minimum financial turnover? Yes/No
4. Whether the applicant has enclosed all necessary certificates? Yes/No
5. Whether the application is accepted / rejected? ACCEPTED/ REJECTED