requests for equitable adjustment & cda claims: a primer · pdf filebased on a change to...
TRANSCRIPT
7/20/2016
1
Solving Post-Award Problems Through Change Orders,
REAs, and Claims
Presented By:
MARIA L. PANICHELLIOF COHEN SEGLIAS PALLAS GREENHALL &FURMAN, P.C.
Requests for Equitable Adjustment & CDA Claims:
A Primer
2
Requests for Equitable Adjustment
Request for Equitable Adjustment (REA): Is a request for compensation
Either for time, money or both
3
7/20/2016
2
Requests for Equitable Adjustment
Request for Equitable Adjustment: Based on a change to the contract arising
during project performance. Examples:
• Differing Site Condition• Defective Specification• Change(s) (Constructive or Express)• Suspension of Work
4
REA Fundamentals
REAs lack the formality of claims
Generally considered a creature of “contract administration” as opposed to “litigation”
5
REA Fundamentals
Filed during project performance
Involves (theoretically) “negotiations”
As compared to a claim, procedural requirements are relaxed, more informal
6
7/20/2016
3
REA Fundamentals
Time for submittal: REAs may be submitted at any time during contract performance or close out
May not be submitted after contract close out
7
REA Fundamentals
Time for submittal: REA’s should typically be submitted within 30 days of change/dispute that gave rise to the REA Failure to do so will not necessarily bar the REA unless there was prejudice to the Government
8
REA FundamentalsFormat: No specific format required Typically takes the form of a letter to the Contracting Officer with any relevant exhibits, such as:
• Cost information• Correspondence between contractor and Government• Schedule updates• Change orders• Any other relevant information for the Government to
consider
The more detail, the better your chance of success
9
7/20/2016
4
REA Fundamentals
Costs: Preparation costs are recoverable
This includes legal and accounting fees, and internal costs
10
REA Fundamentals
Certification: Generally, REAs do not need to be certified
Exception: • Department of Defense contracts where the
value exceeds the simplified acquisition threshold requires certification
11
REA Fundamentals
Certification: Certification Language:
“I certify that the request is make in good faith, and that the supporting data are accurate and complete to the best of my knowledge and belief.” DFARS 243.204‐71 and 252.243‐7002
12
7/20/2016
5
Claims
A Claim: Is filed pursuant to the Contract Disputes Act (“CDA”), 41 USC 701 et seq.
Is a formal written request demanding payment/the adjustment of a contract price or interpretation of a contractual term, or seeking other relief pursuant to or relating to a contract
13
Claims
A Claim: Can lead to litigation:
• Before a Board of Contract Appeals (Armed Services or Civilian, depending on agency at issue) or,
• Court of Federal Claims
14
Claim Fundamentals
Claims are more formal than REAs• Requires certification
No longer a creature of “contract administration”, rather it constitutes the first stage of “litigation”
No longer a negotiation, positions are fixed
15
7/20/2016
6
Claim FundamentalsTime for Submittal: Must be filed within 6 years of claim accrual
• Jurisdictional issues• Equitable Tolling
A contractor must provide a Contracting Officer with notice of a claim prior to final payment on the contract
Claims should be filed within 30 days of cancellation of a stop‐work order
16
Claim Fundamentals
Format: No specific format required. Typically takes the form of a letter to the Contracting Officer with applicable exhibits, including:• Cost information• Correspondence between contractor and
Government• Schedule updates• Change orders• Any other relevant information for the
Government to consider17
Claim Fundamentals
Format:
Claim must include a clear and unequivocal written statement that puts the Contracting Officer on notice of the basis and amount of a claim
18
7/20/2016
7
Claim Fundamentals
Costs:
Preparation costs are NOT recoverable
19
Claim FundamentalsCertification: Certification is required for claims over $100,000
Certification language:• “I certify that the claim is made in good faith; that the
supporting data are accurate and complete to the best of my knowledge and belief; that the amount accurately reflects the contract adjustment for which the contractor believes the Government is liable; and that I am duly authorized to certify the claim on behalf of the contractor.” 48 CFR 33.207
20
Claim Fundamentals
Certification: Defective certification can be corrected, but this causes delay to the claim process; not recommended
What about subcontractor claims? Fraud issues?
