government of meghalaya office of the chief
TRANSCRIPT
-1-
GOVERNMENT OF MEGHALAYA OFFICE OF THE CHIEF ENGINEER WATER RESOURCES SHILLONG
No. CE/WRD/CS&T/1/2016-17/12 Dated Shillong the 31st
Aug. 2016
NOTICE RE-INVITING TENDER
Sealed Tenders, subsequently to be drawn up in M.P.W.D. F-2 form of Tender
Agreement, duly affixed with non-refundable Court Fee Stamp of Rs. 2000/- (Rupees Two
thousand) only are hereby invited in 2 (two) Cover Bids System i.e. Technical & Financial
Bids by the undersigned on behalf of the Governor of Meghalaya from the Registered Class I
contractors only of Water Resources Department of Meghalaya having requisite qualification
for the under mentioned works and will be received in the Office of the Chief Engineer,
Water Resources Department, Meghalaya, Shillong up to 2:00 P.M. 20th
September 2016 and
will be opened on the same date at 2:30 P.M. in the presence of the tenderers or their
authorized representatives who desire to be present. If the last date happens to be a holiday,
the next working day will be considered as the date of receiving and opening of tenders.
The Detailed Tender papers may be obtained from the Technical Branch (Room
No.301), of the Chief Engineer’s office, Water Resources Department, Meghalaya, Cleve
Colony, Shillong- 793003, upto 19th
September 2016 on payment of the requisite amount, in
cash, as indicated against each work below (non-refundable) in cash during office hours on
all working days from 11:00 A.M. to 3:00 P.M. The same may also be downloaded from the
website of the Department (www.megwaterresources.gov.in) and be submitted to the
Department alongwith Demand Draft of required amount (non-refundable) duly pledged in
favour of the Chief Engineer, Water Resources Department, Meghalaya, payable at Shillong.
(NOTE – Tenderers who have already submitted the following tenders need not submit
again)
A. (i) NAME OF WORK: Construction of Stone masonry protection wall and Reinforce
cement concrete wall of Right Bank and Left Bank along the
River Bank of Umtrew River under Umtrew Umkta FIP.
(ii) LOCATION: Umtrew Umkta Village, Umsning C&RD Block.
(iii) APPROXIMATE VALUE: Rs 3,42,23,200/- (to be divided into 3 (three) groups
(v) TIME OF COMPLETION : 15 (fifteen) months from the date of issue of Final
Work order.
(vi) RATES: The rates are to be quoted AT PAR/ABOVE the
MPWD Schedule of Rates for Roads and Bridge works
(other than N.H. works) for National Highway Circle
for 2012-13.
(iv) COST OF TENDER PAPER : Rs. 3000/-
IRRI/IW-1068 (b)/ P-1
-2-
B. (i) NAME OF WORK: Construction of Office Building of the Executive Engineer,
North Garo Hills Water Resources Division, Resubelpara.
(ii) LOCATION: Resubelpara
(v) TIME OF COMPLETION : 18 (eighteen) months from the date of issue of Final
Work order.
(vi) RATES: The rates are to be quoted AT PAR/ABOVE the
MPWD Schedule of Rates for Buildings for 2013-14 for
Garo Hills.
C. EARNEST MONEY: Successful tenderer shall have to deposit Earnest Money @ 2%
of tender value.
D.
1. In case of Joint venture both the partners should submit Trading License and Labour
Certificate.
2. The prospective tenderers should have satisfactorily completed during the last five years at
least one work of similar nature and having a magnitude of 40% (price updated @ 10% per
annum compoundable) of the project cost for which prequalification is sought for or currently
executing satisfactorily at least 1 (one) work of similar nature and having completed billing
not less than 40% of the value of the work for which prequalification is sought.
3. The prospective tenderers or any of their constituent partner should not have abandoned any
work nor any of their contract work should have been rescinded during the last 5 (five) years.
4. The prospective tenderers shall have their own or furnish documentary proof for acquisition
(hire/purchase) of plants and machineries to be utilized in the execution of work (supporting
documents are to be enclosed).
5. The prospective tenderers or any of their constituent partners shall have requisite key
personnel and quality control equipments for the execution of the work which will include
Project Manager, site Engineer (supporting documents are to be enclosed).
6. The average annual turnover of the prospective tenderers or their constituent partner over the
last 5 (five) years shall not be less than 40% (forty percent) of the project cost updated @ 10
% (Ten percent) per annum compoundable.
7. The working capital of the prospective tenderers or their constituent partners shall not be less
than 10% (ten percent) of the project cost.
8. The available bid capacity of the prospective tenderers shall be more than the project cost
which will be calculated as per provision of the bid documents.
9. Non-tribal contractors shall have to furnish valid Trading License from the respective
Autonomous District Council of Meghalaya, while submitting their tender, otherwise the
tenders will not be considered as valid.
10. Those who fulfill all the above conditions are only eligible to cast their tender.
11. The Chief Engineer, Water Resources, Meghalaya Shillong, reserves the right to accept or
reject any or all tender without assigning any reason thereof.
SHRI. K.D. PHAWA Chief Engineer (WR) Meghalaya, Shillong
(iii) APPROXIMATE VALUE: Rs 1,60,69,900/-
:
(iv) COST OF TENDER PAPER : Rs. 1000/-
QUALIFYING CRITERIA -
IRRI/IW-1068 (b)/ P-2
-3-
stNo. CE/WRD/CS&T/1/2016-17/12 Dated Shillong the 31 Aug. 2016
Copy to :-
1. The Commissioner and Secretary to the Govt. of Meghalaya, Water Resources Department,
for favour of information.
2. Director of Information and Public Relation Govt. of Meghalaya for publishing in 2 (two)
issues of widely circulated local newspaper. (English & Vernacular)
3. Superintendent of Govt press for favour of printing in the Meghalaya Gazette.
4. State Informatics Officer for favour of uploading the Detailed Tender in the Department’s website.(soft copy enclosed).
