request for proposal for selection of system …
TRANSCRIPT
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 1 of 107
REQUEST FOR PROPOSAL
FOR
SELECTION OF SYSTEM INTEGRATOR
for
O&M of APeProcurement Platform (Application) of
ITE&C Department, GoAP
April’2020
Andhra Pradesh Technology Services Limited (APTS) 3rd Floor, R&B Building, Opp. Indira Gandhi Municipal Stadium,
MG Road, Labbipet, Vijayawada – 520 010, Andhra Pradesh
Volume II
Contractual and Legal Specifications
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 2 of 107
Proprietary & Confidential
No part of this document can be reproduced in any form or by any means, disclosed or
distributed to any person without the prior consent of APTS except to the extent
required for submitting bid and no more.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 3 of 107
RFP STRUCTURE
This RFP is meant to invite proposals from interested companies capable of delivering
the services described herein. The content of this RFP has been documented as a set of
two volumes explained below:
Volume I: Functional, Technical and Operational Requirements
Volume I of the RFP intends to bring out all the details with respect to solution and
other requirements that Information Technology Electronics and Communication
(ITE&C) department deems necessary to share with the potential bidders. The
information set out in this volume has been broadly categorized as Functional,
Technical, and Operational covering multiple aspects of the requirements. The Volume I
also consists details of the General Terms & Conditions with respect to the bid process
management including the project implementation, financial terms, evaluation criteria
and bid submission forms to be adopted for the proposed project.
Volume II: Contractual and Legal Specifications
Volume II of the RFP details out the Draft Contract for the proposed engagement and
outlines the contractual, legal terms & conditions applicable for the proposed
engagement.
This volume is Volume II
Kindly note that all two volumes of the RFP have to be read in conjunction as there are
cross references on sections in these volumes. The selected System Integrator will be
solely responsible for any gaps in scope coverage caused by not referring to all two
volumes.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 4 of 107
Acronym Full Form
ACL Access Control list
AIS Automatic Identification System
AMC Annual Maintenance Contract
API Application Programming Interface
APSEA Andhra Pradesh State Enterprise Architecture
APSWAN Andhra Pradesh State Wide Area Network
APTS Andhra Pradesh Technology Services
B2G Business to Government
BCP Business Continuity Plan
BE Budget Estimate
BOM Bill of Material
CCN Change Control Notice
CERT-In Indian Computer Emergency Response Team
CGA Controller General of Accounts
CMMI Capability Maturity Model Integration
CMS Content Management System
CO Controlling Officer
CoE Center of Excellence
COTS Commercial Off The Shelf
CPA Central Plan Assistance
CSC Common Service Centers
CSIP Continuous Service Improvement Plans
CV Curriculum Vitae
DC Data Centre
DCIM Data center infrastructure management
DeitY Department of Electronics and Information Technology
DFD Data Flow Diagram
DHCP Dynamic Host Configuration Protocol
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 5 of 107
Acronym Full Form
DIT Department of Information Technology
DMS Date-wise Monthly Statement
DNS Domain Name System
DR Disaster Recovery
DRC Disaster Recovery Centre
DRP Disaster Recovery Plan
DSC Digital Signature Certificate
DSCI Data Security Council of India
DTA Directorate of Treasuries and Accounts
DTO District Treasury Office/ Officer
EADG Enterprise Architecture Design Group
EASG Enterprise Architecture Support Group
EAP Externally Aided Projects
ECS Electronic Clearance System
EITM Empirical Implications of Theoretical Models
EMD Earnest Money Deposit
EMS Enterprise Management Solution
EPRS e-Pragati Requirements Specifications
ERP Enterprise Resource Planning
FIFO First In First Out
FRS Functional Requirement Specifications
FSMO Flexible Single Master Operation
G2B Government to Business
G2C Government to Citizen
G2G Government to Government
GCC General Conditions of Contract
GIS Geographic Information System
GoAP Government of Andhra Pradesh
GoI Government of India
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 6 of 107
Acronym Full Form
GPF General Provident Fund
HLD High Level Design
HOD Head of Department
HOO Head of the Office
HRMS Human Resource Management System
HTML Hypertext Markup Language
HTTP Hypertext Transfer Protocol
HTTPS Hypertext Transfer Protocol Secure
IAFIS Integrated Automated Fingerprint Identification System
ICT Information and Communications Technology
IEEE Institute of Electrical and Electronics Engineers
INR Indian Rupee
IP Internet Protocol
ISO International Organization for Standardization
IT Information Technology
ITB Instructions to Bidders
ITE&C Information Technology, Electronics and Communication
ITIL Information Technology Infrastructure Library
IVRS Interactive voice response System
IVVT Integration, Verification, Validation & Testing
JDBC Java Database Connectivity
KPI Key Performance Indicators
KT Knowledge Transfer
LAN Local Area Network
LLD Low Level Design
LOC Letter of Credit
MCA Ministry of Corporate Affairs
MIS Management Information System
MSA Master Service Agreement
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 7 of 107
Acronym Full Form
MSME Ministry of Micro Small and Medium Enterprise
NDA Non-Disclosure Agreement
NDR Near Disaster Recovery
NeGD National e-Governance Division
NIC National Informatics Center
NPMU National Project Management Unit
NSDG National Service Delivery Gateway
O&M Operation and Maintenance
ODBC Open Database Connectivity
ODS Operational Data Store
OEM Original Equipment Manufacturer
OLTP Online Transaction Processing
ORT Operational Readiness Test
OWASP Open Web Application Security Project
PBG Performance Bank Guarantee
PIU Project Implementation Unit
PKCS Public Key Cryptography Standards
PKI Public Key Infrastructure
PMIS Project Management Information System
PMU Program Management Unit
PoR Prevention of Reoccurrence
PPP Public Private Partnership
PQ Pre-Qualification
QA Quality Assurance
RAID Redundant array of inexpensive disks
RE Revised Estimate
REST Representational State Transfer
RFP Request for Proposal
RPO Recovery Point Objective
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 8 of 107
Acronym Full Form
RTM Requirements Traceability Matrix
RTO Recovery Time Objective
SAN Storage Area Network
SCC Special Conditions of Contract
SDA State Designated Agency
SDC State Data Center
SDDO Self-Drawing and Disbursing Officer
SDLC Systems Development Life Cycle
SeMT State E-Governance Mission Team
SI System Integrator
SIP Service Improvement Plans
SLA Service Level Agreement
SMAC Social Mobile Analytics Cloud
SMS Short Messaging Service
SNMP Simple Network Management Protocol
SOA Service Oriented Architecture
SOAP Simple Object Access Protocol
SOP Standard Operating Procedure
SPOC Single Point of Contact
SQL Structured Query Language
SRS System/Software Requirement Specifications
STO Sub-Treasury Officer/ Officer
SWAN State Wide Area Network
TB Tera Byte
UAT User Acceptance Testing
UC Utilization Certificate
UDDI Universal Description, Discovery, and Integration
VLAN Very Large Area Network
VLC Voucher Level Computerization
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 9 of 107
Acronym Full Form
VPN Virtual Private Network
W&P Works & Projects
W3C World Wide Web Consortium
WAN Wide Area Network
WS Web Services
WSDL Web Services Description Language
XML Extensible Mark-up Language
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 10 of 107
CONTENTS
CONTENTS ........................................................................................................................... 10
DRAFT MASTER SERVICES AGREEMENT ................................................................................ 15
1 ARTICLE I - DEFINITIONS & STRUCTURE ...................................................................... 17
1.1 DEFINITIONS .................................................................................................................. 17
1.2 STRUCTURE .................................................................................................................... 23
1.3 CONDITIONS PRECEDENT .............................................................................................. 23
1.3.1 CONDITIONS PRECEDENT FOR SYSTEM INTEGRATOR ........................................... 23
1.3.2 NON-FULFILMENT OF CONDITIONS PRECEDENT .................................................. 24
1.4 SCOPE OF CONTRACT .................................................................................................... 24
1.4.1 INTERPRETATION OF THE SCOPE OF WORK .......................................................... 25
1.5 PERIOD/ TERM OF CONTRACT ....................................................................................... 25
1.6 EXTENSION OF THIS AGREEMENT ................................................................................. 25
1.7 ADDITIONAL WORK ....................................................................................................... 26
1.8 COMMENCEMENT AND DURATION OF THE SLA ........................................................... 26
2 ARTICLE II – INITIALIZATION ...................................................................................... 27
2.1 PROVISION OF THE SERVICES ........................................................................................ 27
2.2 APPROVALS AND REQUIRED CONSENTS ....................................................................... 27
2.3 USE AND ACQUISITION OF ASSETS ................................................................................ 28
2.4 ACCESS TO SYSTEM INTEGRATOR ................................................................................. 29
3 ARTICLE III - MANAGEMENT ...................................................................................... 31
3.1 GOVERNANCE ................................................................................................................ 31
3.2 USE OF SERVICES ........................................................................................................... 31
3.3 CHANGES/ AMENDMENTS ............................................................................................ 31
3.4 SECURITY AND SAFETY................................................................................................... 31
3.5 CO-OPERATION .............................................................................................................. 32
4 ARTICLE IV - FINANCIAL TERMS .................................................................................. 33
4.1 TERMS OF PAYMENT, PENALTIES AND INCENTIVES ...................................................... 33
4.1.1 MILESTONE PAYMENT ........................................................................................... 33
4.1.2 QUARTERLY PAYMENT FOR DELIVERABLES ........................................................... 33
4.1.3 PENALTIES .............................................................................................................. 33
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 11 of 107
4.2 INVOICING AND SETTLEMENT ....................................................................................... 33
4.3 TAX CONSIDERATION..................................................................................................... 34
4.4 LIQUIDATED DAMAGES ................................................................................................. 34
5 ARTICLE V - BREACH, RECTIFICATION & TERMINATION ............................................... 35
5.1 MATERIAL BREACH ........................................................................................................ 35
5.2 COMPANY NAME CHANGE ............................................................................................ 35
5.3 TERMINATION FOR BANKRUPTCY ................................................................................. 35
5.4 EFFECTS OF TERMINATION ............................................................................................ 36
5.5 FRAUD BY SYSTEM INTEGRATOR, CONSORTIUM PARTNER’S AND SUB-CONTRACTOR’S
PERSONNEL ............................................................................................................................... 36
5.6 Consequences of failure by the Successful Bidder to provide Services: ....................... 38
6 ARTICLE VI - PROTECTION AND LIMITATIONS ............................................................. 39
6.1 WARRANTIES ................................................................................................................. 39
6.2 THIRD PARTY CLAIMS .................................................................................................... 40
6.3 LIMITATION OF LIABILITY .............................................................................................. 42
6.4 FORCE MAJEURE ............................................................................................................ 42
6.5 DATA PROTECTION ........................................................................................................ 44
6.6 AUDIT, ACCESS AND REPORTING .................................................................................. 44
7 ARTICLE VII - INTELLECTUAL PROPERTY ...................................................................... 45
7.1 INTELLECTUAL PROPERTY .............................................................................................. 45
8 ARTICLE VIII – MISCELLANEOUS ................................................................................. 48
8.1 CONFIDENTIALITY .......................................................................................................... 48
8.2 PERSONNEL .................................................................................................................... 51
8.3 SUB-CONTRACTORS ....................................................................................................... 52
8.4 RESPONSIBILITY OF CONSORTIUM (Not applicable) ..................................................... 53
8.5 ASSIGNMENT ................................................................................................................. 53
8.6 TRADEMARKS, PUBLICITY .............................................................................................. 53
8.7 NOTICES ......................................................................................................................... 53
8.8 VARIATIONS AND FURTHER ASSURANCE ...................................................................... 54
8.9 SEVERABILITY AND WAIVER .......................................................................................... 54
8.10 COMPLIANCE WITH LAWS AND REGULATIONS ............................................................. 55
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 12 of 107
8.11 ETHICS ............................................................................................................................ 55
8.12 ENTIRE AGREEMENT ...................................................................................................... 55
8.13 SURVIVABILITY ............................................................................................................... 55
9 ARTICLE IX - DISPUTES AND AMENDMENTS ............................................................... 56
9.1 DISPUTE RESOLUTION ................................................................................................... 56
9.2 AMENDMENT ................................................................................................................ 57
10 SCHEDULE I – CHANGE CONTROL SCHEDULE (Not applicable) ..................................... 59
10.1 PURPOSE ........................................................................................................................ 59
10.2 CHANGE CONTROL NOTE ("CCN") ................................................................................. 59
10.3 QUOTATION ................................................................................................................... 62
10.4 COSTS ............................................................................................................................. 62
10.5 REPORTING .................................................................................................................... 62
10.6 OBLIGATIONS ................................................................................................................. 62
10.7 COST OF CHANGE REQUEST .......................................................................................... 63
11 SCHEDULE II – EXIT MANAGEMENT SCHEDULE ........................................................... 64
11.1 PURPOSE ........................................................................................................................ 64
11.2 TRANSFER OF ASSETS .................................................................................................... 64
11.3 COOPERATION AND PROVISION OF INFORMATION ..................................................... 67
11.4 CONFIDENTIAL INFORMATION, SECURITY AND DATA .................................................. 68
11.5 EMPLOYEES .................................................................................................................... 68
11.6 TRANSFER OF CERTAIN AGREEMENTS .......................................................................... 69
11.7 RIGHTS OF ACCESS TO PREMISES .................................................................................. 69
11.8 GENERAL OBLIGATIONS OF THE SYSTEM INTEGRATOR ................................................ 69
11.9 EXIT MANAGEMENT PLAN ............................................................................................. 70
12 SCHEDULE III - AUDIT, ACCESS AND REPORTING SCHEDULE ....................................... 72
12.1 PURPOSE ........................................................................................................................ 72
12.2 AUDIT NOTICE AND TIMING .......................................................................................... 72
12.3 ACCESS ........................................................................................................................... 72
12.4 AUDIT RIGHTS ................................................................................................................ 73
12.5 AUDIT RIGHTS OF SUPPLIERS AND AGENTS .................................................................. 73
12.6 ACTION AND REVIEW .................................................................................................... 74
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 13 of 107
12.7 TERMS OF PAYMENT FOR COST OF AUDIT .................................................................... 74
12.8 RECORDS AND INFORMATION ...................................................................................... 74
13 SCHEDULE IV – INDICATIVE GOVERNANCE SCHEDULE ................................................. 75
13.1 PURPOSE ........................................................................................................................ 75
13.2 INDICATIVE GOVERNANCE STRUCTURE ........................................................................ 75
13.3 GOVERNANCE PROCEDURES ......................................................................................... 75
14 SCHEDULE V – INVOICING AND SETTLEMENT SCHEDULE ............................................. 77
15 SCHEDULE VI – TERMS OF PAYMENT SCHEDULE ......................................................... 79
16 SCHEDULE VII – O&M SCHEDULE ............................................................................... 80
17 SCHEDULE VIII - ROLES AND RESPONSIBILITIES ........................................................... 81
17.1 ROLES AND RESPONSIBILITIES OF ITE&C DEPARTMENT .............................................. 81
17.2 ROLES AND RESPONSIBILITIES OF APTS ......................................................................... 83
17.3 ROLES AND RESPONSIBILITIES OF SYSTEM INTEGRATOR .............................................. 83
17.4 ROLES AND RESPONSIBILITIES OF OTHER DEPARTMENTS ............................................ 84
17.5 ROLES AND RESPONSIBILITIES OF STATE DATA CENTER ............................................... 85
SCHEDULE IX - SERVICE LEVEL AGREEMENTS (SLA) ................................................................ 86
17.6 SLA DEFINITION & MEASUREMENT ............................................................................... 86
17.7 SLA METRICS .................................................................................................................. 86
17.8 SLA MONITORING .......................................................................................................... 86
18 SCHEDULE X - MANDATORY COMPLIANCES ............................................................... 88
18.1 Form U1: Non-Disclosure Agreement (NDA) .............................................................. 88
18.2 Form U2: Undertaking on IPR and Patent Rights ......................................................... 92
18.3 Form U3: Non- Malicious Code Certificate .................................................................. 93
18.4 Form U4: Undertaking on Provision for Software Support .......................................... 94
18.6 Form U5: Undertaking on Service Level Compliance .................................................. 95
18.7 Form U6: Undertaking on Deliverables ........................................................................ 96
18.8 Form U7: Undertaking on Training the Users ............................................................... 97
18.9 Form U9: Undertaking on Support to Certification ....................................................... 98
18.10 Form U9: Undertaking on Exit Management and Transition ........................................ 99
18.11 Form U10: Undertaking on Continuous Improvement ................................................ 100
18.12 Form U11: Undertaking on Personnel ......................................................................... 101
19 ANNEXURE II: SERVICE LEVEL AGREEMENTS ............................................................. 102
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 14 of 107
19.1 SERVICE LEVEL AGREEMENTS ...................................................................................... 102
19.2 O&M PHASE SLAs ........................................................................................................ 105
20 PERFORMANCE BANK GUARANTEE FORMAT ........................................................... 106
End of the Document ......................................................................................................... 107
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 15 of 107
DRAFT MASTER SERVICES AGREEMENT
The MD, APTS intends to sign Agreements with the successful bidder for O&M of
APeProcurement Platform (Application) of ITE&C Department, GoAP – a Master Services
Agreement (MSA) and a Service Level Agreement (SLA). Given below is a draft of the
MSA. Schedule VIII of the MSA provides a draft SLA.
Master Services Agreement (MSA)
THIS AGREEMENT is made this day of ______ two Thousand and ______, by and
between:
(i) The MD, APTS _________________India; (hereinafter called “the Contracting
Authority”) AND
(ii) ___<name of the company>___, a company registered under the Indian Companies
Act, 1956 and its subsequent amendments having its registered office at
___<address>____ and place of business at __<address>__ (hereinafter referred to as
"System Integrator", which expression, unless excluded or the context otherwise
required hereof includes its successors, administrators and assigns) represented
through its __ <designation of authorized person>___, who is duly authorized by the
System Integrator
WHEREAS
A. The Contracting Authority intends for selection of System Integrator for
Operation & Maintenance of APeProcurement Platform (Application) along with
change management of ITE&C Department, GoAP to the departments for
procurement of goods/ works/ items in transparent manner.
B. Managing Director, APTS on behalf of ITE&C Department under took selection
process of a suitable SI, adopting an open tender process, through competitive
bidding for implementing the O&M of APeProcurement Platform (Application)
issued a Request for Proposal (RFP);
C. The System Integrator has been selected as the successful bidder to undertake
the O&M and change management of APeProcurement Platform (Application) of
ITE&C Department, GoAP, to achieve the defined objectives and desired service
levels for APeProcurement Platform;
D. The Contracting Authority intends to appoint the System Integrator to undertake
and start the O&M and change management as described in Volume I & Volume
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 16 of 107
II, pre-bid clarifications if any on the terms and conditions set forth below.
E. The System Integrator in pursuance of its proposal undertakes to implement the
O&M and change management under APeProcurement Application platform.