21
7/20/2016
8
REAs v. ClaimsInformal v. Formal
Negotiations, Discussions v. Adversarial, Litigation
Certification (Usually) Not Required v. Certification Required
Costs Recoverable v. Costs Not Recoverable
Privilege Issues? 22
REAs v. Claims:Practical Considerations
When to file a REA:
When a contractor has a good working relationship with the Contracting Officer
When the agency had indicated they would be willing to negotiate a change/dispute with the contractor
When a contractor is attempting to show that its willingness to negotiate
23
When to file a Claim:
When the contractor and Contracting Officer do not have a good working relationship, or when there is an antagonistic or adversarial relationship
When it is clear that the Contracting Officer is not willing to negotiate a change/dispute, or when the Government has already stated that it does not believe the contractor is entitled to an equitable adjustment
When the Statute of Limitations is about to run out
REAs v. Claims:Practical Considerations
24
7/20/2016
9
Keep in mind:
An REA can later be converted into a Claim
The filing of an REA does not preclude you from later filing a Claim, in fact, it is quite common to file both
REAs v. Claims:Practical Considerations
25
REAs and Claims: Common Issues
Some of the most common issues leading to REAs or Claims: Differing Site Conditions (FAR 52.236‐2) Changes (Fixed Price) (FAR 52.243‐1) Changes to Prevailing Wages (FAR 52.222‐43) Variations in Estimated Quantity (FAR 52.211‐18) Stop Work Order (FAR 52.212‐13) Suspension of Work (52.242‐14) Terminations Damages Associated with Punitive Punch List Delays Good Faith and Fair Dealing, Duty to Cooperate Recent Case Developments: Declaratory Judgments?
26
REAs and Claims: What Type of Relief is AvailableA Contractor is Entitled to:
Costs
Additional Time (Relation to LDs?)
Reasonable Profit (sometimes)
27
7/20/2016
10
REAs and Claims: What Type of Relief is AvailableA Contractor is Entitled to: Field Overhead/General & Administrative
(“G&A”) Expenses
Home Offense Expenses (in very limited circumstances)
Bond Costs
Preparation Costs (REA Only)28
Subcontractor’s “Pass Through” Claims
29
Subcontractor “Pass Through” Claims
Sovereign Immunity – General rule is that lawsuits against the Federal Government are prohibited
Tucker Act creates an exception to sovereign immunity: suits may arise out of express or implied contracts to which the government was a party
• Thus, to take advantage of this exception, there must be an express or implied contract
• Because subcontractors have no “privity of contract” they can not file claims against the government on their own behalf
30
7/20/2016
11
Subcontractor “Pass Through” Claims
To assert a claim, subcontractors’ claims must be “sponsored” by their prime contractors
Commonly called a “pass‐through” claim because the prime is “passing” the subcontractor’s claims through to the owner
Prime must clearly and affirmatively agree to sponsor the subcontractor claim
31
Subcontractor “Pass Through” Claims
To assert a claim, subcontractors’ claims must be “sponsored” by their prime contractors
Recognized by FAR 44.203(c) allows a subcontractor the right of indirect appeal to the Board of Contract Appeals or Court of Federal Claims
Certification issues?
32
Subcontractor “Pass Through” Claims
Subcontracts should address how these will be dealt with Disputes clause – distinction between claims between
subcontractor and prime, and disputes against owner
Should delineate each party’s responsibility with regard to pass‐through claims, i.e.:• Prime agrees to sponsor• Subcontractor agrees to cooperate fully
Appeal of Binghamton Simulator Company, ASBCA No. 59117 (2014)
33
7/20/2016
12
Subcontractor “Pass Through” Claims
Addressing it in the subcontract is not always enough. Always a good idea to have a Liquidating, or Pass‐Through, Agreement
In these, prime agrees to “sponsor” the sub’s claim against the Government
Combined, or concurrent, with settlement or release agreements dealing with prime and sub’s claims against each other
34
Subcontractor “Pass Through” Claims
Addressing it in the subcontract is not always enough. Always a good idea to have a Liquidating, or Pass‐Through, Agreement
Commonly, in a Liquidation Agreement, the sub agrees to release the prime in exchange for the prime’s promise to:
• Prosecute the sub’s claim against the government; and
• Pay the subcontractor some or all of the money recovered from the Government in connection with that claim
35
Subcontractor “Pass Through” Claims
Remember: Every claim in excess of $100,000 on a federal construction project must be certified
A prime contractor passing through a subcontractor’s claim to the Government must include the certification language
36
7/20/2016
13
Subcontractor “Pass Through” Claims
“I certify that the claim is made in good faith; that the supporting data are accurate and complete to the best of my knowledge and belief; that the amount requested accurately reflects the contract adjustment for which the Contractor believes the Government is liable; and that I am duly authorized to certify the claim on behalf of the Contractor.”