5. Superintending Engineer (WR) Shillong /Tura Circle, Superintending Engineer (F/C) for
information and displaying in office notice board.
6. All Executive Engineers (W/R & FC), for information and for displaying in office notice
board.
7. Office Notice Board.
SHRI. K.D. PHAWA Chief Engineer (WR) Meghalaya, Shillong
IRRI/IW-1068 (b)/ P-3
-4-
CHECK LIST
For facilitating quick checking of the tenders, the tenderers are advised to fill up all
appendices and to ensure that enclosures / attachments are enclosed in the following order:-
1. Receipt for purchase of tender papers, NIT, terms and conditions, appendices, court fee
stamps etc.
2. Registration card.
3. Certificate regarding VAT, professional tax, Pan Card.
4. Labour licence, trading licence.
5. Documents for possession / hiring of machineries.
6. Documents regarding technical personnels.
7. Experience certificates, work done statements, completion certificates, work orders etc.
8. Balance sheets etc.
9. Any other papers not mentioned above.
SHRI. K.D. PHAWA
Chief Engineer (WR)
Meghalaya, Shillong
Detailed mailing address of the tenderer alongwith PIN Code should be given in
every space provided for the same.
IRRI/IW-1068 (b)/ P-4
-5-
NB: The tenderers are instructed to read all the terms and conditions carefully and to fill up all the appendices.Tenderers should sign in each and every page of the terms and conditions failing which the tender may be liable to be rejected. Detailed mailing address of the contractor along with PIN should be given in every space provided for the same.
TERMS AND CONDITIONS
1. a. TIME OF COMPLETION: 15 (fifteen) months from the date of issue of Final Work
order. For works under schemes like NABARD, AIBP,
RRR of Water Bodies time of completion be referred
to Sl.33.6 & Sl.33.7
b. MODE OF PAYMENT: According to progress of work and subject to
availability of fund.
2. Non-Tribal Contractors/Firms shall have to furnish the valid Trading License from the
respective Autonomous District Council along with the Tender; otherwise their
tenders shall be rejected.
3. The prospective tenderers should (i) have satisfactorily completed during the last 5
(five) years at least 1 (one) work of similar nature and having a magnitude of at least
40% (price updated @ 10% per annum compoundable) of the value of the contract for
which pre-qualification is sought or (ii) be satisfactorily executing currently at least
1(one) work of similar nature and having complete billing not less than 40% of the
value of the work for which pre-qualification is sought. (In case of (ii) amount of
billing should invariably be furnished in Appendix-5).
4. The prospective tenderers or any of the constituent partner should not have abandoned
any work nor should any of their contract works have been rescinded in the last 5
(five) years.
5. The average annual financial turnover of the prospective applicant over the last 5
(five) years shall not be less than 40% of the project cost. (Balance sheets for the last
five years, to be signed by the Chartered Accountant, should be enclosed without
which the tenders will be rejected. The abstract of Annual Turnover and Working
Capital for those last five years, to be signed by the Chartered Accountant is to be
submitted as per Appendix-3.
6. The prospective applicant or any of their constituent partners shall have their own
plants, machineries and equipments for execution of the work or furnish documentary
proof for acquisition (hire/purchase) of plants and machineries to be utilized in the
execution of work. Supporting documents are to be enclosed without which the
tenders are liable for rejection.
IRRI/IW-1068 (b)/ P-5
-6-
7. The prospective applicant should have minimum key personnel with adequate
experince for the project which include Project Manager (any Degree holder), Site
Engineer (Minimum qualification B.E., Civil), Quality Control Personnel (Minimum
Qualification Diploma Civil).The information in this regard is to be submitted as per
prescribed format at Appendix-6 along with supporting documents, without which the
tenders are liable for rejection.
8. The working capital of the prospective applicant or any of their constituent partners
shall not be less than 10% of the project cost.
9. The available bid capacity of the prospective applicant or any of the constituent
partners (in case of Joint Venture) shall be more than the cost of the project, which
will be calculated as per provision of the bid document. (as at Sl.27)
10. Registered contractor/Firm who fulfill all the above conditions are only eligible to
cast the Tender.
11. In case of joint venture, both the partners should submit trading license and labour
certificate.
12. The Chief Engineer Water Resources, Meghalaya Shillong has the right to accept or
reject any or all tender without assigning any reason thereof.
13. (a) The complete prequalification documents and price bid in separate sealed cover,
duly filled in all respect, should reach the office of the Chief Engineer Water
Resources, Cleve Colony, Shillong 793003 up to 2:00 PM of 20
14. The prequalification shall be based on an objective evaluation of details regarding
past performance, Technical & Financial capabilities and resourcefulness of the
applicant etc,.
15. PROCEDURE FOR SUBMITTING TENDERS
following in a sealed cover No. A which shall be superscribed “SEALED COVER-A”
(i) A covering letter from the tenderer.
(ii) A list of documents accompanying the tender.
(iii) Duly executed Power of Attorney in case of Firm/Joint venture.
(iv) Latest certified copies of professional Tax and Labour License, etc.
th
The tender shall be submitted in the following sealed cover: -
September 2016.
(b) The prequalification document in sealed cover No.A will be opened at 2:30 PM on
the same date. All the contractors or their authorized agents, whosoever desire, may
remain present at the time of opening the prequalification documents.
15.1(a) Sealed Cover - A: - The tender documents and accompaniments shall consist of the
IRRI/IW-1068 (b)/ P-6
-7-
(v) The tenderer’s programme of work.
vi) Detailed outline report on the tender’s methodology for execution of the work, with a
note on his programme of work.
(vii) Certificate and proforma as required in the Detailed Notice Inviting Tender document
duly signed.
(viii) A non-refundable Court Fee Stamp of Rs.2000/- (Rupees Two thousand) only
purchased in Meghalaya has to be affixed to the tenders while submitting the same.