NOW THEREFORE, IN CONSIDERATION OF THE MUTUAL PROMISES AND COVENANTS
AND CONDITIONS HEREIN CONTAINED, IT IS HEREBY AGREED BETWEEN THE PARTIES AS
FOLLOWS:
The Contracting Authority and the System Integrator (SI) (each individually a “Party”
hereto and collectively the “Parties”) have agreed to enter into this Agreement to
govern the way in which the System Integrator will design, develop, implement &
manage the solution and facilities and deliver the services specified under this
Agreement and the Service Level Agreement (“SLA") in accordance with roles and
responsibilities of the Contracting Authority and its nominated agencies and the System
Integrator as set forth in this agreement.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 17 of 107
1 ARTICLE I - DEFINITIONS & STRUCTURE
1.1 DEFINITIONS
a. In this Agreement, unless the context requires otherwise:
i. “Agreement" means this Agreement together with all the Schedules and the
contents and specifications of the RFP. In the event of a conflict between this
Agreement and the Schedules, the terms of the Agreement shall prevail;
ii. “Asset” means any data, information, deliverable, solutions, services, products
and materials tangible or intangible that are procured, produced, developed,
installed, maintained and serviced in due course of delivering the scope of
Service provided by the System Integrator/ System Integrator as per the
requirements of the RFP
iii. “Bespoke Software” means the software designed, developed, tested and
deployed by the System Integrator for the purposes of rendering the Services
to the Stakeholders of the Project and includes the source code along with
associated documentation, which is the work product of the development
efforts involved in the Project and the improvements and enhancements
effected during the term of the Project, but does not include the third party
software products (except for the customization components on such
products), proprietary software components and tools deployed by the System
Integrator, and which, i.e., the bespoke software, shall be solely owned by the
Contracting Authority;
iv. “MD, APTS” means Managing Director, AP Technology Services Ltd, on behalf of
ITE&C Department, Government of Andhra Pradesh or an Officer of appropriate
rank as per the Government rules & regulations of the GoAP, appointed by the
Government of Andhra Pradesh mentioned in the RFP.
v. “Consortium Member” means a member associated with the prime bidder to
execute scope of work of APeProcurement Application as per the roles and
responsibilities defined in the Memorandum of Association submitted along
with Proposal.
vi. “Confidential Information" means all information including Project Data
(whether in written, oral, electronic or other format) which relates to the
technical, financial and business affairs, citizens, customers, suppliers,
products, developments, operations, processes, data, trade secrets, design
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 18 of 107
rights, know-how and personnel of each Party and its affiliates which is
disclosed to or otherwise learned by the other Party (whether a Party to this
Agreement or to the SLA) in the course of or in connection with this Agreement
(including without limitation such information received during negotiations,
location visits and meetings in connection with this Agreement or to the SLA);
vii. “COTS/ Commercial off the Shelf Product” means hardware or software that is
ready made available to the general public and tailored to meet the specific
requirements of a particular functionality/ applications and can be used with
little or no modifications.
viii. “Down Time” Defined as the time during which the systems and/or services
running on it are not available and or are deemed to be not available to the
users in part or full due to any non-functioning repairs/problems.
ix. "Deliverables" means the products, infrastructure and services agreed to be
delivered by the System Integrator in pursuance of the agreement as listed in
the RFP and defined more elaborately in Volumes I and II of the RFP in relation
to the Implementation Phase and the Operations and Maintenance Phase and
includes all documents related to the solution, user manual, technical manual,
design, process and operating manuals, service mechanisms, policies and
guidelines and source code and all its modifications;
x. “Effective Date” means the date on which this Contract is signed by both
parties.
xi. “Existing System Integrators” means the existing System Integrators and their
consortium members working on legacy applications in the concerned
departments associated with the Platform/module mentioned in the RFP.
xii. “Intellectual Property Rights" means and includes all rights in the Bespoke
Software, its improvements, upgrades, enhancements, modified versions that
may be made from time to time, database generated, compilations made,
source code and object code of the software, the said rights including designs,
copyrights, trademarks, patents, trade secrets, moral and other rights therein;
xiii. “Managing Director” means Managing Director, APTS Government of Andhra
Pradesh or an Officer of appropriate rank as per the Government rules &
regulations of the GoAP, appointed by the Government of Andhra Pradesh, to
be responsible for discharging all the responsibilities mentioned in the RFP
under O&M of APeProcurement Application Project.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 19 of 107
xiv. “Material Breach” means breach that has an effect on (a) the ability of SI to
perform/discharge any of its duties/obligations under and in accordance with
the provisions of the Agreement; and/or (b) the legal validity, binding nature or
enforceability of the Agreement;
xv. “Operations and Maintenance (O&M)” means and includes without limitation
the services including routine, periodic and milestone maintenance and
servicing to ensure the ITE&C Department of continuous and efficient
operation of the hardware, software and related services required for the
Project.
xvi. “Pilot” means set of activities as mentioned in the RFP to be performed by the
System Integrator at select locations on select data as mentioned in the RFP to
ascertain the functionality of the Platform before it is implemented and rolled
out across all project locations.
xvii. “Project” means the activities associated with Design, Development and/or
customization, Testing, Pilot, Implementation/Rollout, Supply & Installation of
Hardware and Network Components, Operations, and Maintenance of the
whole system and Training, across all the locations of Andhra Pradesh as per the
terms and conditions laid down in the RFP and provision of modules of the
Platform mentioned in the RFP under conformance to the SLA;
xviii. “Project Data" means all proprietary data of the Project generated out of
Project operations and transactions, documents and related information
including but not restricted to user data which the System Integrator obtains,
possesses or processes in the context of providing the Services to the users
pursuant to this Agreement and the SLA;
xix. “Performance Guarantee” and “Performance Bank Guarantee” shall mean the
guarantee provided by a Nationalized/ Scheduled Bank to APTS/ITE&C
Department on behalf of the System Integrator for the amount as specified in
the RFP Datasheet in Volume I of the RFP
xx. “Project Implementation” means Project Implementation as per the testing
standards and acceptance criteria prescribed in the respective section of the
RFP;
xxi. “Project Implementation Completion date”/ ”Go-Live” means the date on
which the proposed Platform/ module under APeProcurement Application is
operational as per the functional, technical and operational requirements
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 20 of 107
specified in the Volume I of the RFP and all the acceptance tests & certifications
as defined in the respective sections of the Volume I of the RFP are successfully
concluded to the satisfaction of the PM.
xxii. "Proprietary Information" means processes, methodologies and technical and
business information, including drawings, designs, formulae, flow charts, data
and computer programs already owned by, or granted by third parties to a
Party hereto prior to its being made available under this Agreement, or the SLA;
xxiii. “Project location” means Place of work wherein the system integrator is
supposed to provide the services defined in the scope of work to the
contracting authority, which shall be located at Vijayawada/ Amaravati.
xxiv. “Payment Authority” means the APTS/ ITE&C Department.
xxv. “Prime Bidder” means Agency/Company part of the consortium and severely
responsible for executing the work as mentioned in the RFP and acts as Single
Point of Contact (SPOC) for the Project.
xxvi. “Program Management Unit (PMU)” means a body created by ITE&C
department exclusively to oversee the progress of the APeProcurement
Project. The PMU will comprise of representatives from the, members of ITE&C
department, APTS, and external consultants selected for this purpose and
appointed by the MD, APTS/ ITE&C Department. The Secretary, ITE&C
Department will be the Chairman of the PMU and the PMU will report to the
Steering Committee. PMU will be formed by the date of signing of the contract.
xxvii. “RFP” or “Request for Proposal” means the documents containing the
Technical, Functional, Operational, Commercial, Legal Specifications and other
data for the implementation of the Project, issued in 2 volumes (referred to as
Volume I and Volume II) and includes the clarifications, explanations and
amendments issued by APTS/ ITE&C Department from time to time.
xxviii. "Replacement System Integrator" means any third party that the
Contracting Authority may appoint to replace the System Integrator upon
expiry of the Term or otherwise termination of this Agreement or the SLA to
undertake the Services or part thereof;
xxix. "Service Level" means the level of service and other performance criteria
which will apply to the Services as set out in the SLA;
xxx. “Service Level Agreement (SLA)” means the Project Implementation and
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 21 of 107
Operation and Maintenance SLA, executed by and between System Integrator
and Contracting Authority in terms of the Service Level Requirements as per
the model set out in Schedule VIII of this Agreement;
xxxi. "Services" means the services delivered to the Stakeholders of the PROJECT,
namely, the departments seeking APeProcurement Platform and other
stakeholders as defined in the respective sections of Volume I and II of the RFP,
using the tangible and intangible assets created, procured, installed, managed
and operated by the System Integrator including the tools of information and
communications technology and includes but is not limited to the list of
services specified in Volume I & II of the RFP herein;
xxxii. “System Integrator (SP)” means the selected bidder along with any or all
consortium members who are signatory to the MSA and have direct or indirect
relation to provide the services mentioned in Volume I, II of this RFP.
xxxiii. System Integrator (SI) is synonymous with System Integrator
xxxiv. “Stakeholders” means departments, APTS/ITE&C Department, all the state
government departments of AP directly or indirectly related to the
APeProcurement project, offices who are directly or indirectly related to the
project, all third parties involved by the Government of AP in relation to
APeProcurement project implementation and their employees;
xxxv. “State Data Centre (SDC)” means the State Data Centre located at Hyderabad/
Amaravati in the new capital of Andhra Pradesh.
xxxvi. “Steering Committee” means a body appointed by the Government of Andhra
Pradesh to oversee the progress of the APeProcurement Application Platform.
xxxvii. "Third Party Systems" means Systems (or any part thereof) in which the
Intellectual Property Rights are owned by a third party and to which System
Integrator has been granted a license to use and which are used in the
provision of Services for this project;
xxxviii. “Up Time” Defined as the time during which the systems and/or services
running on it are available and/or are deemed to be available to the users in
full without any non-functioning repairs/ problems.
xxxix. “Contract Documents” The following documents shall constitute the
Contract between APTS/ITE&C and the System Integrator, and each shall be
read and construed as an integral part of the contract. This contract
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 22 of 107
agreement and the appendices attached to the contract agreement
constitute the contract documents :
a) PBG No.__________________, Dated ________________ for
Rs._________, issued by ____________, Valid up to
____________________.
b) Notification of Award Dated ______________ for Rs.______________
(Rupees __________________________ only) all inclusive of taxes. The
breakup of the cost is enclosed Annex to this contract.
c) This Master Service Agreement (MSA)
d) Price Schedules dated ______________
e) Pre-Bid Conference Minutes and amendments dated
__________________.
f) Bid document with modifications if any.
g) Any other documents (RFP Ref.No._______________, Dated __________
contains 2 (two) Volumes & Technical Bid submitted by Service Provider)
xl. “Order of Precedence”: In the event of any ambiguity or conflict between the
Contract Documents listed above, the order of precedence shall be the order
in which the Contract Documents are listed in (Contract Documents) above
(xxxix).
b. References to any statute or statutory provision include a reference to that statute
or statutory provision as from time to time amended, extended, re-enacted or
consolidated and to all statutory instruments made pursuant to it.
c. Words denoting the singular shall include the plural and vice versa and words
denoting persons shall include firms and corporations and vice versa.
d. Unless otherwise expressly stated, the words "herein", "hereof", "hereunder" and
similar words refer to this Agreement as a whole and not to any particular Article,
Schedule. The term Articles, refers to Articles of this Agreement. The words
"include" and "including" shall not be construed as terms of limitation. The words
"day" and "month" mean "calendar day" and "calendar month" unless otherwise
stated. Where, because of a difference in time zone, the calendar day or calendar
month in one Country differs from another Country, then the calendar day or
calendar month shall be deemed to be the calendar day or calendar month
applicable to India. The words "writing" and "written" mean "in documented form",
whether electronic or hard copy, unless otherwise stated. Any reference to
attorneys' fees shall include reasonable fees of the professional assistants of such
attorneys.
e. The headings and use of bold type in this Agreement are for convenience only and
shall not affect the interpretation of any provision of this Agreement.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 23 of 107
1.2 STRUCTURE
a. This Agreement shall operate as a legally binding services agreement specifying the
master terms which apply to the Parties under this Agreement and to the provision
of the Services by the System Integrator to the stakeholders of the Project under the
duly executed SLA.
b. The SLA in respect of the Operation and Maintenance is being entered into
concurrently with this Agreement between the System Integrator and Contracting
Authority. In respect of any future SLAs entered into between the Parties, each of
the Parties shall observe and perform the obligations set out herein.
c. In the event of a change of Control of the System Integrator during the currency of
this Agreement, System Integrator shall promptly notify the Contracting Authority of
the same and in the event that the net worth of the surviving entity is less than that
of System Integrator prior to the change of Control, the Contracting Authority may
within 30 days of his/ her becoming aware of the change in Control, require a
replacement of existing Performance Guarantee furnished by the System Integrator
from a guarantor acceptable to the Contracting Authority (which shall not be System
Integrator or any of its associated entities). If such a guarantee cannot be obtained
within 30 days of the Contracting Authority becoming aware of the change in
Control, he/ she may exercise its right to terminate the SLA within a further 30 days
by written notice, to become effective when specified in such notice. Pursuant to
termination, the consequences of termination as set out in Article 5.2 will become
effective. The internal reorganization of the System Integrator shall not be deemed
an event of a change of Control for purposes of this Article unless the surviving
entity is of less net worth than the predecessor entity.
1.3 CONDITIONS PRECEDENT
Subject to express terms to the contrary, the rights and obligations under this
Agreement shall be effective (at any point of time during the course of the
Agreement) only upon fulfilment of all the Conditions Precedent set out in Articles
1.3.1 and 1.3.2. However, the Contracting Authority may at any time at its sole
discretion waive fully or partially any of the Conditions Precedent for the System
Integrator.
1.3.1 CONDITIONS PRECEDENT FOR SYSTEM INTEGRATOR
The System Integrator shall have to fulfil Conditions Precedent, which are as follows:
Submit the Performance Bank Guarantee as specified in the respective sections
of the Volume I & II of the RFP or the Security Deposit, in the form of a Bank
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 24 of 107
Guarantee as specified to the APTS, within period as specified in the datasheet
from the date of issue of LOA.
a. Provide the APTS, certified true copies of its constitutional documents and board
resolutions authorizing the execution, delivery and performance of this
Agreement and the SLA;
b. Deploy the team as required and ensure the project take over within fifteen (15
days) calendar days of the issue of LOA by Managing Director, APTS.
c. Fulfil the Mandatory Compliances as listed in Schedule X of this Agreement
1.3.2 NON-FULFILMENT OF CONDITIONS PRECEDENT
a. In the event that any of the Conditions Precedent relating to System Integrator
has not been fulfilled within 30 days of the time limit prescribed for each
condition, and the same has not been waived by the APTS/ ITE&C Department
fully or partially, this Agreement shall cease to have any effect as of that date.
b. In the event that the Agreement fails to come into effect on account of non-
fulfilment of the System Integrator's Conditions Precedent, Contracting Authority
or its nominated agencies shall not be liable in any manner whatsoever to the
System Integrator and Contracting Authority shall forthwith invoke the
Performance Guarantee and forfeit the guaranteed amount.
c. In the event that vacant possession of any of the PROJECT facilities and/or
PROJECT Data has been delivered to the System Integrator prior to the fulfilment
in full of the Conditions Precedent, upon the termination of this Agreement such
Project facilities and Project data shall immediately revert to the Contracting
Authority or its nominated agencies, free and clear from any encumbrances or
claims.
d. Instead of terminating this Agreement as provided in paragraph 1.3.2(a) above,
the Contracting Authority or its nominated agencies, may extend the time for
fulfilling the Conditions Precedent and the Term of this Agreement. It is clarified
that any extension of time shall be subject to imposition of agreed liquidated
damages on the System Integrator linked to the delay in fulfilling the Conditions
Precedent.
1.4 SCOPE OF CONTRACT
The scope of work for the SI will be as per the scope defined in the RFP
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 25 of 107
For the avoidance of doubt, it is expressly clarified that this Agreement shall govern the
provision of the contracted professional services under the SLA to the Contracting
Authority or its nominated agencies. It is anticipated that new or renewal agreements
may be undertaken by creating a separate SLA, with schedules and annexures as
required, under this Agreement for each additional engagement.
1.4.1 INTERPRETATION OF THE SCOPE OF WORK
a) Contracting Authority or its nominated agencies retains the right of the final say
in the interpretation of the scope of the Project. The possible variations to the
processes within the boundaries of the functional requirements specified in the
RFP from the way they are specified in the scope of work should not be
considered as deviations or extensions to the original process specifications.
b) Sign-off on the deliverables by the Contracting Authority does not necessarily
indicate the complete approval of the deliverables. All the responsibilities with
respect to operations and maintenance of the applications, infrastructure or
requirements in the RFP or Department processes will be borne by the System
Integrator. Any gap that is found in a deliverable with respect to the above, even
after the sign-off, will have to be addressed by the System Integrator without
any additional cost to the Contracting Authority.
c) The performance of the ultimate system can be achieved by different
combinations of the Equipment and Network components. The final acceptance
of the integrated solution and infrastructure components should be as per the
performance requirements and will be the determining factor but not the
specifications of the infrastructure alone.
1.5 PERIOD/ TERM OF CONTRACT
The period/ term of this contract shall begin from the ‘Effective Date’. The System for
Operations & Maintenance is 3 (three) years) from the date of go-live. Time shall be the
essence of this Contract as well as of the SLA. The contract shall be valid for 3 years from
the effective date or data of takeover, whichever is earlier.
1.6 EXTENSION OF THIS AGREEMENT
The Contracting Authority may choose to extend the term on mutually agreed terms
and conditions for a period of not exceeding 1 (one) year up to a maximum of 3 (three)
times or at a single period of 3 (three) years to avail the services of SI for specific work
or continuation of the work carried out during the Operations & Maintenance Period of
Contract without the need to go for a separate bid process. The decision on the
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 26 of 107
extension will be taken exclusively by the Contracting Authority keeping in consideration
a) Satisfactory Performance of the Operator b) Time Constraints or other Serious
Impediments in Selection of Replacement Operator c) Technological Reasons d) Where
circumstances inescapably require taking recourse to this option.
All the general terms and conditions other than the scope of work of this Contract will
be in force during the extended period of the Contract. The new scope of work for the
extension period will be defined through the change control procedure mentioned in
Agreement.
1.7 ADDITIONAL WORK
The Contracting Authority has the option to avail the services of System Integrator for
carrying out any additional work within scope of work, as a part of the Project, provided
the prices for the same has been obtained already in the bidding process leading to this
Contract without the need to go for a separate procurement process. All such additional
work will be initiated using the change control procedures listed in the Agreements
1.8 COMMENCEMENT AND DURATION OF THE SLA
a. The Operation and Maintenance (O&M) SLA will commence from the date when the
Project has taken over to the satisfaction of the Contracting authority or its
nominated agencies and certified in accordance with the terms of this Agreement
and shall run for a period coterminous with the MSA.
b. The SLA shall commence on the date on which it is fully executed as specified above
in section 1.8 (a) or as decided by the Contracting Authority and the System
Integrator as the case may be depending on the project requirements and shall,
unless terminated earlier in accordance with its terms or unless otherwise agreed by
the Parties, expire on the date on which this Agreement expires or terminates for
any reason. However such automatic cessation of the SLA do not qualify in case the
various handover of the assets created under this contract is not completed,
settlement of the disputes on SLA, support from the SI to host the applications in the
Government decided location and making the services operational as required to the
fullest satisfaction of the Contracting Authority. In all these cases, SLA would be
continued for the extended period and would also be associated with an extension
of MSA as required by the Contracting Authority.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 27 of 107
2 ARTICLE II – INITIALIZATION
2.1 PROVISION OF THE SERVICES
a. The provision of Services to the Stakeholders with certainty and speed is the essence
of the Agreement between the Parties.
b. The System Integrator represents that it is a competent and efficient provider of a
variety of information technology and business process management services.
System Integrator will keep abreast of the relevant technical, managerial and
operational requirements applicable to the provision of the Services and best
practices in this area and will share their knowledge with the Contracting Authority
or its nominated agencies, regarding matters which would assist the Contracting
Authority or its nominated agencies, in its use of the Services, provided that System
Integrator shall not be obligated to share other Contracting Authority information or
Confidential Information of System Integrator not relevant to this Agreement.
c. The Services shall be performed by the System Integrator pursuant to terms under
the SLA to be entered into in accordance with this Agreement.
d. The System Integrator shall perform the Services (a) in a good professional manner
commensurate with professional industry and technical standards which are
generally in effect for international projects and innovations pursuant thereon
similar to those contemplated by this Agreement, (b) so as to comply with the
applicable Service Levels, in accordance with the terms set out in this Agreement
and the SLA.
e. No Party to this Agreement or to the SLA will at any time perform, or omit to
perform, any act which they are aware, at the time of performance, will place the
other Party in default under any insurance policy, mortgage or lease, governing
activities at any location provided by Contracting Authority or its nominated
agencies.