37
Subcontractor “Pass Through” Claims
When agreeing to pass through a subcontractor’s claim, a prime should consider the Severin Doctrine:
A prime cannot recover from the Government for harm to the sub if either the subcontract or liquidating agreement eliminates the prime’s liability to the sub
38
Subcontractor “Pass Through” Claims
However, a prime’s promise to its sub to reimburse the sub if and when recovery is obtained from the Government does not implicate the Severin Doctrine
The Severin Doctrine will not serve to bar a pass‐through claim unless the agreement between the sub and prime is an explicit and total release of the prime’s liability
39
7/20/2016
14
Subcontractor “Pass Through” Claims
Can Primes retain a portion of the damages obtained from the Government in connection with the subcontractor’s pass‐through claim?
Courts in the federal contracting context have largely ignored dealing with whether this is appropriate• In a Board case, a sub and prime had a liquidating agreement that allowed
a $7,500 “sponsorship fee” to be retained by the prime, and the Board did not address this arrangement at all in the opinion
A United State District Court, addressing a state government contract, allowed a prime to retain a portion of the sub’s damage award based largely on the principles of freedom of contract
40
CDA Claims: Appeals & Litigation
41
Claims Appeal ProcessWhat happens after a claim is filed?
FAR 33.211 ‐ When a claim by or against a contractor cannot be satisfied or settled by mutual agreement and a decision on the claim is necessary, the contracting officer shall:
Review the facts pertinent to the claim
Secure assistance from legal and other advisors
Coordinate with the contract administration officer or contracting office, as appropriate
Prepare a written decision
42
7/20/2016
15
Claims Appeal ProcessThe written decision shall include:
A description of the claim or dispute
A reference to the pertinent contract terms
A statement of the factual areas of agreement and disagreement
A statement of the contracting officer’s decision, with supporting rationale
Paragraphs explaining that the decision constitutes the final decision of the Contracting Officer, and explaining to the contractor their right to appeal, and the procedure for doing so
43
Claims Appeal ProcessWhen will this written decision be completed?
For claims of $100,000 or less:• 60 days after receiving a written request from
the contractor that a decision be rendered within that period
• Or within a reasonable time after receipt of the claim if the contractor does not make such a request.
44
Claims Appeal ProcessWhen will this written decision be completed?
• For claims over $100,000:• 60 days after receiving a certified claim
• However if a decision will not be issued within 60 days, the contracting officer shall notify the contractor, within that period, of the time within which a decision will be issued
45
7/20/2016
16
Claims Appeal ProcessWhen will this written decision be completed? (cont.)
The contracting officer shall issue a decision within a reasonable time, taking into account
The size and complexity of the claim
The adequacy of the contractor’s supporting data
Any other relevant factors
46
Claims Appeal ProcessAppeals: A contractor may appeal their claim to either a Board of Contract Appeals (Armed Services or Civilian, depending on the Agency involved with the Contract at issue) in two circumstances:
Contracting Officer issues a final decision on a claim denying the claim
• Called a “Contracting Officer’s Final Decision”
Contracting officer does not issue a decision
• Can take appeal as a “deemed denial” appeal
47
Claims Appeal ProcessWhere can a contractor file an appeal? And when?
Board of Contract Appeals (90 days)
Court of Federal Claims (12 months)
48
7/20/2016
17
Claims Appeal ProcessWhere SHOULD you appeal? Which forum is best for you?
Court of Federal Claims (“COFC”)
Article 1 Court 11 Judges, serving 15 year terms, and an additional 6
active Senior Judges Highly intelligent judicial officers, but no government
contracts experience needed to become COFC judges Can tax costs and assess attorney’s fees Single Judge decides the case Attorney representation required
49
Claims Appeal ProcessWhere SHOULD you appeal? Which forum is best for you?
Armed Services Board of Contract Appeals (“ASBCA”)
Jurisdiction over DoD and NASA CDA contracts
21 members, experienced Judges
Decisions by panels, but a single judge takes the evidence
Contractor may appear pro se
50
Claims Appeal ProcessWhere SHOULD you appeal? Which forum is best for you?
Civilian Board of Contract Appeals (“CBCA”)
Est. January 2007
Consolidated 8 separate civilian boards, including very active GSBCA (GSA)
Jurisdiction over all civilian agency CDA contracts, other than those of the Postal Service and TVA
13 members, experienced Judges
Decisions by panels, but a single judge takes the evidence
Contractor may appear pro se
51
7/20/2016
18
Claims Appeal ProcessWhere SHOULD you appeal? Which forum is best for you?