No tender will be considered without the specified amount of Court Fee Stamp.
(ix) The Detailed tender documents duly signed on every page as a token of acceptance.
(x) Attested copy of the contractor’s photograph.
(xi) Any other information required to be submitted in accordance with this Detailed
Tender document.
(xii) Money Receipt towards cost of tender document.
15.1 (b) Sealed Cover - B: - The rates for execution of work shall be given separately in
ANNEXURE – R enclosed with the Detailed Tender Document. The ANNEXURE –
R shall be detached from the Detailed Tender Document and shall be submitted in a
separate sealed cover superscribed “SEALED COVER - B (RATES)” & Name of
Work, Tenderer’s name and detailed address with PIN Code.
15.2 The rates shall be given both in figures and in words and shall be in English. Where
there is a discrepancy between the amount in figures and in words, the amount in
words shall govern.
15.3 Both the sealed cover A and sealed cover B shall be submitted in another bigger
sealed cover.
15.4 The inner and outer envelopes shall: -
-
(i) Tender for NAME OF WORK to be given.
(ii) Name and address, with PIN Code, of the tenderer to enable the tender to be
returned unopened in case it is declared as received late or is, otherwise, unacceptable.
N.B: All enclosures/annexures are to be properly tagged to avoid losses. This office will not
take any responsibility for the loss of any paper if they are not properly tagged.
(a) Be addressed to the Chief Engineer (Water Resources), Cleve Colony, Shillong
793003.
(b) Bear the following identification: -
IRRI/IW-1068 (b)/ P-7
-8-
16. RATES: -
16.1 Rates for the work mentioned in the fore-going clauses are to be quoted in ANNEXURE-
R for the items covered by (1) the S.O.R. of MPWD for Roads & Bridge Works (other
than N.H. works) for National Highway Circle for the year 2012-13 for work at ‘A’ and
(2) S.O.R of MPWD for Building for 2013-14 Garo Hill for work at ‘B’.
16.2 The rates quoted by the tenderers shall be inclusive of all expenses for proper and entire
completion of the work to the relevant specifications and to the satisfaction of the
engineer in-charge and shall amongst other things include all taxes, octroi, royalty,
V.A.T., income tax, supply of materials, carriage of materials, water plants and
equipment, incidental charges, power supply. It shall also include all cost involved in
construction such as necessary labour sheds, godown, dismantling work, dewatering of
foundation, shoring in excavation, removal of logs etc. The quoted rate shall cover all
incidental expenditure for satisfactory completion of the Scheme.
16.3 Meghalaya Value Added Tax and cess, as applicable will be deducted from each and
every bill for the works, payable to the contractor, as per the prevailing rates.
17. OTHER CONDITIONS FOR SUBMISSION OF TENDERS: -
17.1 The tenderers shall, prior to submitting their tender for the work, also inspect the site and
satisfy themselves on their own as to the hydrological, climatic and physical condition
prevailing at site, the nature, extent and practicability of the work, availability of housing,
power supply, and other facilities. The availability of different materials and their
adequacy, the extent of lead and lift require for execution of the work, labour and
probable sites for labour camp, stores, godown etc. They shall take into consideration the
local conditions, traffic restriction, obstruction in work, if any, over the entire period
required for completion of the work and shall allow for all such extras likely to be
incurred due to any such conditions, obstruction, restriction etc. They shall themselves
obtain all necessary informations as to risk, contingencies and other circumstances which
may affect or influence their tender. No other change consequent to any misunderstanding
or otherwise shall be allowed after casting their tenders.
17.2 The tenderers shall be deemed to have full knowledge of the site, whether he inspected it
or not, and no extra charges consequent to any misunderstanding or otherwise shall be
allowed.
17.3 For any other information, the same may be obtained from the office of the Executive
Engineer, (Water Resources) of concerned Division / Executive Engineer
(FC/WB/RB) Shillong.
IRRI/IW-1068 (b)/ P-8
-9-
17.4 All corrections, interpolations or cutting in these tenders shall be attested in ink/ dot
pen by the tenderer or his authorized agent with his dated signature in ink/ dot pen.
The tender shall not contain any erasures or overwriting. Use of correcting fluid shall
not be allowed.
17.5 Any tender containing any erasures or overwriting or corrections which are not in
conformity with the above, shall be rejected.
17.6 It will be obligatory for the tenderers to keep the offer of their tender valid for a
period of 180 days from the due date of receipt of tender. If any tenderer withdraws
the tender before the said period or make any modification in the terms and conditions
not acceptable to the department, then the department shall without any prejudice to
any other right or remedy be at liberty to treat his tender as invalid and to forfeit an
amount equal to the fixed deposit at the time of registration and or any amount
17.7 The Chief Engineer, Water Resources Meghalaya Shillong, shall have the right to
omit or suspend certain items of work, to revise or to amend the tender documents
prior to the date of receipt and opening of the tender. Such revisions or amendment or
extensions, if any, shall be given wide publicity through newspapers and
communicated to all concerned in the form of corrigendum by post.
17.8 All works shall have to be carried out as per specification conforming to the relevant
specifications and I.S.code of practice.
17.9 The agreement shall be subsequently drawn up in the PWD F-2 form and this Detailed
Tender document shall form part and parcel of the agreement. The terms and
conditions of these detailed tender documents shall supersede those of the PWD F-2
form wherever the former are at variance with the latter.
17.10 The Tenderer is to sign in all the pages of the Detailed Tender documents as a token
of acceptance of the various conditions of this tender documents, without which the
tender is liable to be rejected.
17.11 The acceptance of tender will rest with the Chief Engineer, Water Resources,
Meghalaya Shillong, who does not bind himself to accept the lowest tender or any
tender and reserve the right to reject any or all the tenders received without assigning
any reasons thereof.