2.2 APPROVALS AND REQUIRED CONSENTS
a. The Parties will cooperate reasonably to obtain, maintain and observe all relevant
and customary regulatory and governmental licenses, clearances and applicable
approvals (hereinafter the “Approvals”) necessary for the System Integrator to
provide the Services. The costs of such Approvals shall be borne by the System
Integrator.
b. Both parties will give each other all co-operation and information reasonably
required to meet their respective obligations under this Agreement.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 28 of 107
c. Contracting Authority or its nominated agencies shall use reasonable endeavours to
assist System Integrator obtain the approvals. In the event that any Approval is not
obtained, the System Integrator, Contracting Authority or its nominated agencies
will co-operate with each other in achieving a reasonable alternative arrangement as
soon as reasonably practicable for the Contracting Authority or its nominated
agencies to continue to process its work with as minimal interruption to its business
operations as is commercially reasonable until such Approval is obtained, provided
that the System Integrator shall not be relieved of its obligations to provide the
Services and to achieve the Service Levels until the Approvals are obtained if and to
the extent that the System Integrator's obligations are dependent upon such
Approvals.
2.3 USE AND ACQUISITION OF ASSETS
During the Term of the MSA, the System Integrator shall:
a. Take all reasonable and proper care of the entire hardware and software, network
or any other information technology infrastructure components used for the Project
and other facilities leased/ owned by the System Integrator exclusively in terms of
the delivery of the Services as per this Agreement (hereinafter the “Assets”) in
proportion to their use and control of such Assets which will include all upgrades/
enhancements and improvements to meet the current needs of the Project; and
b. Keep all the tangible Assets in as good and serviceable condition and/or the
intangible Assets suitably upgraded subject to the relevant standards as stated in the
RFP as at the date the System Integrator takes control of and/or first uses the Assets
and during the entire Term of the Agreement; and
c. Ensure that any instructions or manuals supplied by the manufacturer of the Assets
for use of the Assets and provided to the System Integrator will be followed by the
System Integrator and any person who will be responsible for the use of the Assets;
and
d. Take such steps as may be properly recommended by the manufacturer of the
Assets and notified to the System Integrator or as may, in the reasonable opinion of
the System Integrator, be necessary to use the Assets in a safe manner; and
e. To the extent that the Assets are under the control of the System Integrator, keep
the Assets suitably housed and in conformity with any statutory requirements from
time to time applicable to them; and
f. Provide permission to Contracting Authority or its nominated agencies and any
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 29 of 107
persons duly authorized by him/her to enter any land or premises on which the
Assets are for the time being sited so as to inspect the same, subject to any
reasonable third party requirements; and
g. Not knowingly or negligently use or permit any of the Assets to be used in
contravention of any statutory provisions or regulation or contrary to law; and
h. Use the Assets exclusively for the purpose of providing the Services as appropriate;
and
i. Not sell, offer for sale, assign, mortgage, pledge, sub-let or lend out any of the
Assets; and
j. Use the Assets only in accordance with the terms hereof and those contained in the
SLA; and
k. Obtain and/or maintain standard forms of comprehensive insurance policy including
liability insurance, system and facility insurance and any other insurance for the
personnel, Assets, data, software, and
l. Transfer the ownership of all the Assets (not already with the Contracting Authority
or its nominated agencies, including but not limited to the project documentation
which is the work product of the development efforts involved in the Project) within
30 days of the acceptance of the same by the Contracting Authority or its nominated
agencies upon testing and/or audit, to the Contracting Authority or its nominated
agencies in accordance with the terms of this agreement; and
m. Ensure the integration of the software with hardware to be installed and the current
Assets in order to ensure the smooth operations of the entire solution architecture
to provide efficient services to all the Stakeholders of Project in an efficient and
speedy manner; and
n. An approval (i.e. sign off) from the Project Manager (PM) at each stage is essential to
close each of the above considerations.
2.4 ACCESS TO SYSTEM INTEGRATOR
a. For so long as the System Integrator provides Services from any Project location
and to the extent necessary for the System Integrator or its nominated agencies
to provide the Services and at no cost to the System Integrator, Contracting
Authority or its nominated agencies shall, have the rights to access and inspect
subject to compliance by the System Integrator with any safety and security
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 30 of 107
guidelines which may be notified by the Contracting Authority or its nominated
agencies in writing, the System Integrator shall provide the APTS/ ITE&C
Department with:
(i) Reasonable access, in the same manner granted to the Project employees, to
project locations twenty-four hours a day, seven days a week; and
(ii) Access to office equipment as mutually agreed and other related support
services in such location and at such other project location, if any, as may be
reasonably necessary for the Contracting Authority or its nominated agencies
to perform its audit and related functions hereunder and under the SLA.
b. Locations and items shall be made available to the System Integrator on an "as
is, where is" basis by the Contracting Authority. The System Integrator agrees to
ensure that its employees, agents and contractors do not use the location,
services and items:
(i) For the transmission of any material which is defamatory, offensive or
abusive or of an obscene or menacing character; or
(ii) In a manner which constitutes a violation or infringement of the rights of any
person, firm or company (including but not limited to rights of copyright or
confidentiality).
(iii) Infringes with any provisions of the Indian Information Technology Act 2000
and its subsequent amendments
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 31 of 107
3 ARTICLE III - MANAGEMENT
3.1 GOVERNANCE
The review and management process of this Agreement shall be carried out in
accordance with the Governance Schedule (Schedule IV of this Agreement) and shall
cover all the management aspects as set out in the RFP.
3.2 USE OF SERVICES
a. Contracting Authority or its nominated agencies other stakeholders will undertake
and use the Services in accordance with the business requirements of this RFP and
shall be guided generally by the government procedures wherever applicable.
System Integrator shall formulate instructions or procedures as required by the
business for such usage and mutually agreed by the Parties from time to time.
b. Contracting Authority or its nominated agencies shall be responsible for the
operation and use of the Deliverables resulting from the Services provided by the SI.
3.3 CHANGES/ AMENDMENTS
Unless expressly dealt with elsewhere in this Agreement, any amendments under or to
this Agreement or under or to the SLA shall be dealt with in accordance with the Change
Control Schedule (Schedule I of this Agreement).
3.4 SECURITY AND SAFETY
a. The System Integrator will comply with the directions issued from time to time by
the Contracting Authority or its nominated agencies and the standards related to the
security and safety as stated in the respective sections of the RFP, in so far as it
applies to the provision of the Services.
b. Each Party to the SLA shall also comply with Project’s information technology
security standards and policies in force from time to time at each location of which
the Contracting Authority makes the System Integrator aware in writing in so far as
the same apply to the provision of the Services.
c. The Parties to the SLA shall use reasonable endeavours to report forthwith in writing
to each other all identified attempts (whether successful or not) by unauthorized
persons (including unauthorized persons who are employees of any Party) either to
gain access to or interfere with the Project's data, facilities or Confidential
Information.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 32 of 107
d. The System Integrator shall upon reasonable request by the Contracting Authority or
its nominee(s) participate in regular meetings when safety and information
technology security matters are reviewed.
e. The Parties under the SLA shall promptly report in writing to each other any act or
omission which they are aware that could have an adverse effect on the proper
conduct of safety and information technology security at Project’s Facilities.
f. The System Integrator shall facilitate the Third Party Auditing of the services
provided by the System Integrator from time to time by an agency nominated by
(a) Contracting Authority or its nominated agencies for Go-live and submission to the
department to ensure the security and safety
(b) Agency nominated by the Contracting Authority or its nominated agencies/ APTS
on behalf of ITE&C after Go-live anytime during the Contracting period.
3.5 CO-OPERATION
a. Except as otherwise provided elsewhere in this Agreement or the SLA, each Party
("Providing Party") to this Agreement or to the SLA undertakes promptly to provide
the other Party ("Receiving Party") with all such information and co-operation which
the Receiving Party reasonably requests, provided that such information and co-
operation:
(i) Is reasonably required by the Receiving Party in order for it to comply with its
obligations under this Agreement or the SLA; and
(ii) Is not Confidential Information; and
(iii) Is capable of being provided by the Providing Party.
b. Each Party agrees to co-operate with the contractors and sub-contractors of the
other Party as reasonably requested in order to accomplish the purposes of this
Agreement.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 33 of 107
4 ARTICLE IV - FINANCIAL TERMS
4.1 TERMS OF PAYMENT, PENALTIES AND INCENTIVES
Terms of payments are: (a) Quarterly payments for deliverables (b) Penalties
4.1.1 MILESTONE PAYMENT
In consideration of the Services and subject to the provisions of this Agreement and of
the SLA, the Contracting Authority shall pay the System Integrator for the application
services in accordance with the Terms of Payment Schedule (Schedule VI of this
Agreement)
4.1.2 QUARTERLY PAYMENT FOR DELIVERABLES
In consideration of the Services and subject to the provisions of this Agreement and of
the SLA, the Contracting Authority shall pay the System Integrator for the Services
rendered in pursuance of this agreement, in accordance with the Terms of Payment
Schedule (Schedule VI of this Agreement). The Contracting Authority shall release the
payment to System Integrator only if the System Integrator is able to achieve the
Service Levels as specified in Service Level Agreement.
4.1.3 PENALTIES
a. All payments are subject to the application of liquidated damages and penalties
defined and provided for in this Agreement and the SLA. It is clarified here that the
Contracting Authority, can also calculate a financial sum based on the certification
and recommendations of the PM and debit or credit the same against the terms of
payment as defined in the Terms of Payment Schedule as a result of the failure or
success of the System Integrator to meet the Service Level under the SLA, such sum
being determined in accordance with the terms set out in this Agreement and the
SLA.
b. Except as otherwise provided for herein or as agreed between the Parties in writing,
the Contracting Authority shall not be required to make any payments in respect of
the Services other than those covered by the terms of payment as stated in the
Terms of Payment Schedule (Schedule VI of this Agreement).
4.2 INVOICING AND SETTLEMENT
The provisions of the Invoicing & Settlement Schedule (Schedule V of this
Agreement) shall apply.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 34 of 107
4.3 TAX CONSIDERATION
a. The Contracting Authority shall be responsible for withholding taxes from the
amounts due and payable to the System Integrator wherever applicable. The System
Integrator shall pay for all other taxes in connection with this Agreement, and SLA
including, but not limited to, property, sales, use, excise duty, value-added, goods
and services, consumption and other similar taxes or duties.
b. The Contracting Authority shall provide System Integrator with the original tax
receipt of any withholding taxes paid for the project on payments under this
Agreement. The System Integrator agrees to reimburse and hold the Contracting
Authority harmless from any deficiency (including penalties and interest) relating to
taxes that are its responsibility under this paragraph. For the purposes of this
Agreement, taxes shall include, taxes incurred on transactions between and among
the Contracting Authority the System Integrator and any third party subcontractors.
c. In the event of any increase or decrease of the rate of taxes due to any statutory
notification(s) or new enactments during the Term of the Agreement the
consequential effect shall be to the account of the Contracting Authority. Taxes
should be invoiced at actual at the prevailing rates at the time of submission of
invoice.
d. In the event that any new laws or regulations imposing Taxes in respect of Supplier
supplies/ services under this Agreement are enacted after the Effective Date, the
party directly subject to such Taxes under such laws or regulations shall be
responsible for such Taxes. Where such Taxes are the responsibility of supplier and
supplier is entitled to charge them to contracting authority. Contracting Authority
shall pay/Adjust as the case may be. These Taxes in addition/deduction of taxes to the
consideration payable under this Agreement.
e. The Parties shall cooperate to enable each Party to accurately determine its own tax
liability and to minimize such liability to the extent legally permissible. In connection
therewith, the Parties shall provide each other with (i) any resale certificates, (ii) any
relevant information regarding use of out-of-state materials, equipment or services
and (iii) any exemption certificates or information reasonably requested by the
other Party.
4.4 LIQUIDATED DAMAGES
In the event of the System Integrator failure to submit the Bond, Guarantees and
Documents and supply the solution/ equipment as per the RFP, the contracting
Authority may at its discretion withhold any payment until the completion of the
contract. Contracting Authority shall deduct from the payment due to the Bidder as
agreed, liquidated damages are applicable as per SLA.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 35 of 107
5 ARTICLE V - BREACH, RECTIFICATION & TERMINATION
5.1 MATERIAL BREACH
In the event that either Party is in Material Breach of its obligations under this
Agreement or the SLA, the aggrieved Party may terminate this Agreement or the SLA
upon notice to the other Party. Any notice served pursuant to this Article shall give
reasonable details of the Material Breach, which could include the following events
and the termination will become effective:
(i) IF there is Breach which translates into default in providing Services by the
System Integrator as per this Agreement or the SLA, continuously for more
than one week, then the Contracting Authority will serve a seven (7) days’
notice for curing such Material Breach. In case the Material Breach continues
after the notice period, the Contracting Authority will have the option to
terminate the Agreement.
(ii) If there is a Breach by the Contracting Authority, by not providing support for
integration of system with the systems of the other departments that interface
the APeProcurement Application or other agencies (if any), or not providing the
certification without any valid reason, then the System Integrator may give a 15
days’ notice for curing the Material Breach. In the event the Breach continues,
the System Integrator will have the option to terminate the Agreement subject
to the Clause 5.4 (Termination) and of the provisions of the Exit management
Schedule (Schedule II of this Agreement).
5.2 COMPANY NAME CHANGE
Where a change of control of the System Integrator has occurred whereby the
System Integrator-company has merged, amalgamated or been taken over, due to
which the majority shareholding of the System Integrator has been transferred to
another entity, the Contracting Authority can by a 30 days written notice, terminate
this Agreement and such notice shall become effective at the end of the notice
period.
5.3 TERMINATION FOR BANKRUPTCY
a. The Contracting Authority may serve written notice on System Integrator at any time
to terminate this Agreement with immediate effect in the event of a reasonable
apprehension of bankruptcy of the System Integrator:
i) System Integrator shall in the event of an apprehension of bankruptcy
immediately inform the Contracting Authority well in advance (at least 3
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 36 of 107
months) about such a development;
ii) Conversely if the Contracting Authority apprehends a similar event regarding the
System Integrator, he/she can exercise the right of termination in the manner
stated hereinabove.
b. On termination of this Agreement for any reason, the SLA shall automatically
terminate forthwith and the Contracting Authority will decide the appropriate
course of action.
c. The termination provisions set out in Article V of this Agreement shall apply to the
SLA and “this Agreement” shall be deemed to refer to the SLA.
5.4 EFFECTS OF TERMINATION
a. In the event that the Contracting Authority, or the System Integrator, terminates this
Agreement pursuant to Article 5.1 and depending on the event of default,
compensation will be decided in accordance with the Terms of Payment Schedule
(Schedule II and VI of this Agreement).
b. Upon termination of this Agreement, the Parties will comply with the Exit
Management Schedule (Schedule II of this Agreement).
5.5 FRAUD BY SYSTEM INTEGRATOR, CONSORTIUM PARTNER’S AND SUB-
CONTRACTOR’S PERSONNEL
a. Contracting Authority reserves its right to initiate criminal action against the agents/
employees of the System Integrator/ Consortium Partner’s/ Sub Contractor’s for
fraud or misappropriation, besides stringent penalties. The management of the
System Integrator would also be made liable for action in case of fraud, under the
applicable laws and Contracting Authority may call for termination of the contract if
Contracting Authority finds it necessary to do so.
b. The Bidders and their respective officers, employees, agents and advisers shall
observe the highest standard of ethics during the bidding process and subsequent to
the issue of the LOA and during the subsistence of the Services Agreement.
Notwithstanding anything to the contrary contained herein, or in the LOA or the
Services Agreement, APTS may reject a Proposal, withdraw the LOA, or terminate
the Services Agreement, as the case may be, without being liable in any manner
whatsoever to the Bidder or the System Integrator, as the case may be, if APTS
determines that the Bidder or the System Integrator, as the case may be, has
directly or indirectly or through an agent, engaged in corrupt practice, fraudulent
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 37 of 107
practice, coercive practice, undesirable practice or restrictive practice in the bidding
process. In such an event, APTS/ ITE&C Department shall be entitled to encash and
appropriate the Bid Security or Performance Security, as the case may be, as
damages, without prejudice to any other right or remedy that may be available to
APTS under the Bidding Documents and/or the Services Agreement, or otherwise.
c. Without prejudice to the rights of APTS/GoAP (as applicable) under this RFP herein
above and the rights and remedies which may have under the LOA or the Services
Agreement, or otherwise, if a Bidder or the System Integrator/APTS/GoAP (as
applicable), as the case may be, is found by APTS to have directly or indirectly or
through an agent, engaged or indulged in any corrupt practice, fraudulent practice,
coercive practice, undesirable practice or restrictive practice during the bidding
process, or after the issue of the LOA or the execution of the Services Agreement,
such Bidder or the System Integrator, as the case may be shall not be eligible to
participate in any tender or RFP issued by APTS during a period of 2 (two) years from
the date such Bidder or the System Integrator, as the case may be, is found by APTS/
ITE&C Department to have directly or indirectly or through an agent, engaged or
indulged in any corrupt practice, fraudulent practice, coercive practice, undesirable
practice or restrictive practices, as the case may be.
d. For the purposes of this RFP, the following terms shall have the meaning hereinafter
respectively assigned to them:
(a) “corrupt practice” means (i) the offering, giving, receiving, or soliciting,
directly or indirectly, of anything of value to influence the actions of any
person connected with the bidding process (for avoidance of doubt,
offering of employment to or employing or engaging in any manner
whatsoever, directly or indirectly, any official of Contracting
Authority/APTS/ITE&C (as applicable) who is or has been associated in
any manner, directly or indirectly, with the bidding process or the LOA or
has dealt with matters concerning the Services Agreement or arising
there from, before or after the execution thereof, at any time prior to the
expiry of 1 (one) year from the date such official resigns or retires from or
otherwise ceases to be in the service of Contracting
Authority/APTS/ITE&C (as applicable), shall be deemed to constitute
influencing the actions of a person connected with the bidding process);
or (ii) save and except as permitted under this RFP, engaging in any
manner whatsoever, whether during the bidding process or after the
issue of the LOA or after the execution of the Services Agreement, as the
case may be, any person in respect of any matter relating to the Project
or the LOA or the Services Agreement, who at any time has been or is a
legal, financial or technical adviser of Contracting Authority/APTS/ITE&C
(as applicable) in relation to any matter concerning the Project;
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 38 of 107
(b) “fraudulent practice” means a misrepresentation or omission of facts or
suppression of facts or disclosure of incomplete facts, in order to
influence the bidding process;
(c) “coercive practice” means impairing or harming, or threatening to impair
or harm, directly or indirectly, any person or property to influence any
person’s participation or action in the bidding process;
(d) “undesirable practice” means (i) establishing contact with any person
connected with or employed or engaged by Contracting Authority with
the objective of canvassing, lobbying or in any manner influencing or
attempting to influence the bidding process; or (ii) having a Conflict of
Interest; and
(e) “restrictive practice” means forming a cartel or arriving at any
understanding or arrangement among Bidders with the objective of
restricting or manipulating a full and fair competition in the bidding
process.