Key considerations:
Size of Contract/Dispute Amount v. Cost of Litigation Complexity of Issues Government Contracting Experience of Judges Preparation Time Required Objectivity v. Settlement Authority (Agency Counsel v. DOJ) Appeal Filing Deadlines Ruling Precedent, Trends in Decisions Formality Timing (Attorney Preference – Educate yourself)
52
Claims Appeals: Common Government Defenses
The Government tends to rely on the same defenses over and over. Some of the favorites include:
Waiver, Release or Accord & Satisfaction
Notice
Lack of Governmental Authority
53
Waiver/Release/Accord & Satisfaction
Contract Modifications often include broad waiver language that purports to release the Government from further liability
54
Claims Appeals: Common Government Defenses - Waiver
7/20/2016
19
For example:
CLOSING STATEMENT: “It is understood and agreed that pursuant to the above, the contract time is extended the number of calendar days stated, and the contract price is increase as indicated above, which reflects all credits due the Government and all debits due the Contractor. It is further understood and agreed that this adjustment constitutes compensation in full on behalf of the Contractor and its Subcontractors and Suppliers for all costs and markups directly or indirectly attributable for the change ordered, for all delays related thereto, for all extended overhead costs, and for performance of the change within the time frame stated”
55
Claims Appeals: Common Government Defenses - Waiver
It is vital to understand the difference between bilateral and unilateral modifications, and the impact this difference can have on a waiver/release or accord & satisfaction defense:
Unilateral – signed only by the Government Bilateral – signed by Government and
Contractor, can function as “accord and satisfaction”
56
Claims Appeals: Common Government Defenses - Waiver
The lesson(s)?
Be aware of waiver language before you sign Add your own language to any release to make
it clear that you take exception and that you reserve your rights to file a claim in the future
Be aware that the Government will sometimes apply pressure, or withhold modifications to entice you to sign
57
Claims Appeals: Common Government Defenses - Waiver
7/20/2016
20
What if you DID sign a modification with broad waiver language?
Is an obstacle, but not an insurmountable one. There are several responses that can help defeat a waiver argument based on release language in a modification
58
Claims Appeals: Common Government Defenses - Waiver
1. Scope
Remember the language from the closing statement: “. . . constitutes compensation in full on behalf of the
Contractor and its Subcontractors and Suppliers for all costs and markups directly or indirectly attributable for the change ordered . . .”
What do the earlier sections of the modification say about the scope of the “change ordered”?
59
Claims Appeals: Common Government Defenses - Waiver
2. Date
What was the date of the modification? What was the date, or the range of dates on which you were effected/for which you are claiming compensation?
60
Claims Appeals: Common Government Defenses - Waiver
7/20/2016
21
3. Is there any other way to defeat an accord and satisfaction defense?
Accord and Satisfaction Elements:• Proper subject matter• Competent parties• Meeting of the minds of the parties• Consideration
Can you disprove any of these elements?
61
Claims Appeals: Common Government Defenses - Waiver
Can you disprove any of these elements? (cont.)
Where the parties continue to consider the claim after execution of a release, such conduct manifests an intent that the parties never construed the release as an abandonment of plaintiff's earlier claim.
Cmty. Heating & Plumbing Co. v. Kelso, 987 F.2d 1575, 1581 (Fed. Cir. 1993)
62
Claims Appeals: Common Government Defenses - Waiver
Notice
Government often argues that the contractor failed to give the Government the requisite notice, and that the lack of notice bars the contractor’s claim(s)
Particularly prevalent in differing site condition and constructive change claims
63
Claims Appeals: Common Government Defenses - Notice
7/20/2016
22
Notice
Responses to a Notice argument
• Notice need not be in any particular form (Serial Letter?)
• Actual v. constructive notice
• Lack of prejudice
64
Claims Appeals: Common Government Defenses - Notice
Another common argument made by the Government, in particular in the “Changes” context, is that the Government official that made the change did not have the authority to bind the Government, and that the contractor’s claim is therefore barred
65
Claims Appeals: Common Government Defenses - Authority
Who has authority to bind the Government?
The Contracting Officer Any formally‐designated representative:
• ACO, COR, COTR Any representative assigned without formal designation
Different dollar levels of authority?