17.12 If either the Contractor himself or any of his employee were retired Government
employees of the gazetted rank in any Government Department they should give the
date of retirement and if their retirement is within 3 (three) years from the date of
calling the tender, necessary permission from the Government is to be obtained and
IRRI/IW-1068 (b)/ P-9
-10-
enclosed alongwith the tender. If this condition is not fulfilled the tender is liable to be
rejected. Technically qualified and experienced person(s) as will be approved by the
Engineer in-charge shall have to be kept at site by the contractor to supervise all the
work.
17.13 Canvassing in connection with the acceptance of the tender is strictly prohibited and
is liable to disqualify the tender without assigning any reason thereof.
17.14 Tools and Plants as available and as can be spared will be lent by the Department to
the tenderer on usual hire charge and terms as per P.W.D. Codes and Rules. Before
submitting the tender, the tenderer should ascertain from the Executive Engineer of
concerned Division about the availability and terms of hire of tools and plants. The
tenderers shall be responsible for collaboration with other contractor so as to expedite
the execution of his or other contractor’s work which may run simultaneously. The
hire charge of tools and plants shall be as per current rate of the concerned Water
Resources Division. The hire charge of tools and plants lent to the contractor will be
recovered from every bill of the contractor. The tools and plants will be issued from
the nearest Water Resources godown and shall be returned to the Water Resources
godown /Compound in good condition at the contractor’s own cost and expenses. No
final bill will be paid to the contractor unless the materials are returned in good
condition.
18. OPENING OF TENDER: -
18.1 The tender document in sealed cover - A will be opened by the Chief Engineer Water
Resources Meghalaya Shillong or such officer as may be authorized on his behalf in
the office of the Chief Engineer Water Resources Meghalaya Shillong-3 on 20th
Sept.
2016 at 2:30hrs in the presence of the tenderers or their authorized representative who
desire to be present. In case the above date is declared as a holiday, the tenders will be
opened on the following working day at the same time and place.
18.2 The price bid of those tenderers found to be qualified by the Chief Engineer Water
Resources, Meghalaya Shillong shall be opened at a later date to be notified.
18.3 The Chief Engineer, Water Resources, Meghalaya Shillong, reserves the right to open
or not to open the price bid in Sealed Cover - B of any tenderer without assigning any
reason(s) thereof.
19. EARNEST MONEY:-
19.1 Registered Class I Contractor of Water Resources need not furnish the Earnest Money
at the time of submission of tender.
IRRI/IW-1068 (b)/ P-10
-11-
19.2 The Earnest Money or the Fixed Deposit for the amount prescribed duly pledged to
the concerned Executive Engineer (WR) is to be deposited by the selected contractor
before signing the Tender agreement. This earnest money or Fixed Deposit will be
forfeited to the Govt. if the contractor fails to start the work within the stipulated time
or abandon the work at the later stage of progress.
20. REJECTION OF TENDERS: -
20.1 All tenderers are hereby cautioned that conditional offer or deviation from the
conditions of contract or other requirement stipulated in these tender documents shall
be summarily rejected as non-responsive and shall not be considered further in tender
evaluation and contract award.
20.2 A tender not accompanied by current Professional Tax Certificates, VAT Certificate
may be liable for rejection.
20.3 Canvassing in connection with a tender in any form, renders the tender liable to be
rejected.
20.4 Tenders not accompanied by necessary details and relevant documents are liable to be
rejected.
20.5 Tenders not affixed with the stipulated Court Fee Stamp shall be summarily rejected.
20.6 Tender containing any erasures or otherwise defective may be rejected.
PRE-QUALIFICATION PARTICULARS
21. GENERAL INFORMATION: -
21.1 The applicant shall give details of his/her registration with Meghalaya Water
Resources Department.
21.2 Attested copies of registration certificate shall be submitted along with the tender.
21.3 Attested photograph of the applicant shall also be submitted along with the tender.
21.4 The structure and organization details shall be given in Appendix-2. In case of firms,
a certified copy of the Articles of Association or Power of attorney shall be submitted
along with the tender.
21.5 EXPERIENCE: -
21.6 The applicant shall furnish details of their turnover in Appendix-3. Supporting
documents, such as audited report and balance sheets from Chattered Accountant,
income tax returns, certificate from the Executive Engineer shall be submitted along
with the tender. Abstract of Balance Sheets for the last five years showing Turnover
& Working Capital as per Annexure – 3 filled up and signed by Chartered Accountant
should invariably be filled up.
IRRI/IW-1068 (b)/ P-11
-12-
21.7 The applicant shall give details of experience in construction of similar type of works
in Appendix-4 (Just filling up as “enclosed” will not be accepted). Certificates of
successful completion of the works and regarding the quality of works shall be
obtained from the concerned Executive Engineer in whose jurisdiction the work was
completed, and attested copies shall be enclosed with the applications. The certificates
shall clearly indicate the name of works, nature of works along with Tender value.
(For construction of headwork, the similar nature of works are (i) Construction of
Barrage/Headwork & (ii) Permanent RCC bridges only).
21.8 The Applicant shall give details of the works in progress on current contract
commitments in Appendix-5 (Just filling up as “statement enclosed” or “enclosed”
will not be accepted).
22. TECHNICAL PERSONNEL: -
22.1 The Applicant must have suitable qualified personnel to fill the position given in
Appendix-6. The details shall be correctly furnished as required in Appendix-6.
22.2 An undertaking from the Technical Personnel along with their photograph and
Educational Qualification Certificate shall be enclosed along with the application.
23. PLANTS AND MACHINERIES: -
23.1 The Applicant shall give details of the Plants and Machineries and equipments
available with the applicant with requisite documentary proof in the form of court
affidavit or certificate of possession of machinery & equipment to be given by an
officer not below the rank of Executive Engineer.
23.2 The Applicant may indicate the equipments he /she intend to procure/hire with
necessary undertakings.