5.6 Consequences of failure by the Successful Bidder to provide Services:
a) Risk Purchase Clause as per Govt. contracts
If the System Integrator fails to supply material/ deliver services within the stipulated
delivery date, the Contracting Authority reserves the right to procure same or
equivalent material/ services from alternative sources at the System Integrator's risk,
responsibility and cost. Any extra cost incurred in the procurement of the material/
service from alternative source will be recovered from the pending bills/ Security
Deposit/ Bank Guarantee of the defaulting System Integrator and if the value of the
materials under risk purchase exceeds, the amount of Security Deposit and/or Bank
Guarantee, the same may be recovered if necessary by due legal process.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 39 of 107
6 ARTICLE VI - PROTECTION AND LIMITATIONS
6.1 WARRANTIES
a. The System Integrator warrants and represents to the Contracting Authority that:
(i) It has full capacity and authority and all necessary approvals to enter into and
to perform its obligations under this Agreement;
(ii) This Agreement is executed by a duly authorized representative of System
Integrator;
(iii) It shall discharge its obligations under this Agreement with due skill, care
and diligence so as to comply with other clauses of this MSA
b. In the case of the SLA, the System Integrator warrants and represents to the
Contracting Authority, that:
(i) The System Integrator has full capacity and authority and all necessary
approvals to enter into and perform its obligations under the SLA and to
provide the Services;
(ii) The SLA has been executed by a duly authorized representative of the
System Integrator;
(iii) The System Integrator is experienced in managing and providing works
similar to the Services and that it will perform the Services with all due skill,
care and diligence so as to comply with Article 1.8;
(iv) The Services will be provided and rendered by appropriately qualified,
trained and experienced personnel;
(v) System Integrator has and will have all necessary licenses, approvals,
consents of third parties and all necessary technology, hardware and
software to enable it to provide the Services;
(vi) The Services will be supplied in conformance with all applicable laws,
enactments, orders and regulations;
(vii) System Integrator will use its reasonable endeavours to ensure that the
equipment, software and hardware supplied and/or used in the course of the
provision of the Services, save for the Assets, are operational and functional;
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 40 of 107
and
(viii) If System Integrator uses, in the course of the provision of the Services,
components, equipment, software and hardware manufactured by any third
party which are embedded in the Deliverables or are essential for the
successful use of the Deliverables, it will pass through third party
manufacturer's warranties relating to those components, equipment,
software and hardware to Contracting Authority to the extent possible. In
the event that such warranties cannot be enforced by the Contracting
Authority, the System Integrator will enforce such warranties on behalf of
the ITE&C Department and pass on to the Contracting Authority, the benefit
of any other remedy received in relation to such warranties.
(ix) System Integrator warrants that it will perform its responsibilities under the
Agreement in a manner that does not infringe any patent, copyright,
trademark, trade secret, or other proprietary rights of Contracting Authority
(x) System Integrator hereby warrants that neither the System Integrator and its
affiliates, nor its employees have, will have or will acquire any contractual,
financial, business or other interest that would conflict with the System
Integrator’s responsibilities under the Agreement.
c. Notwithstanding what has been stated elsewhere in this Agreement and the
Schedules attached herein, in the event the System Integrator is unable to meet the
obligations pursuant to the implementation of the Pilots, Projects, Operations and
Maintenance Services and any related scope of work as stated in this Agreement and
the Schedules attached herein, the Contracting Authority will have the option to
invoke the Performance Guarantee after serving a written notice fifteen days in
advance on the System Integrator.
d. Disclosure - In the event that any occurrence or circumstance comes to the attention
of either Party that renders any of its aforesaid representations or warranties untrue
or incorrect, such Party shall immediately notify the other Party of the same. Such
notification shall not have the effect of remedying any breach of the representation
or warranty that has been found to be untrue or incorrect nor shall it adversely
affect or waive any obligation of either Party under this Contract.
6.2 THIRD PARTY CLAIMS
a. Subject to Article 6.2b below, System Integrator (the "Indemnifying Party")
undertakes to indemnify the Contracting Authority (the "Indemnified Party") from
and against all losses, claims or damages on account of bodily injury, death or
damage to tangible personal property arising in favour of any person, corporation or
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 41 of 107
other entity (including the Indemnified Party) attributable to the Indemnifying
Party's performance or non-performance under this Agreement or the SLA.
b. The indemnities set out in Articles 6.2a shall be subject to the following conditions:
(i) The Indemnified Party, as promptly as practicable, informs the Indemnifying
Party in writing of the claim or proceedings and provides all relevant
evidence, documentary or otherwise;
(ii) The Indemnified Party shall, at the cost of the Indemnifying Party, give the
Indemnifying Party all reasonable assistance in the defence of such claim
including reasonable access to all relevant information, documentation and
personnel provided that the Indemnified Party may, at its sole cost and
expense, reasonably participate, through its attorneys or otherwise, in such
defence;
(iii) If the Indemnifying Party does not assume full control over the defence of a
claim as provided in this Article, the Indemnifying Party may participate in
such defence at its sole cost and expense, and the Indemnified Party will
have the right to defend the claim in such manner as it may deem
appropriate, and the cost and expense of the Indemnified Party will be
included in Losses;
(iv) The Indemnified Party shall not prejudice, pay or accept any proceedings or
claim, or compromise any proceedings or claim, without the written consent
of the Indemnifying Party;
(v) All settlements of claims subject to indemnification under this Article will: (a)
be entered into only with the consent of the Indemnified Party, which
consent will not be unreasonably withheld and include an unconditional
release to the Indemnified Party from the claimant for all liability in respect
of such claim; and (b) include any appropriate confidentiality agreement
prohibiting disclosure of the terms of such settlement;
(vi) The Indemnified Party shall account to the Indemnifying Party for all awards,
settlements, damages and costs (if any) finally awarded in favour of the
Indemnified Party which are to be paid to it in connection with any such
claim or proceedings;
(vii) The Indemnified Party shall take legally permissible steps that the
Indemnifying Party may reasonably require to mitigate or reduce its loss as a
result of such a claim or proceedings; and
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 42 of 107
(viii) In the event that the Indemnifying Party is obligated to indemnify an
Indemnified Party pursuant to this Article, the Indemnifying Party will, upon
payment of such indemnity in full, be subrogated to all rights and defences of
the Indemnified Party with respect to the claims to which such
indemnification relates;
6.3 LIMITATION OF LIABILITY
a. Notwithstanding any other term, there shall be no limitation of liability in case of
any damages for bodily injury (including death) and damage to real property and
tangible personal property and wilful fraud.
b. In all other cases not covered by 6.3.a above, the total financial liability of the
System Integrator shall be limited to the value of the contract under this contract.
c. Neither this Agreement nor the SLA grants or creates any rights, benefits, claims,
obligations or causes of action in, to or on behalf of any person or entity (including
any third party) other than between the respective Parties to this Agreement or the
SLA, as the case may be.
d. Any claim or series of claims arising out or in connection with this Agreement or the
SLA shall be time barred and invalid if legal proceedings are not commenced by the
relevant Party against the other Party within such period as may be permitted by
applicable law without the possibility of contractual waiver or limitation.
e. The Contracting Authority shall be entitled to claim the remedy of specific
performance under this Agreement or the SLA.
6.4 FORCE MAJEURE
a. Neither Party to this Agreement or to the SLA shall be liable to the other for any loss
or damage which may be suffered by the other due directly to the extent and for the
duration of any cause beyond the reasonable control of the Party unable to perform
("Force Majeure") events such as but not limited to acts of God not confined to the
premises of the Party claiming the Force Majeure, flood, drought, lightning or fire,
earthquakes, strike, lock-outs beyond its control, labour disturbance not caused at
the instance of the Party claiming Force Majeure, acts of government or other
competent authority, war, terrorist activities, military operations, riots, epidemics,
civil commotions etc. No failure, delay or other default of any contractor or sub-
contractor to either Party shall entitle such Party to claim Force Majeure under this
Article.
b. The Party seeking to rely on Force Majeure shall promptly, within 2 days, notify the
other Party of the occurrence of a Force Majeure event as a condition precedent to
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 43 of 107
the availability of this defence with particulars detailed in writing to the other Party
and shall demonstrate that it has taken and is taking all reasonable measures to
mitigate the events of Force Majeure.
c. In the event the Force Majeure substantially prevents, hinders or delays the System
Integrator's performance of Services necessary for project’s implementation or the
operation of the projects critical business functions for a period in excess of 5 days,
the Contracting Authority may declare that an emergency exists. However, when the
situation arising out of force majeure comes to an end in the assessment of
Contracting Authority, the following conditions shall apply:
i. Prior to commencement of operations: If the event of Force Majeure had
occurred prior to commencement of operations, upon its coming to an end the
System Integrator shall resume normal activities under this agreement
immediately. The Contracting Authority, if he considers it necessary, may grant an
extension of time to the System Integrator for resuming normal activities under
this agreement. If the System Integrator does not resume normal activities
immediately or within the extended period, if any, granted by the Contracting
Authority, the Contracting Authority will have the option to invoke the
Performance Guarantee, levy liquidated damages as per data sheet of Volume I of
RFP, obtain substitute performance from an alternate supplier at the cost of
System Integrator and/or terminate this Agreement.
ii. Post commencement of operations: If Force Majeure had occurred post
commencement of operations, upon its coming to an end, the System Integrator
shall resume normal services under this agreement immediately. The Contracting
Authority, if he considers it necessary, may grant an extension of time to the
System Integrator for resuming normal services under this agreement. However,
the Contracting Authority will deduct for each day of the extension period a
percentage proportionate to the number of days and the volume(s) (measured in
terms of ratio to the overall volume as recorded in the previous month) expected
in the affected area(s) from the next payable amount as per Payment Schedule. If
normal services are not resumed immediately or within the extended time, the
Contracting Authority will have the option to invoke the Performance Guarantee
and/or terminate the Agreement.
d. All payments pursuant to termination due to Force Majeure event shall be in
accordance with the Terms of Payment Schedule (Schedule VI of this Agreement).
e. Notwithstanding the terms of this Article, the failure on the part of the System
Integrator under the SLA or terms under the SLA to implement any disaster
contingency planning and back-up and other data safeguards in accordance with the
terms of the SLA or this Agreement against natural disaster, fire, sabotage or other
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 44 of 107
similar occurrence shall not be an event of Force Majeure.
6.5 DATA PROTECTION
a. In the course of providing the Services the System Integrator may be compiling,
processing and storing proprietary Project Data relating to the users.
b. The System Integrator and each user are responsible for complying with its
respective obligations under the applicable data protection laws and regulations
governing the Project Data.
c. As a processor of Project Data, the System Integrator will process Project Data in
accordance with the terms of this Agreement or the SLA.
d. The System Integrator shall not transfer any Project Data unless otherwise
authorized by the Contracting Authority in this regard.
e. Upon reasonable written request from a Party to the SLA, the other Party to the SLA
will provide the requesting Party with such information that it has regarding the
Project, Data and its processing which is necessary to enable the requesting party to
comply with its obligations under the applicable data protection law or regulation.
f. The System Integrator shall adhere to the relevant standards laid down by
Government of Andhra Pradesh and Government of India in the areas of Data
protection.
g. In the case of the data being transferred and/or stored in a cloud environment,
System Integrator shall take necessary measures and controls to protect the data
and also provide access to Contracting Authority or Its authorized agencies or third
parties to access and audit the controls and procedures followed for the data
protection of the data pertaining to this project only including audit of
infrastructure.
6.6 AUDIT, ACCESS AND REPORTING
a. The Parties shall comply with the Audit, Access and Reporting Schedule provided in
Schedule III.
b. The System Integrator shall, on request, allow access to the Contracting Authority
and its nominees to all information which is in the possession or control of the
System Integrator, which relates to the provision of the Services as set out in the
Audit, Access and Reporting Schedule and is reasonably required to comply with the
terms of the Audit, Access and Reporting Schedule.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 45 of 107
7 ARTICLE VII - INTELLECTUAL PROPERTY
7.1 INTELLECTUAL PROPERTY
a. Except to the extent otherwise expressly provided in this Agreement, the
Contracting Authority or its nominated agencies shall retain exclusive intellectual
property rights to the bespoke developed software, forms, customized source code
of the COTS software, Data Models, and the compilations of the Project to which
the Contracting Authority has sovereign rights and nothing herein shall or will be
construed or deemed to grant to the System Integrator any right, title, license, sub-
license, proprietary right or other claim against or interest in, to or under (whether
by estoppels, by implication or otherwise) to the aforesaid rights.
b. The IPR on the APeProcurement application shall vest with Government of Andhra
Pradesh as soon as the system is certified by a 3rd Party. A copy of the source code
shall be kept in the custody of APTS/ ITE&C/PMU on a quarterly basis, with proper
version control.
c. Without limiting the generality of Article 7.1.a and except to the extent otherwise
expressly agreed by the Parties to this Agreement or the SLA in writing, nothing
contained in this Agreement or the SLA shall or will be construed or deemed to grant
to the System Integrator any right, title, license or other interest in, to or under
(whether by estoppel, by implication or otherwise) any logo, trademark, trade name,
service mark or similar designations of PROJECT or its respective affiliates/ nominees
or any confusingly similar designations of Project.
d. Subject to any sole or exclusive rights granted by the Contracting Authority to a third
party prior to the Effective Date, the Contracting Authority grants to the System
Integrator and any sub-contractors to the System Integrator solely in their
performance of Services for PROJECT or its nominated agencies, non-exclusive, paid-
up, royalty-free right and license during the Term of this Agreement, but not the
right to sub-license, to use the PROJECT Data including the right to copy, perform,
display, execute, reproduce, modify, enhance and improve the Project Data to the
extent reasonably necessary or useful for the provision of Services hereunder.
e. All the licenses required for the APeProcurement Platform solution should be held
by and in the name of the GoAP as full use, enterprise licenses, unrestricted and
irreversible. This includes licenses for the Database, Application Server and any of
their components or any other software required to run the application successfully.
f. System Integrator shall not use the PROJECT Data to provide services for the benefit
of any third party, as a service bureau.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 46 of 107
g. System Integrator shall indemnify, defend and hold harmless Contracting Authority
and their respective officers, employees, successors and assigns, from and against
any and all losses arising from claims by third parties that any Deliverable (or the
access, use or other rights thereto) created by System Integrator pursuant to this
Agreement, and/or the SLA, or any equipment, software, information, methods of
operation or other intellectual property (or the access, use or other rights thereto)
provided by System Integrator or sub-contractors to the System Integrator pursuant
to this Agreement or the SLA (i) infringes a copyright enforceable in India, (ii)
infringes a patent issued in India, or (iii) constitutes misappropriation or unlawful
disclosure or use of another Party's trade secret under the laws of India (collectively,
"Infringement Claims"); provided, however, that this will not apply to any
Deliverable (or the access, use or other rights thereto) created by (A) Contracting
Authority ; (B) third parties (i.e., other than System Integrator or sub-contractors) at
the direction of Contracting Authority.
g. The Contracting Authority shall have no liability or obligation to System Integrator or
any other Party under Article 7.1.e above to the extent the Infringement Claim is
based upon any use of the equipment, software, information, methods of operation
or other intellectual property (or the access, use or other rights thereto) for the
benefit of any Party (including any use by System Integrator or its nominees outside
the scope of the Services) other than for the Project.
h. Notwithstanding any provisions of this Agreement to the contrary, the foregoing
remedies constitute the Parties' sole and exclusive remedies and each Party's entire
liability, with respect to Infringement Claims.
i. If System Integrator uses in the course of the provision of the Services any Third
Party System it will use all commercially reasonable endeavours to pass through to
the Contracting Authority such third party's warranties relating to such Third Party
Systems. In the event that such warranties cannot be passed through to or enforced
by the Contracting Authority, the System Integrator will enforce such warranties on
Contracting Authority behalf and account to APTS/ITE&C Department for so doing.
j. All rights, title and interest in and to, and ownership in, Proprietary Information of
Project which is provided to System Integrator, and all modifications, enhancements
and other derivative works of such Project Proprietary Information ("PROJECT
Proprietary Information"), as a result of Services rendered by the System Integrator
hereunder shall remain solely with the Contracting Authority. System Integrator
shall be entitled to use such Project Proprietary Information only during the
Agreement Term and only for the purposes of providing the Services or to the extent
necessary for System Integrator's normal operational, repair and maintenance
purposes related to the Services. The Contracting Authority shall retain ownership of
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 47 of 107
all Intellectual Property Rights related to Project Proprietary Information.
l. With respect to ownership of the Deliverables, the Parties agree that the following
shall apply:
(i) All the deliverables provided to Contracting Authority by System Integrator
during the course of its performance under this Agreement, and/or the SLA
which includes but is not limited to Bespoke Software as defined in this
Agreement, in which, subject to the foregoing provisions of this Article, all right,
title and interest in and to such Deliverables, shall, as between System
Integrator and Contracting Authority, immediately upon creation vest in
Contracting Authority.
m. The Contracting Authority hereby grants to System Integrator a non-exclusive right
and license to access and use the Project Proprietary Information solely for the
purpose of providing Services to Contracting Authority. Such right and license shall
terminate upon the expiration or termination of this Agreement.
n. Upon the expiration or any termination of this Agreement (and also in respect of the
SLA), System Integrator shall undertake the actions set forth below in this Article to
assist the Contracting Authority to procure replacement services equivalent to
Services provided hereunder.
(i) The System Integrator undertakes to negotiate in good faith with the
Contracting Authority to provide or receive services substantially equivalent to
the Services hereunder.
(ii) In respect of System Integrator’s usage of third party Intellectual Property
Rights, System Integrator undertakes to assist the Contracting Authority to
secure such consents or licenses from such third parties as are necessary to
enable the Project to receive services substantially equivalent to the Services
hereunder. The obligations of the System Integrator under this Article shall be
considered part of the services performed by the System Integrator under the
Exit Management Services.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 48 of 107
8 ARTICLE VIII – MISCELLANEOUS
8.1 CONFIDENTIALITY
a. The Contracting Authority may permit the System Integrator to come into
possession of confidential records as per the needs of the project and the System
Integrator shall maintain the highest level of secrecy, confidentiality and privacy
with regard thereto.
b. Additionally, the System Integrator shall keep confidential all the details and
information with regard to the Project, including systems, facilities, operations,
management and maintenance of the systems/ facilities.
c. System Integrator shall be prohibited from using the project data in whatever
manner, for purposes other than handling transactions through this project under
APeProcurement Application. System Integrator shall undertake, on behalf of its
agents and employees, that no project related data shall be copied in any manner
(paper, electronic, or human memory) and transferred to any entity (human or
machine) other than that being through this project for delivering job
responsibilities defined for each individual.
d. The Contracting Authority shall retain all rights to prevent, stop and if required take
the necessary punitive action against the System Integrator regarding any forbidden
disclosure.
e. The System Integrator shall ensure that all its employees, agents and sub-
contractors execute individual non-disclosure agreements, which have been duly
approved by the Contracting Authority, with respect to this Project.
f. The aforesaid provisions shall not apply to the information:
i. Already in the public domain; and
ii. Disclosed to the public due to a court order or under the Right to Information
Act; and
iii. Information required to be furnished to the Parliament and/or its
Committees
g. The System Integrator recognizes that during the term of this Agreement and the
SLA, sensitive data will be procured and made available to it, its Sub contractors and
agents and others working for or under the System Integrator. Disclosure or usage of
the data by any such recipient may constitute a breach of applicable laws causing
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 49 of 107
harm to the concerned citizens. The function of the Contracting Authority requires
the System Integrator, its Subcontractors and agents to demonstrate utmost care,
sensitivity and strict confidentiality. Any breach of this Article will result in the
Contracting Authority and its nominees receiving a right to seek injunctive relief and
damages without any limit, from the System Integrator and/or also seek
termination.
h. Each Party agrees as to any Confidential Information disclosed by a Party to this
Agreement or the SLA (the "Discloser") to the other Party to this Agreement or the
SLA (the "Recipient"):
i. To take such steps necessary to protect the Discloser's Confidential
Information from unauthorized use, reproduction and disclosure as the
Recipient takes in relation to its own Confidential Information of the same
type, but in no event less than reasonable care; and
ii. To use such Confidential Information only for the purposes of this Agreement
or the SLA or as otherwise expressly permitted or expressly required by this
Agreement or
iii. The SLA or as otherwise permitted by the Discloser in writing; and
iv. Not, without the Discloser's prior written consent, to copy the Confidential
Information or cause or allow it to be copied, directly or indirectly, in whole
or in part, except as otherwise expressly provided in this Agreement or the
SLA, or as required in connection with Recipient's use as permitted under this
Article, or as needed for the purposes of this Agreement or the SLA, provided
that any proprietary legends and notices (whether of the Discloser or of a
Third Party) are not removed or obscured; and not, without the Discloser's
prior written consent, to disclose, transfer, publish or communicate the
Confidential Information in any manner to any person except as permitted
under this Agreement or the SLA.