66
Claims Appeals: Common Government Defenses - Authority
7/20/2016
23
How do you know who has been designated as having authority?
Solicitation/Contract might designate who has authority, and to what amount
If not in the Solicitation, might be another writing (letter, modification, amendment, etc.)
Often conveyed (or reiterated, or altered) at pre‐construction (or other) meeting
67
Claims Appeals: Common Government Defenses - Authority
When is the Government bound by a Government representative’s actions?
Government is bound when an official acted within the scope of their ACTUAL authority, is NOT bound by “apparent” authority
But when else is it bound? What type of response can you offer when someone technically acted outside the scope of their authority and the Government uses this as a defense?
68
Claims Appeals: Common Government Defenses - Authority
When is the Government bound by a Government representative’s actions?
When a Government official acted with “implied” authority
• A government representative will be deemed to have implied authority when “it is an integral part of the duties assigned to the particular government employee.”
• A government representative can be found to have implied authority to make a change to the Contract if the change is within, or reasonably related and consequent to, the representative’s official responsibilities
69
Claims Appeals: Common Government Defenses - Authority
7/20/2016
24
When is the Government bound by a Government representative’s actions?
More on “implied” authority, Wieman v. U.S., 230 Ct. Cl. 563
• On‐site representative had implied authority based on: (1) the acquiescence and acceptance by the Government of benefits accruing to it from direction by on‐site representatives of the CO; and (2) the fact that the on‐site representative was authorized, although not contractually, to direct the contractor’s work and the contractor was expected to comply
• Obvious from on‐site representative’s daily inspections and other on‐site actions that the CO had delegated the “broad discretion in supervising [the] contract” and exercised that delegated authority on a daily basis
70
Claims Appeals: Common Government Defenses - Authority
When is the Government bound by a Government representative’s actions?
An unauthorized representative’s directives can be “ratified” by the government at a later date; if a superior with explicit authority to bind the government later endorses the directives given by a government representative, that representative’s actions are considered “ratified” by the government, and a contractor may be entitled to a equitable adjustment of the Contract price in connection with such directives
71
Claims Appeals: Common Government Defenses - Authority
Subcontractor v. Prime Contractor Claims
72
7/20/2016
25
Sub’s Lawsuits Against PrimeWhat if a prime breaches the subcontract?
If a nonpayment issue, sub should serve timely notice of nonpayment upon prime and prime’s surety
73
Sub’s Lawsuits Against PrimeWhat if a prime breaches the subcontract? If prime continues to refuse to honor subcontract, sub can:
• Bring suit against the prime in the appropriate U.S. District Court
• Submit a claim to the prime’s surety
74
Sub’s Lawsuits Against PrimeCommon Issues in Sub v. Prime Litigation
Pay if Paid v. Pay When Paid?
Exhaustion of Administrative Remedies
ADR
Jurisdiction (Colorado cases example)
75
7/20/2016
26
Miller Act Claims
76
The Miller Act ‐ 40 USC 3131‐3134
Mandates the furnishing of payment bonds and performance by Federal prime contractors
Defines and limits where and when a bond claim may be brought
Thus addresses two concerns that would otherwise exist in the performance of federal government construction projects . . .
77
Miller Act Claims
When does the Miller Act Apply?
Applies to all projects for the construction, alteration or repair of any public building or public work of the federal government where the prime contract exceeds $100,000• “Public Work” not defined by Act
Alternates allowed for contracts more than $25,000 and less than $100,000: (Bond, Letter of Credit, Escrow Agreement, CD, Cash)
78
Miller Act Claims
7/20/2016
27
Who is a Miller Claim against?
A subcontractor Miller Act claim is not brought against the Prime Contractor
A subcontractor Miller Act claim is brought against the Prime Contractor’s surety/sureties
79
Miller Act Claims
How does a First‐Tier Subcontractor Bring a Miller Act Claim?
No notice required Must wait 90 days from non‐payment – waiting
period to give bond principal a chance to make payments
Must file suit within 1 year of last work performed or materials supplied• Contract work v. Punch list or warranty work
80
Miller Act Claims
How does a Second‐Tier Subcontractor Bring a Miller Act Claim?
All requirements from previous slide
PLUS
MUST provide notice within 90 days (strictlyconstrued!) of supply of last labor or supplies
81
Miller Act Claims
7/20/2016
28
Questions?
82
Maria L. Panichelli, [email protected]@MariaPanichelli (twitter)www.linkedin.com/in/mariapanichelli/
83
Contact Information