24. FINANCIAL POSITION: -
24.1 The applicant shall demonstrate that he/she has access to or has available, liquid
assets (Working capital and cash in hand) and/or credit facilities of not less than 10%
of the contract applied for.
24.2 Banker’s certificate in Bank’s letter head and relevant documents shall be enclosed
with the application to prove the applicant’s financial capacity and credit facility.
24.3 The details of the applicant’s financial capability shall be given in Appendix-7.
25. LITIGATION HISTORY: -
25.1 The applicant shall provide accurate information on any litigation or arbitration
resulting from contracts completed or under execution by him/her over the last five
years in Appendix-8.
IRRI/IW-1068 (b)/ P-12
-13-
25.2 Even though the Applicants meet the above criteria, they are subject to be disqualified
if they have: -
(i) Made misleading or false representation in the forms, statement and attachments
submitted, and/or have (ii) Records of poor performance.
26. JOINT VENTURES
26.1 Joint Venture must comply with the following minimum qualification requirements: -
(i) The lead partner shall meet not less than 40% of all the qualifying criteria given in
clauses 3, 5 & 8 above.
(ii) Each of the other partners shall meet not less than 30% of all the qualifying criteria
given in clauses 3, 5 and 8 above.
(iii) The Joint Venture must satisfy collectively the criteria of clauses 3, 5 & 8, for which
purpose the relevant figures for each of the partner shall be added together to arrive at
the joint venture’s total capacity. Individual members must each satisfy the
requirements of clauses 22 and 23.
27. Applicants who meet the minimum qualification criteria will be qualified only if their
available bid capacity at the expected time of bidding is more than the total estimated
cost of the works. The available bid capacity will be calculated as under.
Available Bid Capacity = (A x N x 2-B), where
A = Maximum value of Civil Engineering works executed in any one year during the
last five years (updated to the current price level), rate of inflation may be taken as
10% per year which will take into account the completed as well as works in progress.
B = Value of works at current price level of the existing commitments and ongoing
works to be completed during the next 1.5 years (period of completion of works for
which bids are invited); and
N = Number of years prescribed for completion of the works for which the bids are
invited.
Note: - In case of Joint Venture the Available Bid Capacity will be applied for each partner to
the extent of his proposed participation in the execution of the works.
28. CONDITIONS RELATING TO AWARD OF WORK: -
The successful tenderer will be notified by a letter that his tender has been accepted.
The successful tenderer will have to furnish the necessary security deposit as per
terms and conditions mentioned in clause 19 and sign the formal tender agreement to
be drawn up by the Department within 15 (fifteen) days of the communication of
IRRI/IW-1068 (b)/ P-13
-14-
acceptance of his tender. No work shall be started before signing and acceptance of
the formal tender agreement.
29 SECURITY DEPOSIT: -
29.1. The successful tenderer will be required to furnish security deposit for the fulfillment
of his contract. The total Security Deposit will be 10% (ten percent) of gross
payments to the contractor. However, a security deposit in any approved form of
deposit amounting to 2% (two percent) of the value of the contract will have to be
furnished by the successful tenderer at the time of signing the formal tender and
before issue of final work order. The balance of the security deposit shall be
recovered from the contractor from his interim bills @ 8% from all payment.
29.2. The recovery of security deposit by deduction from running account bills does not
arise in case the contractor deposits the total security deposit in the form of
Government securities of deposit at call receipts for total amount, acceptable to the
Government duly pledged to the Executive Engineer Water Resources, of concerned
Division. Government papers tendered as security shall be taken at the surrendered
value at the time of submission of the tender.
29.3 The Security Deposit will be retained by the Department for a period of 12 (twelve)
months after completion of the work during the defect liability period. For any reason,
if the final payment of the work is not made within 12 months of the date of
completion, the validity of the security deposit shall have to be extended up to the
date of final payment
29.4 In case the contractor does not complete the work or leaves the work or part of it
unfinished, the security deposited by the contractor will be forfeited.
29.5 Preference for allotment of work may be given to landowners provided they are
registered contractors of the Department.
29.6 The allotting authority reserve the right to split the work within a group if found
necessary and practicable.
29.7 Blacklisted contractors either from this Deptt. or from any other Govt. Deptt will not
be considered for allotment of work.
30 MATERIALS: -
30.1 Materials for construction like cement, rods, bitumen, etc, shall have to be procured by
the Contractor at his own arrangement. The construction materials conforming to
relevant I.S specifications shall be procured by the contractor/firm from any
registered/authorized dealers/manufacturers. Documentary proof of purchase, like
IRRI/IW-1068 (b)/ P-14
-15-
cash memo, etc., should be submitted to the Executive Engineer concerned for his
necessary verification and subsequent acceptance/rejection which is final. However, if
the same are available and sparable in stock, these will be issued to the contractors
from the nearest godown/storeyard, and carriage to the site of work shall be done by
the contractor at his own cost. Recovery of the cost of such materials issued by the
Department will be made at the current issue rates of the Division concerned, revised
from time to time.
30.2 Excess materials not utilized in the specified work, if any, taken by the Contractor
from the Department should be returned in perfect condition within 7(seven) days
from the date of final measurement. Damaged/defective materials will not be accepted
back by the Department. The cost of such materials will be recovered from the
contractor’s bill at double the rates stipulated in the contract.
30.3 Recovery rate of any/all stock materials issued by the Deptt. will be valid up to the
stipulated date of completion as per contract, beyond which recovery will be made as
per the issue rates of the Division concerned, revised from time to time.
30.4 The oversized/undersized and substandard stones not conforming to ISI required
specifications will not be accepted by the Deptt. The Contractor who brought such
materials to the site of work shall have to remove the same immediately failing which
the Deptt. will remove the same and the cost of removal will be recovered from the
contractor’s bill.
30.5. Materials required for the work whether brought by the contractor or supplied by the
Department shall be stored by the contractor only at appropriate and safe places,
Storage and safe custody of the materials shall be the responsibility of the contractor.