i. The restrictions of this Article shall not apply to Confidential Information that:
i. Is or becomes generally available to the public through no breach of this
Article by the Recipient; and
ii. Was in the Recipient's possession free of any obligation of confidence prior
to the time of receipt of it by the Recipient hereunder; and
iii. Is developed by the Recipient independently of any of Discloser's
Confidential Information; and
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 50 of 107
iv. Is rightfully obtained by the Recipient from third parties authorized at that
time to make such disclosure without restriction; and
v. Is identified in writing by the Discloser as no longer proprietary or
confidential; or
vi. Is required to be disclosed by law, regulation or Court Order or under the
Right to Information Act 2005, or to be furnished to the Parliament and/or its
Committees, provided that the Recipient gives prompt written notice to the
Discloser of such legal and regulatory requirement to disclose so as to allow
the Discloser reasonable opportunity to contest such disclosure.
j. To the extent that such disclosure is required for the purposes of this Agreement or
the SLA, either Party may disclose Confidential Information to:
i. Its employees, agents and independent contractors and to any of its affiliates
and their respective independent contractors or employees but all of them
should in turn be bound to maintain the confidentiality referred to herein on
their part; and
ii. Its professional advisors and auditors, who require access for the purposes of
this Agreement or the SLA, whom the relevant Party has informed of its
obligations under this Article and in respect of whom the relevant Party has
used commercially reasonable efforts to ensure that they are contractually
obliged to keep such Confidential Information confidential on terms
substantially the same as set forth in this Article. Either Party may also
disclose Confidential Information to any entity with the other Party's prior
written consent.
k. The provisions of this Article shall survive the expiration or any earlier termination of
this Agreement.
l. Confidential Information shall be and remain the property of the Discloser and
nothing in this Article shall be construed to grant either Party any right or license
with respect to the other Party's Confidential Information otherwise than as is
expressly set out in this Agreement.
m. Subject as otherwise expressly provided in this Agreement all Confidential
Information in tangible or electronic form under the control of the Recipient shall
either be destroyed, erased or returned to the Discloser promptly upon the earlier
of: (i) the written request of the Discloser, or, (ii) termination or expiry of this
Agreement or, in respect of the SLA, the termination or expiry of the SLA.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 51 of 107
Notwithstanding the forgoing, both Parties may retain, subject to the terms of this
Article, a reasonable number of copies of the other Party's Confidential Information
solely for confirmation of compliance with the confidentiality obligations of this
Agreement.
n. Neither Party is restricted by the provisions of Article 8.1 from using (including using
to provide products or perform services on behalf of third parties) any ideas,
concepts, knowhow and techniques that are related to the Recipient's business
activities and which are retained in unaided memories of the Recipient's employees
or agents (and not intentionally memorized for the purpose of later recording or
use) (collectively, the "Residuals"). This Article shall not permit the disclosure or use
by either Party of any financial (including business plans), statistical, product,
personnel or customer data of the other Party. Each Party agrees not to disclose the
source of the Residuals.
o. Both Parties agree that monetary damages would not be a sufficient remedy for any
breach of this Article by the other Party and that the Contracting Authority and
System Integrator, as appropriate, shall be entitled to equitable relief, including
injunction and specific performance as a remedy for any such breach. Such remedies
shall not be deemed to be the exclusive remedies for a breach by a Party of this
Article, but shall be in addition to all other remedies available at law or equity to the
damaged Party.
p. In connection with the Services, System Integrator may from time to time undertake
one or more quality assessment reviews for the purpose of improving the Project. In
order for such reviews to be frank and candid, for the greatest benefit to Contracting
Authority and System Integrator, they shall be kept confidential to the greatest
extent possible. The Parties agree that any documentation created in connection
with such quality assessment reviews shall be Confidential Information of System
Integrator which is licensed to Contracting Authority for any internal use except that
in no event shall such documentation or the results of such reviews be discoverable
or admissible (or used for any purpose) in any arbitration or legal proceedings
against System Integrator related to this Agreement or the Services.
8.2 PERSONNEL
a. Personnel assigned by System Integrator to perform the Services shall be employees
of System Integrator and under no circumstances will such personnel be considered
employees of the Project. System Integrator shall have the sole responsibility for
supervision and control of its personnel and for payment of such personnel's entire
compensation, including salary, withholding of income taxes and social security
taxes (insurance), worker's compensation, employee and disability benefits and the
like and shall be responsible for all employer obligations under all applicable laws.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 52 of 107
b. System Integrator shall use its best efforts to ensure that sufficient System
Integrator personnel are employed to perform the Services, and also that such
personnel have appropriate qualifications to perform the Services. The Contracting
Authority shall have the right to require the removal or replacement of any System
Integrator personnel performing work under this Agreement. In the event that the
Contracting Authority requests that any System Integrator personnel be replaced,
the substitution of such personnel shall be accomplished pursuant to a mutually
agreed upon schedule but not later than 3 working days.
c. The System Integrator shall also be responsible to train certain employees of the
Project with regard to the Services being provided by the System Integrator as and
when required by the Project during the Term of this Project. The parameters of the
training required for these employees of Project shall be communicated by the
Contracting Authority to the System Integrator periodically and shall be in
accordance with the latest procedures and processes available in the relevant areas
of work.
d. In the event the Contracting Authority identifies any personnel of System Integrator
as "Key Personnel", then the System Integrator shall not remove such personnel
without the prior written consent of the Contracting Authority under the applicable
terms of this Agreement and/or SLA.
e. Except as stated in this Article, nothing in this Agreement or the SLA will limit the
ability of System Integrator to assign or reassign its employees; provided that
System Integrator shall be responsible, at its expense, for transferring all appropriate
knowledge from personnel being replaced to their replacements. The Contracting
Authority shall have the right to review and approve System Integrator's plan for any
such knowledge transfer. System Integrator shall maintain the same standards for
skills and professionalism among replacement personnel as in personnel being
replaced.
f. Each Party shall be responsible for the performance of all its obligations under this
Agreement or the SLA and shall be liable for the acts and omissions of its employees
and agents in connection therewith.
8.3 SUB-CONTRACTORS
i. System Integrator shall not subcontract any work related to the scope of work of
the implementation and maintenance of the Project to be performed under this
Agreement without the Contracting Authority’s prior written consent.
ii. At any point, subcontracting by System Integrator and/or its consortium
members shall not be entertained for any of the core activities of the project
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 53 of 107
proposed in the RFP.
iii. It is clarified that the System Integrator shall be the responsible for all claims
arising from the liabilities statutory or otherwise, concerning the sub-
contractors. The System Integrator undertakes to indemnify the Contracting
Authority or its nominated agencies from any claims on the grounds stated
hereinabove.
8.4 RESPONSIBILITY OF CONSORTIUM (Not applicable)
8.5 ASSIGNMENT
All terms and provisions of this Agreement shall be binding on and shall ensure to the
benefit of Contracting Authority and System Integrator and any assignment or transfer
of this Agreement or the SLA or any rights hereunder by either Party shall be strictly
prohibited.
8.6 TRADEMARKS, PUBLICITY
Neither Party may use the trademarks of the other Party without the prior written
consent of the other Party. Except as required by law or the rules and regulations of
each stock exchange upon which the securities of one of the Parties is listed, neither
Party shall publish or permit to be published either alone or in conjunction with any
other person any press release, information, article, photograph, illustration or any
other material of whatever kind relating to this Agreement, the SLA or the business of
the Parties without prior reference to and approval in writing from the other Party, such
approval not to be unreasonably withheld or delayed. Provided however that System
Integrator may include Contracting Authority lists for reference to third parties subject
to the prior written consent of Contracting Authority not to be unreasonably withheld
or delayed. Such approval shall apply to each specific case and relate only to that case.
8.7 NOTICES
a. Any notice or other document, which may be given by either Party under this
Agreement or under the SLA, shall be given in writing in person or by pre-paid
recorded delivery post or by facsimile transmission.
b. In relation to a notice given under this Agreement, any such notice or other
document shall be addressed to the other Party's principal or registered office
address as set out below:
Contracting Authority
Address: ……………….
Tel: ………………………
Fax: ………………………
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 54 of 107
Email: …………………….
System Integrator:
Address: ……………….
Tel: ………………………
Fax: ………………………
Email: ………………………
c. Both the parties agree to inform each other, any changes to the address mentioned
above within 7 days of such change.
d. Any notice or other document shall be deemed to have been given to the other
Party (or, if relevant, its relevant associated company) when delivered (if delivered
in person) if delivered between the hours of 10.00 am and 5.00 pm on a working day
at the address of the other Party set forth above or through email or if sent by fax,
provided the copy fax is accompanied by a confirmation of transmission, or on the
next working day thereafter if delivered outside such hours, and 7 days from the
date of posting (if by letter).
e. Either Party to this Agreement or to the SLA may change its address, telephone
number, facsimile number and nominated email for notification purposes by giving
the other reasonable prior written notice of the new information and its effective
date.
8.8 VARIATIONS AND FURTHER ASSURANCE
a. No amendment, variation or other change to this Agreement or the SLA shall be
valid unless authorized in accordance with the change control procedure as set out
in the Change Control Schedule and made in writing and signed by the duly
authorized representatives of the Parties to this Agreement or the SLA.
b. Each Party to this Agreement or the SLA agrees to enter into or execute, without
limitation, whatever other agreement, document, consent and waiver and to do all
other things which shall or may be reasonably required to complete and deliver the
obligations set out in this Agreement or the SLA.
8.9 SEVERABILITY AND WAIVER
a. If any provision of this Agreement or the SLA, or any part thereof, shall be found by
any court or administrative body of competent jurisdiction to be illegal, invalid or
unenforceable the illegality, invalidity or unenforceability of such provision or part
provision shall not affect the other provisions of this Agreement or the SLA or the
remainder of the provisions in question which shall remain in full force and effect.
The relevant Parties shall negotiate in good faith in order to agree to substitute for
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 55 of 107
any illegal, invalid or unenforceable provision a valid and enforceable provision
which achieves to the greatest extent possible the economic, legal and commercial
objectives of the illegal, invalid or unenforceable provision or part provision.
b. No failure to exercise or enforce and no delay in exercising or enforcing on the part
of either Party to this Agreement or the SLA of any right, remedy or provision of this
Agreement or the SLA shall operate as a waiver of such right, remedy or provision in
any future application nor shall any single or partial exercise or enforcement of any
right, remedy or provision preclude any other or further exercise or enforcement of
such right, remedy or provision or the exercise or enforcement of any other right,
remedy or provision.
8.10 COMPLIANCE WITH LAWS AND REGULATIONS
Each Party to this Agreement and the SLA accepts that its individual conduct shall (to the
extent applicable to it) at all times comply with all applicable laws, rules and regulations.
For the avoidance of doubt, the obligations of the Parties to this Agreement and the SLA
are subject to their respective compliance with all applicable laws and regulations.
8.11 ETHICS
System Integrator represents, warrants and covenants that it has given no
commitments, payments, gifts, kickbacks, lavish or expensive entertainment, or other
things of value to any employee or agent of Contracting Authority, or its nominated
agencies in connection with this agreement and acknowledges that the giving of any
such payment, gifts, entertainment, or other things of value is strictly in violation of
Contracting Authority standard policies and may result in cancellation of this
Agreement, and the SLA.
8.12 ENTIRE AGREEMENT
This Agreement, and the SLA, all schedules appended thereto and the contents and
specifications of all the Volumes of the RFP constitute the entire agreement between
the Parties with respect to their subject matter, and as to all other representations,
understandings or agreements which are not fully expressed herein.
8.13 SURVIVABILITY
The termination or expiry of this Agreement or the SLA for any reason shall not affect or
prejudice any terms of this Agreement, or the rights of the Parties under them which are
either expressly or by implication intended to come into effect or continue in effect
after such expiry or termination.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 56 of 107
9 ARTICLE IX - DISPUTES AND AMENDMENTS
9.1 DISPUTE RESOLUTION
Any dispute arising out of or in connection with this Agreement or the SLA shall in the
first instance be dealt with in accordance with the escalation procedure as set out in the
Governance Schedule (Schedule IV of this Agreement).
Any dispute or difference whatsoever arising between the parties to this Agreement out
of or relating to the construction, meaning, scope, operation or effect of this Agreement
or the validity of the breach thereof, which cannot be resolved through the application
of the provisions of the Governance Schedule, shall be dealt in accordance with the
provisions set forth herein.
a. Scope of Dispute Resolution
Except where otherwise provided in the agreement, all questions and disputes relating
to the meaning of the specifications, design, drawings and instructions here-in before
mentioned and as to the quality of workmanship or materials used on the work or as to
any other question, claim, right, matter or thing whatsoever in any way arising out of or
relating to the agreement, designs, drawings, specifications, estimates, instructions,
orders or these conditions or otherwise concerning the services and deliverables or the
execution or failure to execute the same whether arising during the progress of the
Project or after the cancellation, termination, completion or abandonment thereof shall
be dealt with as mentioned hereinafter:
b. Dispute Resolution Board
If any dispute arises between Contracting Authority and the System Integrator in
connection with, or arising out of, the agreement or the execution of the Project,
whether during the execution of the Project or after its completion and whether before
or after the repudiation or other termination of the agreement, including any
disagreement by either party with any action, inaction, opinion, instruction,
determination, certificate or valuation, the matter in dispute shall, in the first place, be
deferred to the Dispute Resolution Board here in after called “the Board.”
For purposes of this agreement, the Governance Structure referred to under section
3.1/Schedule IV of Volume II of the RFP, shall act as the Board. The board at its
discretion may co-opt any other officer if in its opinion it may help in resolving the
dispute. Either party may refer a dispute to the Board. The board shall give a decision in
writing within 30 days of reference of dispute. Either party may refer a written decision
of the board to arbitration. If neither party refers the disputes to arbitration within 30
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 57 of 107
days of the date of such decision, the Board’s decision will be final and binding.
Contracting Authority at its discretion may change any of the members of the board
after duly informing the System Integrator within 7 days of such change.
c. Arbitration
In case, a dispute is referred to arbitration, the arbitration shall be under the Indian
Arbitration and Conciliation Act, 1996 and any statutory modification or re-enactment
thereof. Such disputes shall be referred to an Arbitral Tribunal consisting of 3 (three)
arbitrators, one each to be appointed by Contracting Authority and the System
Integrator, the third arbitrator shall be chosen by the two arbitrators so appointed by
the parties and shall act as Presiding Arbitrator. In case of failure of the two arbitrators,
appointed by the parties to reach a consensus regarding the appointment of the third
arbitrator within a period of 30 days from the date of appointment of the two
arbitrators, the Presiding Arbitrator shall be appointed by the Chief Secretary,
Government of Andhra Pradesh.
Arbitration proceedings shall be held in High Court of Judicature at Hyderabad for the
States of Telangana and Andhra Pradesh or the High Court which may be established in
the State of Andhra Pradesh and the language of the arbitration proceedings and that of
all documents and communications between the parties shall be English.
The decision of the majority of arbitrators shall be final and binding upon both parties.
The expenses of the arbitrators as determined by the arbitrators shall be shared
equally by Contracting Authority and the System Integrator. However, the expenses
incurred by each party in connection with the preparation, presentation shall be borne
by the party itself. All arbitration awards shall be in writing and shall state the reasons
for the award.
9.2 AMENDMENT
The Parties acknowledge and agree that amendments to this agreement shall be made
through mutual agreement between the parties in writing in accordance with the
procedure this Agreement is executed and signed.
IN WITNESS WHEREOF the Parties have by duly authorized representatives set their
respective hands and seal on the date first above written in the presence of:
MD, APTS [SYSTEM INTEGRATOR]
Signed Signed
For and on behalf of the For and on behalf of the
Government of Andhra Pradesh _______ (Company name) _______
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 58 of 107
By: ____ (signature) ______ By: ____ (signature) ______
___ (Name and designation) ____ _____ (Name and designation) ___
An authorized signatory duly nominated
pursuant to Board Resolution No._______
dated_______ of the [ System Integrator]
WITNESSES:
(Name, Designation, Organization,
and Signature)
(Name, Designation, Organization, and
Signature)
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 59 of 107
10 SCHEDULE I – CHANGE CONTROL SCHEDULE (Not applicable)
10.1 PURPOSE
This Schedule applies to and describes the procedure to be followed in the event of any
proposed change to the Master Services Agreement (“MSA”) and/or Service Level
Agreement (SLA), Project Operation and Management SLA. Such change shall include,
but shall not be limited to, changes in the scope of services provided by the System
Integrator and changes to the terms of payment as stated in the Terms of Payment
Schedule (Schedule VI of this Agreement).
The Contracting Authority and the System Integrator recognize that frequent change is
an inevitable part of delivering services and that a significant element of this change can
be accomplished by re-organizing processes and responsibilities without a material
effect on the cost. The System Integrator will endeavour, wherever reasonably
practicable, to effect change without an increase in the terms of payment as stated in
the Terms of Payment Schedule and the Contracting Authority will work with the System
Integrator to ensure that all changes are discussed and managed in a constructive
manner.
10.2 CHANGE CONTROL NOTE ("CCN")
a. Change requests in respect of the MSA, and/or SLA will emanate from the Parties'
respective Project Manager who will be responsible for obtaining approval for the
change and who will act as its sponsor throughout the Change Control Process and
will complete CCN attached as provided in this section. CCNs will be presented to
the other Party's Project Manager who will acknowledge receipt by signature of the
CCN.
b. The System Integrator and the Contracting Authority, while preparing the CCN, shall
consider the change in the context of the following parameter, namely whether the
change is beyond the scope of Services including ancillary and concomitant services
required and as detailed in the RFP and is suggested and applicable only after the
testing, commissioning and certification of the Pilot and project go-live as set out in
this Agreement.
c. It is hereby also clarified that the payment for the changes brought in after project
certification and ‘Go Live’ date will be calculated on the basis of man-month rate
quoted by the System Integrator in its bid and estimated man-month effort to be
submitted by the System Integrator as part of the change of control event.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 60 of 107
Change Control Note CCN Number:
Part A: Initiation
Title:
Originator:
Sponsor:
Date of Initiation:
Details of Proposed Change
(To include reasons for change and appropriate details/specifications. Identify any
attachments as A1, A2, and A3 etc.) Change should include various types such as functional
changes, Technical changes, Technology upgradations, Infrastructure change, training,
additional man power and other forms as mentioned in the RFP
Authorized by:
Contracting Authority Date:
Name:
Signature:
Received by the Date:
System Integrator
Name:
Signature:
Change Control Note CCN Number:
Part B : Evaluation
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 61 of 107
(Identify any attachments as B1, B2, and B3 etc.)
Changes to Services, charging structure, payment profile, documentation, training, service
levels and component working arrangements and any other contractual issue.
Brief Description of Solution:
Impact:
Deliverables:
Timetable:
Charges for Implementation:
(including a schedule of payments)
Other Relevant Information:
(including value-added and acceptance criteria)
Authorized by the Date:
System Integrator
Name:
Signature:
Change Control Note CCN Number :
Part C : Authority to Proceed
Implementation of this CCN as
submitted in Part A, in accordance with
Part B is: (tick as appropriate)
Approved
Rejected
Requires Further Information (as
follows, or as Attachment 1 etc.)
For Contracting Authority and its nominated
agencies For the System Integrator
Signature Signature
Name Name
Title Title
Date Date
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 62 of 107
10.3 QUOTATION
a. The System Integrator shall assess the CCN and complete all relevant part of the
CCN. In completing CCN the System Integrator or Contracting Authority shall provide
as a minimum:
i. A description of the change;
ii. A list of deliverables required for implementing the change;
iii. A timetable for implementation;
iv. An estimate of any proposed change;
v. Any relevant acceptance criteria;
vi. An assessment of the value of the proposed change;
vii. Material evidence to prove that the proposed change is not already covered
within the scope of the project, SLA, or MSA as applicable.
b. Prior to submission of the completed CCN to the Contracting Authority, or its
nominated agencies, the System Integrator will undertake its own internal review of
the proposal and obtain all necessary internal approvals. As a part of this internal
review process, the System Integrator shall consider the materiality of the proposed
change in the context of the MSA, the Project Implementation, Operation and
Management SLA affected by the change and the total effect that may arise from
implementation of the change.
c. Materiality criteria will be established by the Contracting Authority and the System
Integrator's Project Manager. Changes requiring no escalation of authority can be
implemented. Discussion and agreement as to materiality will be held in accordance
with the Governance Schedule (Schedule IV of this Agreement).
10.4 COSTS
Each Party shall be responsible for its own costs incurred in the quotation, preparation
of CCNs and in the completion of its obligations described in this process provided each
party meets the obligations as set in the CCN.
10.5 REPORTING
Change requests and CCNs will be reported monthly to each Party's Project Managers
who will prioritize and review progress.
10.6 OBLIGATIONS
The System Integrator shall be obliged to implement any proposed changes once
approval in accordance with above provisions has been given, with effect from the date
agreed for implementation and within an agreed timeframe.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 63 of 107
10.7 COST OF CHANGE REQUEST
The cost of change requests beyond the scope defined in the RFP shall not be more than
20% of the contract value either individually or cumulatively for the entire contract
period.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 64 of 107
11 SCHEDULE II – EXIT MANAGEMENT SCHEDULE
11.1 PURPOSE
a. This Schedule sets out the provisions, which will apply on expiry or termination of
the MSA, the Project Implementation, Operation and Management SLA.
b. In the case of termination of the Project Implementation and/or Operation and
Management SLA due to illegality, the Parties shall agree at that time whether, and
if so during what period, the provisions of this Schedule shall apply.
c. The Parties shall ensure that their respective associated entities carry out their
respective obligations set out in this Exit Management Schedule.
11.2 TRANSFER OF ASSETS
a. The Contracting Authority shall be entitled to serve notice in writing on the System
Integrator at any time during the exit management period as detailed hereinabove
requiring the System Integrator and/or its sub-contractors to provide the
Contracting Authority with a complete and up to date list of the Assets within 30
days of such notice. The Contracting Authority or its nominated agencies shall then
be entitled to serve notice in writing on the System Integrator at any time prior to
the date that is 30 days prior to the end of the exit management period requiring
the System Integrator to sell any of the Assets to be transferred to the Project at
book value as determined as of the date of such notice in accordance with the
provisions of relevant laws.
b. In case of contract being terminated by the Contracting Authority, Contracting
Authority reserves the right to ask the System Integrator to continue running the
project operations for a period of 6 months after termination orders are issued and
all the matters associated with such requests shall be dealt as per article V of this
MSA.
c. Upon service of a notice under this Article the following provisions shall apply:
(i) In the event, if the Assets to be transferred are mortgaged to any financial
institutions by the System Integrator, the System Integrator shall ensure that all
such liens and liabilities have been cleared beyond doubt, prior to such transfer.
All documents regarding the discharge of such lien and liabilities shall be
furnished to the Contracting Authority.
(ii) All risk in and title to the Assets to be transferred / to be purchased by the
Contracting Authority pursuant to this Article shall be transferred to the Project,
on the last day of the exit management period.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 65 of 107
(iii) Contracting Authority shall pay to the System Integrator on the last day of the
exit management period such sum representing the Net Block (procurement
price less depreciation as per provisions of Companies Act) of the Assets to be
transferred as stated in the Terms of Payment Schedule if any.
(iv) Payment to the outgoing System Integrator shall be made to the tune of last set
of completed transactions, subject to SLA requirements and for any Capex
component that has been accepted by the Contracting Authority but is pending
for payment.
(v) Contracting Authority shall have the rights to buy back the assets owned by the
System Integrator, which are not to be transferred to the Contracting Authority
as part of this contract at a prevailing depreciated value of the asset. In such
transfers, System Integrator shall pass on all the warranties and other
associated rights to the Contracting Authority.
(vi) The outgoing System Integrator will pass on the assets in working condition,
cure from all defects if any on the data of handing over to the Contracting
Authority and/or to any agency identified by the Contracting Authority, free
from all obligations
1. Upon completion of the contract period or upon termination of the agreement
for any reasons, the System Integrator shall comply with the following:
a. Notify to the Contracting agency forthwith the particulars of all Project
Assets.
b. Deliver forthwith actual or constructive possession of the Project free and
clear of all Encumbrances and execute such deeds, writings and documents
as may be required by the Contract Authority for fully and effectively
divesting the SP of all of the rights, title and interest of the SP in the Project
and conveying the Project.
c. Comply with the Divestment Requirements set out except in case if
Termination of this Agreement is due to Contracting Authority Event of
Default. In case of Termination due to Contacting Authority Event of Default,
the SP shall have implemented the maintenance schedule as well as any
repairs pointed out by the Independent Consultant in its Operations &
Maintenance Inspection Report prior to date of Termination Notice. In case
of Termination due to Force Majeure Event, the Divestment Requirements
shall be agreed between Contacting Authority and the Operator.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 66 of 107
d. Pay all transfer costs and stamp duty applicable on hand back of project
assets except in case the Project is being transferred due to Contacting
authority event of default or expiry of contract period, where Contacting
Authority shall be responsible for transfer costs and stamp duty, if any. For
clarification of doubt, transfer costs in this Clause relate to taxes and duties
applicable at transfer of SP, if any.
2. Subject to clause 11.2a of exit management, upon completion of the contract
period or upon termination of the agreement, the System Integrator shall
comply and conform to the following Divestment Requirements in respect of the
System Integrator:
a. All Project Assets including the hardware, software, documentation and any
other infrastructure shall have been renewed and cured of all defects and
deficiencies as necessary so that the System Integrator is compliant with the
Specifications and Standards set forth in the RFP, Agreement and any other
amendments made during the contract period.
b. The System Integrator delivers relevant records and reports pertaining to the
SP and its design, engineering, operation, and maintenance including all
operation and maintenance records and manuals pertaining thereto and
complete as on the Divestment Date.
c. The System Integrator executes such deeds of conveyance, documents and
other writings as the Contacting authority may reasonably require to convey,
divest and assign all the rights, title and interest of the System Integrator in
the System Integrator free from all Encumbrances absolutely and free of any
charge or tax unto the Contacting authority or its Nominee.
d. The System Integrator complies with all other requirements as may be
prescribed under Applicable Laws to complete the divestment and
assignment of all the rights, title and interest of the System Integrator in the
System Integrator free from all Encumbrances absolutely and free of any
charge or tax to Contacting authority or its nominee.
3. Not earlier than 3 (three) months before the expiry of the contract Period but
not later than 30 (thirty) days before such expiry, or in the event of earlier
Termination of the contract, immediately upon but not later than 15 (fifteen)
days from the date of issue of Termination Notice, the Independent Consultant
as nominated by the Contacting authority or its nominated agencies shall verify,
in the presence of a representative of the System Integrator, compliance by the
System Integrator with the Divestment Requirements set forth in relation to the
System Integrator’s and, if required, cause appropriate tests to be carried out at
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 67 of 107
the System Integrator’s cost for determining the compliance therewith. If any
shortcomings in the Divestment Requirements are found by either Party, it shall
notify the other of the same and the System Integrator shall rectify the same at
its cost.
Upon the SP conforming to all Divestment Requirements and handing over actual or
constructive possession of the SP to Contacting authority or a person nominated by
Contacting authority in this regard, Contacting authority shall issue a certificate
substantially, which will have the effect of constituting evidence of divestment of all
rights, title and lien in the SP by the SP and their vesting in SP pursuant hereto. Issue of
such certificate shall not be unreasonably withheld by Contacting authority. The
divestment of all rights, title and lien in the SP shall be deemed to be complete on the
date when all the Divestment Requirements have been fulfilled or the Certificate has
been issued, whichever is earlier, it being expressly agreed that any defect or deficiency
in any Divestment Requirement shall not in any manner be construed or interpreted as
restricting the exercise of any rights by State Government or its nominee on or in
respect of the SP on the footing as if all Divestment Requirements have been complied
with by the Concessionaire.
11.3 COOPERATION AND PROVISION OF INFORMATION
During the exit management period:
a. The System Integrator will allow the Contracting Authority access to information
reasonably required to define the then current mode of operation associated with
the provision of the services to enable the Contracting Authority to assess the
existing services being delivered;
b. Promptly on reasonable request by the Contracting Authority, the System Integrator
shall provide access to and copies of all information held or controlled by them
which they have prepared or maintained in accordance with the MSA, and/or SLA
relating to any material aspect of the services (whether provided by the System
Integrator or consortium members or other agencies). The Contracting Authority
shall be entitled to copy all such information. Such information shall include details
pertaining to the services rendered and other performance data. The System
Integrator shall permit the Contracting Authority or its nominated agencies and/or
any Replacement System Integrator to have reasonable access to its employees and
facilities as reasonably required by the Contracting Authority to understand the
methods of delivery of the services employed by the System Integrator and to assist
appropriate knowledge transfer.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 68 of 107
11.4 CONFIDENTIAL INFORMATION, SECURITY AND DATA
a. The System Integrator will promptly on the commencement of the exit management
period supply to the Contracting Authority the following:
(i) Information relating to the current services rendered and customer satisfaction
surveys and performance data relating to the performance of sub-contractors
in relation to the services;
(ii) Documentation relating to project’s intellectual property rights;
(iii) Project data and confidential information;
(iv) Documentation relating to sub-contractors;
(v) All current and updated project data as is reasonably required for purposes of
the project or its nominated agencies transitioning the services to its
Replacement System Integrator in a readily available format specified by the
Contracting Authority;
(vi) All other information (including but not limited to documents, records and
agreements) relating to the services reasonably necessary to enable the
Contracting Authority or its nominated agencies, or its Replacement System
Integrator to carry out due diligence in order to transition the provision of the
Services to the Contracting Authority S or its nominated agencies, or its
Replacement System Integrator (as the case may be).
b. Before the expiry of the exit management period, the System Integrator shall deliver
to the Contracting Authority all new or up-dated materials from the categories set
out in Article above and shall not retain any copies thereof.
c. Before the expiry of the exit management period, unless otherwise provided under
the MSA, the Contracting Authority shall deliver to the System Integrator all forms of
System Integrator confidential information, which is in the possession or control of
the Project or its users.
11.5 EMPLOYEES
a. Promptly on reasonable request at any time during the exit management period, the
System Integrator shall, subject to applicable laws, restraints and regulations
(including in particular those relating to privacy) provide to the Contracting
Authority a list of all employees (with job titles) of the System Integrator dedicated
to providing the services at the commencement of the exit management period;
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 69 of 107
b. To the extent that any Transfer Regulation does not apply to any employee of the
System Integrator, the Project, or its Replacement System Integrator may make an
offer of employment or contract for services to such employee of the System
Integrator and the System Integrator shall not enforce or impose any contractual
provision that would prevent any such employee from being hired by the
Contracting Authority or any Replacement System Integrator.
c. The APTS/ ITE&C Department or Replacement of System Integrator designated by it
shall retain the right for hiring a minimum of 5 key personnel of the outgoing System
Integrator spearheading the project, as identified by APTS/ITE&C Department, so as
to provide for continuity. SP is hence required to incorporate suitable provisions/
conditions in the appointment orders issued to its personnel, including a service
bond to this effect.
11.6 TRANSFER OF CERTAIN AGREEMENTS
On request by the Contracting Authority, the System Integrator shall effect such
assignments, transfers, licenses and sub-licenses as the Contracting Authority may
require in favour of the Contracting Authority, or its Replacement System Integrator in
relation to any equipment, lease, maintenance or service provision agreement between
System Integrator and third party lessors, vendors, and which are related to the services
and reasonably necessary for the carrying out of replacement services by the Managing
Director, APTS or its Replacement System Integrator.
11.7 RIGHTS OF ACCESS TO PREMISES
a. At any time during the exit management period, where Assets are located at the
System Integrator's premises, the System Integrator will be obliged to give
reasonable rights of access to (or, in the case of Assets located on a third party's
premises, procure reasonable rights of access to) the Contracting Authority, and/or
any Replacement System Integrator in order to make an inventory of the Assets.
b. The System Integrator shall also give the Contracting Authority or its nominated
agencies, or any Replacement System Integrator right of reasonable access to the
System Integrator's premises and shall procure the Contracting Authority or its
nominated agencies and any Replacement System Integrator rights of access to
relevant third party premises during the exit management period and for such
period of time following termination or expiry of the MSA as is reasonably necessary
to migrate the services to the Contracting Authority or its nominated agencies, or a
Replacement System Integrator.
11.8 GENERAL OBLIGATIONS OF THE SYSTEM INTEGRATOR
a. The System Integrator shall provide all such information as may reasonably be
necessary to effect as seamless a handover as practicable in the circumstances to
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 70 of 107
the Contracting Authority or its nominated agencies or its Replacement System
Integrator and which the System Integrator has in its possession or control at any
time during the exit management period.
b. For the purposes of this Schedule, anything in the possession or control of any
System Integrator, associated entity, or subcontractor is deemed to be in the
possession or control of the System Integrator.
c. The System Integrator shall commit adequate resources to comply with its
obligations under this Exit Management Schedule.
11.9 EXIT MANAGEMENT PLAN
a. An Exit Management plan shall be furnished by System Integrator in writing to the
Contracting Authority or its nominated agencies within 9 months from the Effective
Date of this Agreement, which shall deal with at least the following aspects of exit
management in relation to the MSA and SLA.
(i) A detailed program of the transfer process that could be used in conjunction
with a Replacement System Integrator including details of the means to be
used to ensure continuing provision of the services throughout the transfer
process or until the cessation of the services and of the management structure
to be used during the transfer;
(ii) Plans for the communication with such of the System Integrator's staff,
suppliers, customers and any related third party as are necessary to avoid any
material detrimental impact on Project’s operations as a result of undertaking
the transfer;
(iii) (if applicable) proposed arrangements for the segregation of the System
Integrator's networks from the networks employed by the Project and
identification of specific security tasks necessary at termination;
(iv) Plans for provision of contingent support to the Project and Replacement
System Integrator for a reasonable period after transfer.
b. The System Integrator shall re-draft the Exit Management Plan annually thereafter
to ensure that it is kept relevant and up to date.
c. Each Exit Management Plan shall be presented by the System Integrator to and
approved by the APTS/ITE&C Department or its nominated agencies.
d. The terms of payment as stated in the Terms of Payment Schedule include the costs
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 71 of 107
of the System Integrator complying with its obligations under this Schedule.
e. In the event of termination or expiry of MSA and SLA, each Party shall comply with
the Exit Management Plan.
f. During the exit management period, the System Integrator shall use its best efforts
to deliver the services.
g. Payments during the Exit Management period shall be made in accordance with the
Terms of Payment Schedule VI.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 72 of 107
12 SCHEDULE III - AUDIT, ACCESS AND REPORTING SCHEDULE
12.1 PURPOSE
This Schedule details the audit, access and reporting rights and obligations of the
Contracting Authority and the System Integrator under the MSA and SLA.
12.2 AUDIT NOTICE AND TIMING
a. As soon as reasonably practicable after the Effective Date, the Parties shall use their
best endeavours to agree to a timetable for routine audits during the Project
Implementation Phase and the Operation and Management Phase. During the
Implementation Phase, the Contracting Authority and thereafter during the
Operation Management Phase, the Contracting Authority shall conduct routine
audits in accordance with such agreed timetable and shall not be required to give
the System Integrator any further notice of carrying out such audits.
b. The Contracting Authority may conduct non-timetabled audits at his/her own
discretion if he/she reasonably believes that such non-timetabled audits are
necessary as a result of an act of fraud by the System Integrator, a security violation,
or breach of confidentiality obligations by the System Integrator, provided that the
requirement for such an audit is notified in writing to the System Integrator a
reasonable period time prior to the audit (taking into account the circumstances
giving rise to the reasonable belief) stating in a reasonable level of detail the reasons
for the requirement and the alleged facts on which the requirement is based. If the
System Integrator considers that the non-timetabled audit was not appropriate, the
matter shall be referred to the escalation procedure as set out in the Governance
Schedule (Schedule IV of this Agreement).
c. The frequency of audits shall be 6 monthly excluding the performance audits which
may be necessary for the acceptance of the Pilot and Go-Live, provided always that
the Contracting Authority shall endeavour to conduct such audits with the lowest
levels of inconvenience and disturbance practicable being caused to the System
Integrator.
d. In addition to the above, there will be audits conducted by statutory bodies (e.g.
CAG) as and when they are required to do it. Notwithstanding any condition given in
the MSA, System Integrator will have to provide these statutory bodies access to all
the facilities, infrastructure, documents and artefacts of the Project as required by
them and approved by the Contracting Authority, in writing.
12.3 ACCESS
The System Integrator shall provide to the Contracting Authority reasonable access to
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 73 of 107
employees, subcontractors, suppliers, agents and third party facilities, documents,
records and systems reasonably required for audit and shall provide all such persons
with routine assistance in connection with the audits and inspections. The Contracting
Authority shall have the right to copy and retain copies of any relevant records. The
System Integrator shall make every reasonable effort to co-operate with them.
12.4 AUDIT RIGHTS
a. The Contracting Authority shall have the right to audit and inspect suppliers, agents
and third party facilities, data centres, documents, records, procedures and systems
relating to the provision of the services, but only to the extent that they relate to the
provision of the services, as shall be reasonably necessary to verify:
(i) The security, integrity and availability of all Project data processed, held or
conveyed by the System Integrator on behalf of Project and documentation
related thereto;
(ii) That the actual level of performance of the services is the same as specified in
the SLA;
(iii) That the System Integrator has complied with the relevant technical standards,
and has adequate internal controls in place; and
(iv) The compliance of the System Integrator with any other obligation under the
MSA and SLA.
b. For the avoidance of doubt the audit rights under this Schedule shall not include
access to the System Integrator's profit margins or overheads associated with any
obligation under the MSA.
12.5 AUDIT RIGHTS OF SUPPLIERS AND AGENTS
a. The System Integrator shall use reasonable endeavours to achieve the same audit
and access provisions as defined in this Schedule with suppliers and agents who
supply labour, services, equipment or materials in respect of the services. The
System Integrator shall inform the Contracting Authority prior to concluding any
sub-contract or supply agreement of any failure to achieve the same rights of audit
or access.
b. REPORTING: The System Integrator will provide quarterly reports to the Contracting
Authority regarding any specific aspects of the Project and in context of the audit
and access information as required by the Contracting Authority.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 74 of 107
12.6 ACTION AND REVIEW
a. Any change or amendment to the systems and procedures of the System Integrator,
or sub-contractors, where applicable arising from the audit report shall be agreed
within thirty (30) calendar days from the submission of the said report.
b. Any discrepancies identified by any audit pursuant to this Schedule shall be
immediately notified to the Contracting Authority or the appropriate Project
Manager and the System Integrator Project Manager who shall determine what
action should be taken in respect of such discrepancies in accordance with the terms
of the MSA.
12.7 TERMS OF PAYMENT FOR COST OF AUDIT
The Contracting Authority shall bear costs of any audits. The System Integrator shall
coordinate and extend their cooperation for smooth conduct of the audit etc.
12.8 RECORDS AND INFORMATION
For the purposes of audit in accordance with this Schedule, the System Integrator shall
maintain true and accurate records in connection with the provision of the services and
the System Integrator shall handover all the relevant records and documents upon the
termination or expiry of the MSA.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 75 of 107
13 SCHEDULE IV – INDICATIVE GOVERNANCE SCHEDULE
13.1 PURPOSE
The purpose of this Schedule is to (i) establish and maintain the formal and informal
processes for managing the relationship between the Contracting Authority and the
System Integrator (including the outputs from other Schedules to this Agreement; (ii)
define the principles that both Parties wish to follow to ensure the delivery of the
Services; (iii) ensure the continued alignment of the interests of the Parties; (iv) ensure
that the relationship is maintained at the correct level within each Party; (v) create the
flexibility to revise and maintain the relationship and this Agreement during the Term;
(vi) set out the procedure for escalating disagreements; and (vii) enable contract
administration and performance management.