If during construction, it becomes necessary to remove or shift the stored materials,
shed, workshops, etc, to facilitate construction of the allotted work, the contractor
shall have to do so at his own cost as directed by the Engineer-in-charge.
31. EXPLOSIVE:
31.1 If explosives are required for the work, the contractor will be responsible for making
necessary arrangement for procuring the same from the nearest PWD magazine where
the materials are available. The contractor will submit a written request to the
concerned PWD office routing the application through the officer of the respective
Executive Engineer (Water Resources) who will recommend for the issue of the
materials. The contractor will bear the cost of the explosives and will be responsible
for the carriage, safe and proper storage etc of the materials. The contractor will also
IRRI/IW-1068 (b)/ P-15
-16-
be responsible for the proper utilization of the explosives which should be exclusively
for the specified work and he should also strictly follow the rules, regulation and
guidelines as laid down by PWD with respect to utilization of explosives for civil
construction works.
31.2 The contractor shall exercise utmost care while using explosive and inflammable
materials so as not to endanger life and property and he shall be solely responsible for
any and all damages resulting from the use of such materials. Further, he shall
indemnify absolutely the Department and its officers and employees against any claim
or liability arising out of accident or violation of any laws, rules, orders, etc, enforce
regarding use of such materials.
32. DEFECTIVE MATERIALS:
32.1 All materials used on work, without prior inspection (and where testing is necessary)
and without approval of the Engineer-in-charge is liable to be considered
unauthorized and defective.
32.2 The Engineer-in-charge shall have full powers for getting removed any or all of the
materials brought for construction to the site by the contractor which are not in
accordance with the contract specifications or do not conform in character or quality
to the samples approved by him. In case of default on the part of the contractor in
removing rejected material, the Engineer-in-charge be at liberty to have them
removed by other means at the cost of the contractor.
32.3 The Engineer-in-charge shall have full powers to order for proper materials to be
substituted for rejected materials and in the event of the contractor refusing to comply
to this, the Engineer-in-charge may cause the same to be supplied by other mean at
the cost of the contractor.
33. PROGRAMME OF CONSTRUCTION:
33.1 Time is the essence of the contract and it shall be clearly understood that the
contractor is bound to complete the work in all respects within the time specified vide
clause 1.a of these documents.
33.2 The work shall be carried out as per detailed programme of work drawn up by
the tenderer and submitted with the tender. The tender’s programme of work
shall give the forecast of the date of commencement and completion of the
various construction stages of the work. It shall also indicate the time scheduled for
all preliminary arrangement the contractor intends to make before starting the work.
This progress scheduled after modification, if any during the progress of seeking
clarification while examining the tender, shall form a part of the contract. In absence
IRRI/IW-1068 (b)/ P-16
-17-
of such programme of work detailed programme shall be drawn up by the
Engineer-in-charge which shall be binding on the contractor and shall form a
part of the contract.
33.3 The progress schedule may be amended as and when necessary by agreement
between the Engineer-in-charge and the contractor.
33.4 Any major change in the work programme shall be intimated by the contractor
to the Engineer-in-charge in writing for his approval. Minor changes will only be
recorded in the work register which shall be maintained by the contractor. Site
office throughout the period of execution of work shall be opened for inspection by
the Engineer-in-charge or is representative.
33.5 Work may be carried out day and night and one or more shift irrespective of Sundays
and holidays as considered fit by the contractor but for work on Sundays and holidays
and night, the contractor shall have to give prior notice in time to the Engineer-in-
charge or his representative so that supervisory staff will be deputed in time. The
contractor shall not be allowed to execute any permanent nature of work in absence of
supervisory staffs or Engineer-in-charge. No work shall be kept suspended for more
than forty-eight hours except on reason of inspection or delay in taking measurement.
33.6 Work should strictly be completed within scheduled time. However, for special
scheme like NABARD /AIBP / RRR of Water Bodies completion time should strictly
be observed in conformity with the special terms and conditions laid down there-
under for which penalty may be imposed accordingly.
33.7 For NABARD scheme, the contractor/Firm shall be responsible for the defect liability
period for 3 (three) years after the project is completed /commissioned.
34. PROGRESS OF WORK:
34.1 The contractor shall give the Engineer-in charge on the 4th
day of each month a
report on progress of work done during the previous month as per suitable
proforma.
34.2 If at any time, during the progress of work, the Engineer-in charge shall be of the
opinion that the contractor is not executing the work with reasonable diligence, it
shall be lawful for him, by notice in writing, to call upon the contractor to complete
a specified portion (s) of the work by a date to be appointed in the notice and, in
case the contractor continues to do so even after one month of a notice in writing
from the Engineer-in charge, the contractor will render himself liable to action as
provided vide clause 44.
IRRI/IW-1068 (b)/ P-17
-18-
34.3 According to progress of work and availability of fund, payment of Bills to
contractor may be made.
35. EXTENSION OF TIME:
(a) Force Majeure, or
(b) Abnormal bad weather, or
(c) Serious loss or damage by fire, or
(d) Civil commotion, strike or lockout other than the labour engaged by the
contractor or effecting any of the trade employed on the work, or
(e) Delay on the part of other contractors or tradesmen engaged by the Department
in executing work on which the progress of the work under this contract is
dependent but does not form part of this contractor, or
(f) Any other cause which in the absolute discretion of the accepting authority is
beyond the contractor’s control. Then, upon the happening of any such event
causing delay, the contractor shall immediately give notice thereof in writing to the
Engineer-in charge but shall nevertheless pursue constantly his best endeavours to
prevent or make good the delay and shall take all possible steps to the satisfaction of
the Engineer-in charge to proceed with the work.
35.2 Intimation of the necessity for extension of time shall be given by the
contractor in writing not later than fourteen days of the happening of the event
causing delay. The contractor may also, if practicable, indicate in such a letter
the period for which extension is desired.
35.3 In any such case, the accepting authority may give a reasonable extension of
time for completion of the works which shall be communicated to the
contractor by the Engineer-in-charge in writing within three months of the
date of receipt of such request by the Engineer-in-charge.
35.4 Formal request for extension of time for a specific period shall be submitted to
the Engineer-in-charge at least 6 (six) months before the expiry of the contract
period. The request for extension of time shall be accompanied with justifiable
reasons for the request.
35.5 Extension of time shall also be advisable in the case of temporary suspension of
work ordered in writing by the Engineer-in-charge.
35.1 If the work be delayed by
IRRI/IW-1068 (b)/ P-18
-19-
36 SUB-LETTING OF CONTRACT
The contract or any part thereof shall not be assigned or sublet without the prior
written approval of the Engineer-in-charge.
37. SETTING OUT OF WORK
37.1 The contractor shall be responsible for the true and proper setting out of the work.
He shall be responsible for proper maintenance of all reference pillars, bench marks,
statues and other evidences existing in the field required in connection with the
setting of work at his own cost till physical completion of all the items of the work
or prior to that, if agreed to by Engineer-in charge.
37.2 All such bench marks, reference pillars, etc, established by the contractor shall be
subjected to check and approval of the Engineer-in-charge or his authorized
representatives at all times. Any variation noticed in the work as a result of
improper establishment or maintenance of these shall be at the risk and expense of
the contractor.
38. INSPECTION OF WORK:
38.1 The contractor shall either himself supervise the execution of the work or shall
appoint a competent agent approved by the Engineer-in-charger to act on his behalf.
If the contractor fails to appoint suitable agent as directed by the Engineer-in-
charge, the latter shall have full power to suspend the execution of the work until
such date a suitable agent is appointed and the contractor shall be held responsible
for the delay so caused to the work.
38.2 The Engineer-in-charge or the Sub-Divisional Officer or the officer in charge is to
have at all times access to the works which are to be entirely under his control.
Engineer-in-charge shall communicate or confirm his instruction to the contractor in
respect of the execution of work in a ‘Work Site Order Book’ and the contractor or
his authorized agent shall confirm receipt of such instruction by signing relevant
entries in the book. If required the contractor agent shall be considered to have the
same status as if they had given to the contractor himself.
38.3 The contractor shall allow inspection of the Registers or others documents by
inspecting officers and the Engineer-in-charge or his authorized representatives at
any time.
38.4 One copy of the approved drawing shall be kept by the contractor at the site and the
same shall be at all reasonable times be available for inspections and use by the
Engineer-in-charge.
IRRI/IW-1068 (b)/ P-19
-20-
38.5 All works shall be subjected to examination and approval by the Engineer-in-
charge, no work shall be covered up or put out of view prior to such approval and
the contractor shall give due notice to the Engineer-in-charge or his authorized
representatives, shall without unreasonable delay, attend for the purpose of
examining such works.
39. MEASUREMENT AND RECORD:
39.1 The Engineer-in-charge shall, except as otherwise stated, ascertain and determine by
measurement the value of the work done.
39.2 He shall, when he requires any parts of the work to be measured, give notice to the
contractor’s authorized agent or representative who shall forthwith attend or send a
qualified authorized agent to assist the Engineer-in-charge’s representative in
making measurement and shall furnished all particulars required by either of them.
39.3 Should the contractor not attend or neglect or refuse to send such agent, then the
measurement made by the Engineer-in-charge or representative approved by him
shall be taken to be the correct measurement of the work. Measurement taken
jointly shall be signed and dated by both parties of each day of measurement. The
value of work under additional items if ordered and executed shall be ascertained by
measurement.
Measurement taken jointly shall be signed and dated by both parties if each day of
measurement. The value of work additional items if ordered and executed shall be
ascertained by measurement.
40. DISPUTE:
In case of any disputes, questions or differences etc, that may arise shall arise
between the parties of the contract, it is to be referred to the Chief Engineer. Water
Resources Department, Meghalaya, Shillong, whose decision shall be final,
conclusive and binding on the contractor.
41. FINAL CERTIFICATE:
41.1 Within ten days after the work is completed the contractor shall give notice of such
completion to the Engineer-in charge and within thirty days of receipt of such
notice, the Engineer-in charge shall inspect the work and if there is no defect in the
work, shall furnish the contractor with a certificate indicating the date of
completion. However, if there are any defects which in the opinion of the Engineer-
in charge do not need reconstruction and can be rectified, he shall give a certificate
IRRI/IW-1068 (b)/ P-20
-21-
indicating (a) the date of completion (b) defects to be rectified by the contractor as
may require for rectification of defects.
43.2 In the event of the contractor failing to rectify the defect or damage within the
period to be notified by the Engineer-in-charge in his notice aforesaid, the Engineer
44. CANCELLATION OF CONTRACT IN FULL OR IN PART:
41.2 No certificate of completion shall be issued nor shall the work considered to be
complete till the site is finally cleared of unused materials, spoils, debris etc (as
provided for in clause 42 of these documents), except for such materials and
equipments as may be required for rectification of defects.
42. FINAL CLEARANCE OF SITE:
On completion of works, the contractor shall clear away and remove rubbish from
the site including all constructional plants, surplus materials and temporary works of
every kind, etc. to the satisfaction of the Engineer-in charge.
43. DEFECT LIABILITY:
43.1 The contractor shall be responsible to make good and remedy at his own expense
within such a period as may be stipulated by the Engineer-in-charge, any defect
which may develop or may be noticed before the expiry of a period of 12 (twelve)
months for a period of 3 (three) years in case of NABARD Schemes (referred to as
defect liability period) from the certificate of completion and intimation of which
shall be sent to the contractor by a letter sent by hand or by registered post.
-
in-charge may rectify or remove or re-execute the work and or remove and replace
with others the materials articles complained of as the case may be by other means
at the risk and expense of the contractor.