13.2 INDICATIVE GOVERNANCE STRUCTURE
Governance structure for APeProcurement Project
The committee will be supported by
• Steering Committee for the APeProcurement Project appointed by the Government
of Andhra Pradesh.
• Implementation Committee
• Project Manager, eProcurement, ITE&C Department
• APTS
Place of Work
1. At present the Government operates from Vijayawada, Amaravati.
2. SI has to coordinate with departments from the new capital location of
Amaravati.
3. The System Integrator has to operate from his development centre and or
premises as informed by Contracting Authority or its Nominated Agencies.
4. System Integrator should set up a local office in Andhra Pradesh.
13.3 GOVERNANCE PROCEDURES
a. The System Integrator shall document the agreed structures in a procedures manual.
b. The agenda for each meeting of the Committee mentioned above as applicable shall
be set to reflect the discussion items referred to above and extraordinary items may
be added either with the agreement of the Parties or at the request of either Party.
Copies of the agenda for meetings of the Steering Committee and other Committees
as applicable and relevant, along with relevant pre-reading material, shall be
distributed at least one week in advance of the relevant meeting.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 76 of 107
c. All meetings and proceedings will be documented; such documents to be distributed
to both Parties and copies shall be kept as a record. All actions, responsibilities and
accountabilities arising out of any meeting shall be tracked and managed.
d. The Parties shall ensure as far as reasonably practicable that the Steering Committee
and PMU shall resolve the issues and resolve the objectives placed before them and
that the members representing that Party are empowered to make relevant
decisions or have easy access to empowered individuals for decisions to be made to
achieve this.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 77 of 107
14 SCHEDULE V – INVOICING AND SETTLEMENT SCHEDULE
a. In respect of its remuneration for the Services the System Integrator shall be eligible
to receive payments in accordance with the Terms of Payments Schedule (Schedule
VI of this Agreement). Subject to the completeness of the Invoice and specific terms
of each Service Level Agreement, the System Integrator submit its invoices in
accordance with the following principles:
(i) The Contracting Authority shall be invoiced by the System Integrator for the
Services. Generally and unless otherwise agreed in writing between the
Parties or expressly set out in the Service Level Agreement, the System
Integrator shall raise an invoice as per the terms of payment as stated in this
Schedule.
(ii) Any invoice presented in accordance with this Article shall be in a form
agreed with the Contracting Authority.
(iii) The completeness of the Invoice shall mean the submission of the Invoice
along with the acceptance certificate of the respective deliverables of the
milestones and other associated dependencies to process and approve the
invoice.
(iv) Invoice should have the taxes at actual at the prevailing rates at the time of
submission of invoice.
b. Invoices shall be accurate and all adjustments to or changes in the terms of payment
as stated in the Terms of Payment Schedule shall be applied to the next payment
invoice. The System Integrator shall waive any charge for a Service that is not
invoiced within six months after the end of the month in which the terms of
payment as stated in the Terms of Payment Schedule relating to such Service are
authorized or incurred, whichever is later.
c. Payments shall be made within (60) days of the receipt of invoice by the Contracting
Authority, subject to adjustments if any for the previous performance.
d. The Contracting Authority shall be entitled to delay or withhold payment of any
invoice or part of it delivered by the System Integrator under this Schedule where
the Contracting Authority disputes such invoice or part of it provided that such
dispute is bona fide. The withheld amount shall be limited to that which is in
dispute. The disputed amount shall be settled in accordance with the escalation
procedure as set out in the Governance Schedule (Schedule IV of this Agreement).
Any exercise by the Contracting Authority under this Article shall not entitle the
System Integrator to delay or withhold provision of the Services.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 78 of 107
e. If any amount is due and payable by the System Integrator to the Contracting
Authority or Its Nominated Agencies, the same shall be either adjusted by the
System Integrator in the subsequent Invoices or Paid to the Contracting Authority in
a method as informed by the Contracting Authority or its Nominated Agencies on a
case to case basis.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 79 of 107
15 SCHEDULE VI – TERMS OF PAYMENT SCHEDULE
SNo Milestone Timeline
I PBG for the contract Value
A Signing of the contract 10 Days from the date of issue of the LOI
& signing of the contract = T0
SNo Milestone Timeline& Payment
II Takeover of Existing Applications & support
Activity description Time line Payment
A Takeover of Existing
Applications of AP
eProcurement &
Knowledge Transfer (KT)
T0 + 15 days
Payment will be made to the existing
System Integrator till the takeover & KT
completed. The same has to be confirmed
by the selected SI.
III Operation and Maintenance
A Operation and Maintenance
from the date of complete
taking over & handing over
Go-live Starts
from the date
of complete
hand-over &
taken over
process
completed &
Knowledge
Transfer (KT)
Payment shall be made in equated
quarterly instalments on completion of
each Quarter and certification by ITE&C
Department for the contract period and
submission of the invoice with required
documents/ certification.
IV Exit Management
A Exit Management,
Knowledge Transfer and
Acceptance by the
department
T0 + 36 Months Payment of Last quarter payment and
return of PBG
Total towards Exit Management Return of the PBG after deducting
penalties, if any.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 80 of 107
16 SCHEDULE VII – O&M SCHEDULE
SNo Milestone Deliverables from SI
Operations and Maintenance
1 Signing of the Contract Performance Bank Guarantee 10 % of total contract value
2 Third Party Audit a. Application Audit Compliance and Security Certification
from Third Party Agency, as per the time schedule.
b. Source code after completion of every audit.
a. Submission of MIS reports along with other artifacts
such as analytical and statistical models, custom
algorithms if any and other relevant artifact to
departments as per the requirements in terms of
monthly, quarterly, half-yearly and annual
b. Call Log & Resolution Reports for Helpdesk.
c. Daily/ Weekly/ Fort-nightly/ Monthly Performance
Monitoring Reports
d. Operational Document on Strategic Control over the
Project.
e. Quarterly Report for Operations and Maintenance
Activities carried out during the quarter.
f. Software change logs, etc.
g. Annual Certification stating all patches/ upgrades/
service releases have been properly installed
c. Other Reports as mentioned in the Scope of Work.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 81 of 107
17 SCHEDULE VIII - ROLES AND RESPONSIBILITIES
17.1 ROLES AND RESPONSIBILITIES OF ITE&C DEPARTMENT
1. Approval of budget and releasing the funds
2. Management of funds for APeProcurement Application Platform
3. Provision of the Hardware infrastructure at APSDC/ cloud infrastructure/ supply
and procurement would be responsible of the ITE&C department
4. Owning the critical assets of the Project
5. Ensuring that all the APTS/ITE&C departments and constituent organizations
take active part in the project.
6. Releasing the funds as per the recommendations of the Contracting Authority
7. Periodic project progress review with the project committees
8. Issuing directions to the PM and System Integrator as may be needed
9. Administration, Support and Maintenance of APeProcurement Platform
10. Overall implementation responsibility of the APeProcurement Platform.
11. Issue contract amendments as required based on the recommendations Project
Manager.
12. Act as the single point of contact for various reviews with the Government
13. Coordinate with the departments of the APeProcurement Platform for successful
implementation of the project.
14. Assist PM & Coordinate with the System Integrator to finalize the updated
functional requirements (FRS) of the respective APeProcurement Platform of
identified departments.
15. Assist PM & Coordinate with the System Integrator to finalize training schedules
for the employees of the respective departments who would be using
APeProcurement Platform.
16. Assist PM & Provide the system integrator all available documentation on
business processes and forms that are used by the department.
17. Participate in the UAT of the APeProcurement Platform application and provide
inputs for enhancements.
18. Monitor the performance of the System Integrator on regular intervals.
19. SLA monitoring and clearance of invoices raised by the System Integrator on
time.
20. Facilitate in getting adequate space and racks in the Data center and DR Center
to host the APeProcurement application Platform. Provision of the computing
infrastructure at APSDC or at cloud infrastructure.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 82 of 107
21. Evaluate change requests raised by the System Integrator and ensuring timely
approval on the change request effort estimations.
22. Perform validation of all the deliverables with regards to set-up, configuration,
administration, O&M, and upgrade of the Platform.
23. Appoint 3rd party agencies for security audits or any other audit through APTS.
24. Strive to get necessary government orders for higher adoption of the Platform
and on-boarding of departments.
25. Monitor the progress of the program with respect to adherence to timelines.
Evaluate the reasons for deviation from timelines and take necessary corrective
actions in concurrence with the stakeholders responsible for the same.
26. Monitor and evaluate the risks of the program, communicate the same to the
stakeholders and formulate an appropriate risk mitigation strategy.
27. Ensure timely receipt of deliverables from the System Integrator and initiate
corrective action in case of default
28. Provide approval of the deliverables in consultation with the APTS/PM wherever
necessary within 15 days from the date of receipt of the deliverables from the
System Integrator. The time lag attributed due to the delay in providing the
feedback shall not be considered while computing the Liquidated Damages.
29. Planning and executing the communication plan between the stakeholders.
30. Conduct timely reviews of the program with all the stakeholders to evaluate the
progress, form action plans, identify scope for improvement of quality and
productivity.
31. Monitor the Implementation and Operational SLAs of the System Integrator.
Calculate the penalty due to deviation from the SLA.
32. Define the change control procedure and track the same to ensure that the
program scope and timelines are not affected.
33. Receive the invoices from the System Integrator, ensure correctness of the same
and facilitate timely disbursal of payment to the System Integrator.
34. Coordinate with the APTS, System Integrator to ensure that the training and
change management programs are conducted smoothly and their objectives are
met.
35. Call for the Policy matter issues and to resolve by convening the steering
committee etc.
36. Call for Design/ Technical issues and to resolve by convening the meeting.
37. Conduct exit tests for the participants of the training programs; evaluate the
results of the same and the feedback of the participants. Recommend re-training
of the batch if the performance is poor or if the objectives of the training plan
have not been met.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 83 of 107
38. Facilitate the termination and exit management processes as per the need.
17.2 ROLES AND RESPONSIBILITIES OF APTS
1. RFP issuance, bid process management and contract preparation
2. Engaging a third party for audit of security & controls of the application &
infrastructure on behalf of ITE&C dept.
3. Selection/ engaging of security audits as per the directions of ITE&C.
4. Selection SI for O&M of APeProcurement application platform
17.3 ROLES AND RESPONSIBILITIES OF SYSTEM INTEGRATOR
1. Subject to the requirements specified in this RFP, System Integrator will be
responsible for providing:
i. Complete the scope of work detailed in the RFP.
ii. Maintenance and operations of the APeProcurement application .
iii. Infrastructure and Hardware maintenance including performance tuning.
iv. Training on the application software, training on general computer skills,
soft skills, and customer service & delivery as applicable and mentioned
in the RFP
v. Change management and communication strategy & implementation
vi. Compliance with the SLAs
vii. Raise all invoices for payment as per the agreed payment schedule and
submit the same to the Contracting Authority.
viii. Setup technical Helpdesk, grievance handling and Operate Help Desk
ix. Provide application support for the entire contract period wherever
applicable
x. Development and maintenance of the Platform as mentioned in this RFP
and to comply with all necessary standards and regulations.
xi. Responsible for day to day operation of the Platform including reporting,
issue resolution of tickets etc. pertaining to the Platform.
xii. Undertake all the tasks related to hosting, deployment and operation for
smooth functioning of Platform on cloud, if required.
xiii. Responsible for creation, documentation and publishing of APIs for
departments and external entities/ third parties, if required.
xiv. Responsible for procuring/ developing all the necessary software tools for
deployment and running of the Platform to meet the SLAs.
xv. Create support and ticket management system and provide help desk
personnel who can communicate in English.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 84 of 107
xvi. Work closely with PM, ITE&C Department to manage day to day
relationship SDC and line departments or any other entity as identified by
APTS/ ITE&C Department for operationalisation and management of the
Platform.
xvii. Responsible for getting all necessary sign offs and approvals from the
Department.
xviii. Responsible for support integration of API’s/ Payment Gateways etc.
xix. Tuning & Configuration of APeProcurement Platform, if required.
xx. Supply, installation and configuration of SLA monitoring tools
xxi. In case of a failure at DC the operations of Platform, shift to DR site
without affecting the availability of platform.
xxii.
2. System Integrator shall take over the APeProcurement application Platform
module and then operate & maintain it the contract period from the date of
signing the contract.
3. Ensure that all cases of noncompliance (if any) reported in the security audit are
closed so that approval is received and audit and timelines are not violated.
4. In case of termination/ completion of this contract, it is the responsibility of the
System Integrator to transfer the knowledge to the new System Integrator
identified by APTS/ ITE&C Department or its nominated Agency defined in the
RFP; and shall the new System Integrator be on board before 1 (one) month of
the completion of this contract.
17.4 ROLES AND RESPONSIBILITIES OF OTHER DEPARTMENTS
1. Nominate one nodal officer from each department
2. Assist PM & Coordinate with the System Integrator to finalize and update
functional requirements (FRS) of the respective departments requirement.
3. Assist PM & Coordinate with the System Integrator to finalize training schedules
for the employees of the respective departments.
4. Assist PM & Provide the System Integrator for all available documentation on
business processes and forms that are used by the department.
5. Participate in the UAT of the application and provide inputs for enhancements.
6. Assist PM in Review and approve the change requests, technical, functional
proposed by the System Integrator.
7. Ensuring that all the participating departmental divisions and constituent
organizations take active part in the project.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 85 of 107
8. Ensuring that all the legal amendments and processes are carried out where
occasioned by the re-designed processes.
9. Facilitate the communication program for popularizing the usage of
APeProcurement Application and for encouraging bidders to access various
reports developed under this portal for availing various services.
10. Appoint single point of contact to work with SI/ ITE&C Department for any
technical and non-technical assistance in carrying out O&M.
11. Identify services and finalize scope, specifications and all necessary sign off of
services for the applications on the Platform.
17.5 ROLES AND RESPONSIBILITIES OF STATE DATA CENTER
1. Provide necessary inputs and support to the System Integrator to develop web
services that help the APeProcurement Platform, interact with the existing
applications hosted on the SDC.
2. Provide necessary information on applications and services hosted on the SDC,
NIC and other data centers or clouds of private vendors with regard to nature of
interaction with the APeProcurement Platform and data exchanged with the
same.
3. Adopt security standards so that the existing applications are compliant with the
same.
4. Provide VPN and other access controls to the System Integrators.
5. SDC will provide servers, data storage, network facility, data security, operating
systems and monitoring software.
6. SDC is responsible for network and hardware availability.
7. SDC will provide all the information related to network infrastructure, internet
connectivity, power backups for smooth functioning of the Application.
8. SDC will provide necessary arrangement for periodic backup of the data,
software and other related configurations of Platform in DC and DR.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 86 of 107
SCHEDULE IX - SERVICE LEVEL AGREEMENTS (SLA)
The section outlines the key service level requirements for the project, which needs to
be ensured by the System Integrator during the operations and maintenance period.
These performance requirements shall be strictly imposed and a third party
audit/certification agency shall be deployed for certifying the performance of the
System Integrator against the target performance metrics as outlined in the table below.
The SLA monitoring shall be performed/reviewed on a monthly basis. During the
contract period, it is envisaged that there could be changes to the SLA, in terms of
addition, alteration or deletion of certain parameters, based on mutual consent of both
the parties i.e. Contracting Authority and System Integrator.
17.6 SLA DEFINITION & MEASUREMENT
The SLA specifies the expected levels of service to be provided by the SI to the various
stakeholders of the Project. Payment payable to the SI is linked to the compliance with
the SLA metrics laid down in the table provided as Annexure II to Schedule IX of the
MSA. The table also specifies the limits and metrics for lower/ higher performance and
breach levels.
The following points clarify the manner in which the SLA metrics operate:
a. A set of parameters have been identified as key to ensuring the desired
performance level of APeProcurement Application Platform.
b. The table lists out the baseline performance level, method of measurement and
how low/ high performances will be treated.
c. The SI will get full quarterly payment if the baseline performance metrics are
complied. The SI will get lesser payment in case of a lower performance on any
parameter.
17.7 SLA METRICS
The Service Level metrics that define the Service Levels, the method of measurement of
each SLA and the credits or SLA scores for the baseline, lower performance and higher
performance are specified in Annexure II of the Volume III of the RFP
17.8 SLA MONITORING
The aforementioned SLA parameters shall be measured on a daily/ weekly/ monthly/
quarterly basis as per the individual SLA parameter requirements, through appropriate
SLA Measurement tools to be designed by the SI for the purpose and audited by a 3rd
party for accuracy and reliability. If the performance of the system/services is degraded
significantly at any given point in time during the contract and if the immediate
measures are not implemented and issues are not rectified to the complete satisfaction
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 87 of 107
of Contracting Authority or an agency designated by them, then Contracting Authority
will have the right to take appropriate corrective actions including termination of the
contract. It is to be noted that if the overall penalty applicable in any quarter exceeds
10%; then Contracting Authority shall have the right to terminate the contract. The SLAs
defined in Schedule IX of the MSA, shall be reviewed on an annual basis as Contracting
Authority decides after taking the advice of the System Integrator, PM and other
stakeholders. All the changes would be made by Contracting Authority after
consultation with the System Integrator. The changes made should not result in undue
financial advantage to the System Integrator. Refer Annexure II for detailed Service
Level Agreements.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 88 of 107
18 SCHEDULE X - MANDATORY COMPLIANCES
The System Integrator shall submit undertakings w.r.t mandatory compliances and
declaration on Company Letterhead in the prescribed format listed as below:
i. Non-Disclosure Agreement (NDA)
ii. Undertaking on IPR and Patent Rights
iii. Undertaking on Non-malicious Code Certificate
iv. Undertaking on Provision for Support for Software
v. Undertaking on Service Level Compliance
vi. Undertaking on Deliverables
vii. Undertaking on Training for Users
viii. Undertaking on Support to Certification
ix. Undertaking on Exit Management and Transition
x. Undertaking on Continuous Improvement
xi. Undertaking on Personnel
18.1 Form U1: Non-Disclosure Agreement (NDA)
This AGREEMENT (hereinafter called the “Agreement”) is made on the [day] day of the
month of [month], [year], between, APTS/ITE&C Department on the one hand,
(hereinafter called the “Contracting Authority”) and, on the other hand, [Name of the
bidder] (hereinafter called the “System Integrator”) having its registered office at
[Address]
WHEREAS
The “Contracting Authority” has issued a public notice inviting various organizations to
propose for hiring services of an organization for provision of services under the
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 89 of 107
Implementation of APeProcurement Application Platform Project of APTS/ITE&C
Department of GoAP (hereinafter called the “Project”) of the Contracting Authority;
The System Integrator, having represented to the “Contracting Authority” that it is
interested to bid for the proposed Project,
The Contracting Authority and the System Integrator agree as follows:
1. In connection with the “Project”, the Contracting Authority agrees to provide to
the System Integrator a Detailed Document on the Project vide the Request for
Proposal contained in two volumes. The Request for Proposal contains details
and information of the Contracting Authority operations that are considered
confidential.
2. The System Integrator to whom this Information (Request for Proposal) is
disclosed shall:
a. Hold such Information in confidence with the same degree of care with
which the System Integrator protects its own confidential and proprietary
information;
b. Restrict disclosure of the Information solely to its employees, agents and
contractors with a need to know such Information and advice those persons
of their obligations hereunder with respect to such Information;
c. Use the Information only as needed for the purpose of bidding for the
Project;
d. Except for the purpose of bidding for the Project, not copy or otherwise
duplicate such Information or knowingly allow anyone else to copy or
otherwise duplicate such Information; and
e. Undertake to document the number of copies it makes
f. On completion of the bidding process and in case unsuccessful, promptly
return to the Contracting Authority, all Information in a tangible form or
certify to the Contracting Authority that it has destroyed such Information.
3. The System Integrator shall have no obligation to preserve the confidential or
proprietary nature of any Information which:
a. Was previously known to the System Integrator free of any obligation to
keep it confidential at the time of its disclosure as evidenced by the System
Integrator’s written records prepared prior to such disclosure; or
b. Is or becomes publicly known through no wrongful act of the System
Integrator; or
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 90 of 107
c. Is independently developed by an employee of the System Integrator not
associated with the Project and who did not have any direct or indirect
access to the Information.
4. The Agreement shall apply to all Information relating to the Project disclosed by
the Contracting Authority to the System Integrator under this Agreement.
5. The Contracting Authority will have the right to obtain an immediate injunction
enjoining any breach of this Agreement, as well as the right to pursue any and all
other rights and remedies available at law or in equity for such a breach.
6. Nothing contained in this Agreement shall be construed as granting or conferring
rights of license or otherwise, to the System Integrator, in any of the
Information. Notwithstanding the disclosure of any Information by the
Contracting Authority to the System Integrator, the Contracting Authority shall
retain title and all intellectual property and proprietary rights in the Information.
No license under any trademark, patent or copyright, or application for same
that are now or thereafter may be obtained by such party is either granted or
implied by the conveying of Information. The System Integrator shall not alter or
obliterate any trademark, trademark notice, copyright notice, confidentiality
notice or any notice of any other proprietary right of the Contracting Authority
on any copy of the Information, and shall reproduce any such mark or notice on
all copies of such Information.
7. This Agreement shall be effective from the date the last signature is affixed to
this Agreement and shall continue in perpetuity.
8. Upon written demand of the Contracting Authority, the System Integrator shall
(i) Cease using the Information,
(ii) Return the Information and all copies, notes or extracts thereof to the
Contracting Authority forthwith after receipt of notice, and
(iii) Upon request of the Contracting Authority, certify in writing that the
System Integrator has complied with the obligations set forth in this
paragraph.
9. This Agreement constitutes the entire agreement between the parties relating to
the matters discussed herein and supersedes any and all prior oral discussions
and/or written correspondence or agreements between the parties. This
Agreement may be amended or modified only with the mutual written consent
of the parties. Neither this Agreement nor any right granted hereunder shall be
assignable or otherwise transferable.
10. Confidential information is provided “as is” with all faults. In no event shall the
Contracting Authority be liable for the accuracy or completeness of the
confidential information.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 91 of 107
11. This Agreement shall benefit and be binding upon the Contracting Authority and
the System Integrator and their respective subsidiaries, affiliate, successors and
assigns.
12. Agreement shall be governed by and construed in accordance with the Indian
laws.
For and on behalf of the System Integrator
(Signature) ______
(Name of the Authorized Signatory)
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 92 of 107
18.2 Form U2: Undertaking on IPR and Patent Rights
[Company letterhead]
To, [Date]
The Managing Director,
APTS, Vijayawada.
Sub: Undertaking on IPR and Patent Rights
Sir,
1. I/We as System Integrator (SI) do hereby undertake that none of the deliverables/ source code
being provided by us is infringing on any patent or intellectual and industrial property rights as
per the applicable laws of relevant jurisdictions having requisite competence.
2. I/We also confirm that there shall be no infringement of any patent or intellectual and industrial
property rights as per the applicable laws of relevant jurisdictions having requisite competence,
in respect of the equipment’s, systems or any part thereof to be supplied by us. We shall
indemnify the Contracting Authority against all cost/ claims/ legal claims/ liabilities arising from
third party claim in this regard at any time on account of the infringement or unauthorized use of
patent or intellectual and industrial property rights of any such parties, whether such claims arise
in respect of manufacture or use. Without prejudice to the aforesaid indemnity, the SI shall be
responsible for the completion of the supplies including spares and uninterrupted use of the
equipment and/or system or any part thereof to the Contracting Authority and persons
authorized by the Contracting Authority irrespective of the fact of claims of infringement of any
or all the rights mentioned above.
3. If it is found that it does infringe on patent rights, I/We absolve the Contracting Authority of any
legal action and reserves the right to terminate the contract without any compensation to the
system Integrator
4. We, hereby solemnly affirm to the IPR and Source Code rights as defined in the RFP of the
Contract Agreement. In the event of any deviation from the factual information/ declaration, the
Contracting Authority reserves the right to terminate the Contract without any compensation to
the System Integrator.
Yours faithfully,
Authorized Signatory
Designation
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 93 of 107
18.3 Form U3: Non- Malicious Code Certificate
[Company letterhead]
To, [Date]
The Managing Director,
APTS, Vijayawada.
Sub: Non-Malicious Code Certificate
Sir,
I/We hereby certify that the software being offered/ developed as part of the contract
does not and will not contain any kind of malicious code that would activate procedures
to:
A. Inhibit the desired and the designed function of the equipment/ solution.
B. Cause damage to the user or his equipment/ solution during the operational
exploitation of the equipment/ solution.
C. Tap information regarding network, network users and information stored
on the network that is classified and/or relating to Security.
There are/will be no Trojans, Viruses, Worms, Spy wares or any malicious software on
the system and in the software offered or software that will be developed.
Without prejudice to any other rights and remedies available to the Contracting
Authority, we are liable under Information Technology Act 2000 and subsequent
amendments and Indian Penal Code, 1860 and subsequent amendments in case of
physical damage, loss of information and those relating to copyright and Intellectual
Property rights (IPRs), caused due to activation of any such malicious code in offered/
developed software.
Yours faithfully,
Authorized Signatory
Designation
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 94 of 107
18.4 Form U4: Undertaking on Provision for Software Support
[Company letterhead]
To, [Date]
The Managing Director,
APTS, Vijayawada.
Sub: Undertaking on Pricing of Items of Technical Response
Sir,
I/We do hereby undertake that Commercial Proposal submitted by us is inclusive of all
the items in the technical proposal and is inclusive of all the clarifications provided/ may
be provided by us on the technical proposal during the evaluation of the technical offer.
We understand and agree that our Commercial Proposal is firm and final and that any
clarifications sought by you and provided by us would not have any impact on the
Commercial Proposal submitted by us.
Yours faithfully,
Authorized Signatory
Designation
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 95 of 107
18.5
18.6 Form U5: Undertaking on Service Level Compliance
[Company letterhead]
To, [Date]
The Managing Director,
APTS, Vijayawada.
Sub: Undertaking on Service Level Compliance
Sir,
1. I/We as System Integrator do hereby undertake that we shall monitor, maintain,
and comply with the service levels stated in the RFP to provide quality service to
the Contracting Authority.
2. However, if the proposed number of resources is found to be not sufficient in
meeting the tender and/or the Service Level requirements given by State, then
we will augment the team without any additional cost to the Contracting
Authority.
Yours faithfully,
Authorized Signatory
Designation
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 96 of 107
18.7 Form U6: Undertaking on Deliverables
[Company letterhead]
To, [Date]
The Managing Director,
APTS, Vijayawada.
Sub: Undertaking on Deliverables
Sir,
I/We as System Integrator do hereby undertake the adherence of required Certification
or above standards to the processes, deliverables/ artefact to be submitted to the
Contracting Authority proposed as part of the Software for APeProcurement Platform
modules.
We also recognize and undertake that the Deliverables/ artefacts shall be presented and
explained to the APTS/ITE&C Department and other key stakeholders (identified by
Contracting Authority), and also take the responsibility to provided clarifications as
requested by the Contracting Authority .
We also understand that the acceptance, approval and sign-off of the deliverables by
the Contracting Authority will be done on the advice of PM. We understand that while
all efforts shall be made to accept and convey the acceptance of each deliverable in
accordance with the project schedule, no deliverable will be considered accepted until a
specific written communication to that effect is made by the Contracting Authority
Yours faithfully,
Authorized Signatory and Designation
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 97 of 107
18.8 Form U7: Undertaking on Training the Users
[Company letterhead]
[Date]
To
The Managing Director,
APTS, Vijayawada.
Sub: Undertaking on Training the Users
Sir,
1. I/We hereby undertake to train users (to be identified by the Contracting
Authority) as per APeProcurement Application Platform requirements stated in
the Request for Proposal (RFP). We further undertake that:
a. We shall carry out a comprehensive training needs analysis and
accordingly design the training program
b. Our training program would include, at the minimum, classroom training
followed by supervised work sessions
2. We shall prepare all necessary training materials and deliver the training
Yours faithfully,
Authorized Signatory & Designation
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 98 of 107
18.9 Form U9: Undertaking on Support to Certification
[Company letterhead]
To
[Date]
The Managing Director,
APTS, Vijayawada.
Sub: Undertaking on Support to Certification
Sir,
1. I/We understand that application (including the application and the associated IT
systems) have to be certified by a 3rd
party agency (to be identified by the APTS)
before the system is commissioned.
2. I/We hereby undertake that we shall do all that is required of the System
Integrator to ensure that system will meet all the conditions required for
successful certification.
Yours faithfully,
Authorized Signatory
Designation
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 99 of 107
18.10 Form U9: Undertaking on Exit Management and Transition
[Company letterhead]
To, [Date]
The Managing Director,
APTS, Vijayawada.
Sub: Undertaking on Exit Management and Transition
Sir,
1. I/We hereby undertake that at the time of completion of the engagement, we
shall successfully carry out the exit management and transition (to the
APTS/ITE&C Department or to an agency identified by the Contracting Authority)
to the Department’s satisfaction.
2. I/We further undertake to complete the following as part of the Exit
Management and Transition:
i. Capacity Building at the APTS/ITE&C Department
a. We undertake to design team/organization structure at the APTS/ITE&C
Department to manage the system
b. We undertake to carry out an analysis of the skill set requirement at the
APTS/ITE&C Department to manage system and carry out the training &
knowledge transfer required at the APTS/ITE&C Department to manage
system
ii. Transition of project artefacts and assets
c. We undertake to complete the updating of all project documents and
other artefacts and handover the same to the Contracting Authority
before transition
d. We undertake to design Standard Operating Procedures to manage
system (Including application and IT systems), document the same and
train the APTS/ITE&C Department personnel on the same.
3. I/We also understand that the Exit Management and Transition will be
considered complete on the basis of approval from the APTS/ITE&C Department.
Yours faithfully,
Authorized Signatory
Designation
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 100 of 107
18.11 Form U10: Undertaking on Continuous Improvement
[Company letterhead]
To, [Date]
The Managing Director,
APTS, Vijayawada.
Sub: Undertaking on Continuous Improvement
Sir,
1. I/We understand that Continuous improvement of application is highly critical
for the APTS/ITE&C Department and that the System Integrator is expected to be
the prime driver of continuous improvement during the application management
phase.
2. I/We also understand that the improvements proposed as part of this
Continuous Improvement initiative will not be the usual run-of-the-mill
enhancements, but will be significant changes that result in a quantum leap in
meeting user needs and improving the outcomes in policing.
3. I/We further understand that whether a proposed change forms part of
Continuous Improvement or is a minor change that will have to be incorporated
into the application as part of the Application Management Services will be
determined by the PM of ITE&C Department/ APTS.
Yours faithfully,
Authorized Signatory
Designation
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 101 of 107
18.12 Form U11: Undertaking on Personnel
[Company letterhead]
To, [Date]
The Managing Director,
APTS, Vijayawada.
Sub: Undertaking on Personnel
Sir,
1. I/We as System Integrator do hereby undertake that those persons, whose profiles
were part of the basis for evaluation of the bids and have been identified as “Key
Personnel” Contracting Authority for the design and development of software for
the project, shall be deployed during the Project as per our bid submitted in
response to the RFP.
2. We undertake that any of the identified “Key Personnel” shall not be removed or
replaced without the prior written consent of the Contracting Authority.
3. Under exceptional circumstances, if the Key Personnel are to be replaced or
removed, we shall put forward the profiles of personnel being proposed as
replacements, which will be either equivalent or better than the ones being
replaced. However, whether these profiles are better or equivalent to the ones
being replaced will be decided by the Contracting Authority. The Contracting
Authority will have the right to accept or reject these substitute profiles.
4. We also undertake to staff the Project with competent team members in case any
of the proposed team members leave the Project either due to voluntary severance
or disciplinary actions against them.
5. We acknowledge that the Contracting Authority has the right to seek the
replacement of any member of the Project team being deployed by us, based on
the assessment of the Contracting Authority that the person in question is
incompetent to carry out the tasks expected of him/her or found that person does
not really possess the skills/ experience/ qualifications as projected in his/her
profile or on the ground of security concerns or breach of ethics.
6. In case we assign or reassign any of the team members, we shall be responsible, at
our expense, for transferring all appropriate knowledge from personnel being
replaced to their replacements within a reasonable time.
Yours faithfully,
Authorized Signatory & Designation
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 102 of 107
19 ANNEXURE II: SERVICE LEVEL AGREEMENTS
19.1 SERVICE LEVEL AGREEMENTS
This section describes the service levels to be established for the Services offered by the
SI to the APTS/ ITE&C Department. The SI shall monitor and maintain the stated service
levels to provide quality service to APeProcurement Application Platform.
DEFINITIONS a) “Scheduled Maintenance Time” shall mean the time that the System is not in
service due to a scheduled activity as defined in this SLA. The scheduled
maintenance time would not be during 16X6 timeframe. Further, scheduled
maintenance time is planned downtime with the prior permission/ approval from
APTS/ITE&C Department.
b) “Scheduled operation time” means the scheduled operating hours of the System
for the month. All scheduled maintenance time on the system would be deducted
from the total operation time for the month to give the scheduled operation
time. The total operation time for the systems and applications within the Data
Center environment and critical Contracting Authority site infrastructure will be
24X7X365. The total operation time for the Contracting Authority site systems
shall be (8:00 HRS to 21:00 HRS Technical Support) and IT Support 24X7.
c) “System or Application downtime” means accumulated time during which the
System is totally inoperable within the Scheduled Operation Time but outside the
scheduled maintenance time and measured from the time the APTS Department
and/or its employees log a call with the SI team of the failure or the failure is
known to the SI from the availability measurement tools to the time when the
System is returned to proper operation.
d) “Availability” means the time for which the services and facilities are available for
conducting operations on the system including application and associated
infrastructure. Availability is defined as:
1. {(Scheduled Operation Time – System Downtime) / (Scheduled Operation
Time)} * 100%
e) “Helpdesk Support” shall mean the (9:00 HRS to 21:00 HRS Monday to Saturday)
basis support center which shall handle Fault reporting, Trouble Ticketing and
related enquiries during this contract.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 103 of 107
f) “Incident” refers to any event/ abnormalities in the functioning of the Data Centre
Equipment/ Services that may lead to disruption in normal operations of the Data
Centre, System or Application services.
INTERPRETATIONS a) The business hours are 10.00 AM to 6.00 PM on all working days (Mon-Sat)
excluding Public Holidays or any other Holidays observed by the State of Andhra
Pradesh. The SI however recognizes the fact that the offices will require to work
beyond the business hours on need basis.
b) "Non-Business Hours" shall mean hours excluding “Business Hours”.
c) The SLA parameters shall be monitored on a monthly basis as per the individual
SLA parameter requirements. However, if the performance of the system/ services
is degraded significantly at any given point in time during the contract and if the
immediate measures are not implemented and issues are not rectified to the
complete satisfaction of the APTS/ITE&C Department or an agency designated by
them, then the APTS/ITE&C Department will have the right to take appropriate
disciplinary actions including termination of the contract.
d) A Service Level violation will occur if the SI fails to meet Minimum Service Levels,
as measured on a half yearly basis, for a particular Service Level. Overall
Availability and Performance Measurements will be on a monthly basis for the
purpose of Service Level reporting. An “Availability and Performance Report” will
be provided by the SI on monthly basis in the suggested format and a review shall
be conducted based on this report. A monthly Availability and Performance Report
shall be provided to Contracting Authority at the end of every month containing
the summary of all incidents reported and associated SI performance
measurement for that period. The monthly Availability and Performance Report
will be deemed to be accepted by the Contracting Authority upon review and
signoff by SI and the Contracting Authority where required, some of the Service
Levels will be assessed through audits or reports e.g. utilization reports,
measurements reports, as appropriate to be provided by the SI on a monthly basis,
in the formats as required by the Contracting Authority. The tools to perform the
audit will need to be provided by the SI. Audits will normally be done on regular
basis or as required by the Contracting Authority will be performed by the APTS or
the Contracting Authority appointed third party agencies.
e) The Post Implementation SLAs will prevail from the start of the Operations and
Maintenance Phase. However, SLAs will be subject to being redefined, to the
extent necessitated by field experience at the APTS/ITE&C Department offices and
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 104 of 107
the developments of technology practices globally. The SLAs may be reviewed on
an annual/ bi-annual basis as the APTS/ITE&C Department decides after taking the
advice of the SI and other agencies. All the changes would be made by the
APTS/ITE&C Department in consultation with the SI.
f) The SI is expected to provide the following service levels. In case these service
levels cannot be achieved at service levels defined in the tables below, it shall
result in a breach of contract and invoke the penalty clause. Payments to the SI are
linked to the compliance with the SLA metrics laid down in the tables below. The
penalties will be computed and calculated as per the computation explained in this
section. During the contract period, it is envisaged that there could be changes to
the SLA, in terms of addition, alteration or deletion of certain parameters, based
on mutual consent of both the parties i.e. the Contracting Authority and SI.
g) During both the implementation phase and Operations Phase any two violations of
SLAs reaching the maximum limit, shall result in uncapping the penalty.
Following tables outline the key service level requirements for the system, which needs
be ensured by the SI during the operations and maintenance period. These
requirements shall be strictly imposed and either the Contracting Authority or a third
party audit/certification agency shall be deployed for certifying the performance of the
SI against the target performance metrics as outlined in the tables below.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 105 of 107
19.2 O&M PHASE SLAs
(To be inserted from Volume-I RFP)
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 106 of 107
20 PERFORMANCE BANK GUARANTEE FORMAT
<Name>
<Designation>
<Address>
<Phone Nos.>
<Fax Nos.>
<Email id>
Whereas, <name of the supplier and address > (hereinafter called “System Integrator”)
has undertaken, in pursuance of contract no. <Insert Contract No.> dated. <Date> to
provide Implementation services for <name of the assignment> to APTS/ITE&C
(hereinafter called “the beneficiary/ Contracting Authority”)
And whereas it has been stipulated by in the said contract that the System Integrator
shall furnish you with a bank guarantee by a recognized bank for the sum specified
therein as security for compliance with its obligations in accordance with the contract;
And whereas we, <Name of Bank> a banking company incorporated and having its
head/registered office at <Address of Registered Office> and having one of its office at
<Address of Local Office>have agreed to give the supplier such a bank guarantee.
Now, therefore, we hereby affirm that we are guarantors and responsible to you, on
behalf of the supplier, up to a total of Rs.<Insert Value>(Rupees <Insert Value in Words>
only) and we undertake to pay you, upon your first written demand declaring the
supplier to be in default under the contract and without cavil or argument, any sum or
sums within the limits of Rs.<Insert Value>(Rupees<Insert Value in Words> only) as
aforesaid, without your needing to prove or to show grounds or reasons for your
demand or the sum specified therein.
We hereby waive the necessity of your demanding the said debt from the bidder before
presenting us with the demand.
We further agree that no change or addition to or other modification of the terms of the
contract to be performed there under or of any of the contract documents which may
be made between you and the Bidder shall in any way release us from any liability under
this guarantee and we hereby waive notice of any such change, addition or
modification.
RFP for Identification of SI for O&M of APeProcurement Platform (Application) of ITE&C Department, GoAP (Vol-II)
Page 107 of 107
This Guarantee shall be valid until <Insert Date>)
Notwithstanding anything contained herein:
a. Our liability under this bank guarantee shall not exceed Rs. <Insert Value>
(Rupees <Insert Value in Words> only).
b. This bank guarantee shall be valid up to <Insert Expiry Date>
c. It is condition of our liability for payment of the guaranteed amount or any part
thereof arising under this bank guarantee that we receive a valid written claim or
demand for payment under this bank guarantee on or before <Insert Expiry
Date>) failing which our liability under the guarantee will automatically cease.
End of the Document