44.1 If the contractor fails to complete the work or portion of the work specified within
the specified time, the accepting Authority may without prejudice to any other right
or remedy which shall have accrued or shall accrued thereafter, by written notice,
cancel the contract in whole or in part.
44.2 The Accepting Authority shall in such cancellation have powers to:
(a) Take possession of the site and any materials, constructional plants, implements,
stores etc. thereon and
(b) Carry out the incomplete work by any means at the risk and cost of the
contractor.
44.3 On cancellation of the contract in full or in part, the Engineer-in-charge shall
determine what amount if any is recoverable from the contractor for completion of
IRRI/IW-1068 (b)/ P-21
-22-
the work and the loss or damage suffered by the Department. In determining this
amount, credit shall be given to the contractor for the value of the work executed by
him up to the time of cancellation, the value of contractor’s materials taken over and
incorporated in the work and use of machinery belonging to the contractor.
45.1 The contractor shall employ skilled and experienced labours in sufficient number to
maintain the required rate of progress and quality to ensure workmanship of the
degree specified in the contract and to the satisfaction of the Engineer-in-charge. In
connection with the work, the contractor shall not employ any person who has not
completed fourteen years of age.
45.2 The contractor shall furnish to the Engineer-in-charge forth-nightly distribution
return of the number and description by the trades of work in which people are
employed on the work.
45.3 Contractor shall not employ labour or staff of doubtful integrity. If anti-state or anti-
social elements are employed by the contractor, his contract will be cancelled and
no claim whatsoever will be entertained for any losses or damages.
45.4 For the purpose of all labour laws, the contractor shall be deemed as “Employer” in
respect of the labours employed by him for the contract work. The Department shall
not take any liabilities whatsoever in this respect.
45.5 The contractor shall pay to the labourers employed by him adequate wages and shall
be as per the Rules and Regulations framed by the Department/Government from
time to time. The register of work men and Register of Wage-Cum-Muster Roll
shall be maintained and kept at the work site or near to it as possible.
45.6 The contractor shall see that sufficient numbers of technically qualified men are
always at the site of the work during working hours personally checking all the
items for the work and paying extra attention to the specification and quality of
work. For this purpose the tenderers should mention their own technical
qualification and experience in the tender as credentials.
45.7 If the contractor employs 5(five) or more migrant workmen, he should obtain
Registration Certificate and License as the case may be from the Registering and
Licensing Officer i.e. in respect of Shillong Sardar Division from the Labour
Commissioner and other areas from the D.C/Addl. D. C. and S.D.O. (C) of their
respective jurisdiction.
45. LABOUR REGULATION:
IRRI/IW-1068 (b)/ P-22
-23-
45.8 The contractor shall maintain proper record of labour employed by him and shall submit fortnightly
returns to the Engineer in charge.
45.9 (a) 1% labour cess shall be deducted from each running and final bills
(b) To furnish either a copy of applicable license/ registration or proof of applying for obtaining
labour license, registration with EPFO, ESIC & BOCW registration.
(c) To register the labourers with the Meghalaya Building & Other Construction Workers’ Welfare
Board.
(d) The contractor shall, at all stages of work, deploy skilled/semi skilled tradesmen who are
qualified and possess certificate in particular trade from CPWD Training Institute/Industrial Training
Institute/National Institute of construction Management and Research (NICMAR)/ National
Academy of Construction, GIDC or any similar reputed and recognized Institute managed/ certified
by State/Central Government. The number of such qualified tradesmen shall not be less than 20% of
total skilled/semi skilled workers required in each trade at any stage of work. The contractor shall
submit number of man days required in respect of each trade, its scheduling and the list of qualified
tradesmen along with requisite certificate from recognized Institute to Engineer in charge for
approval.
46. MATERIALS SOURCES:-
46.1 Quarry for stone, sand, earth etc. has to be ascertained from the site and approved by the
Engineer-in-charge.
46.2 The tenderers shall make their own independent investigations into the availability as well
as suitability of the various materials required for construction.
46.3 No claim whatsoever in respect of 46.2 above will be admissible for any extra leads etc.
Materials conforming to specifications shall have to be brought from all leads.
46.4 Payment of Forest Royalty on minor minerals such as stone, sand, earth etc. will be recovered
from the contractor’s bill. The rates of royalty shall be as per prevailing rates. However,
recovery of Forest Royalty will be exempted from those contractors who can show that they
have already paid the forest royalty at the time of purchase from the dealers/quarry owners
and, on such proof, with relevant voucher clearly indicating that forest royalty has been
paid, no deduction shall be made.
47. SPECIFICATION OF THE WORK:
47.1 All works shall be carried out as per specifications specified in the approved drawings.
47.2 Necessary chowkidars shall be provided by the contractor for guarding the machineries etc at the site
of work. If any obstruction to road communications, sufficient red lights as night caution to the
drivers of moving vehicles to be provided by the contractors at their own cost. If any accident takes
place, the contractor will solely be responsible.
47.3 Materials used for the work should satisfy all the necessary test as per I.S. specifications.
SHRI. K.D. PHAWA
Chief Engineer (WR)
Meghalaya, Shillong
IRRI/IW-1068 (b)/ P-23
_________________
-24-
A P P E N D I X - 1
GENERAL INFORMATION
-
(ii) Enclose attested copy of photograph of the Applicant
Full Name:
All firm and contractors applying for pre-qualification are requested to
complete the information in this form.
1. Name of firm/contractor__________________________________________________
2. Head office address: - ________________________________Pin Code:
3. Telephone (Land Line): -________________Cell: -_______________
4. Fax: -_________________________________________________________________
5. Place of incorporation Registration: -________________________________________
6. Years of incorporation Registration: -_______________________________________
7. Registration Number: -___________________________________________________
8. Organization with which the
Applicant is Registered: - ___________________________________________________
9. Whether SC/ST (to enclose certificate).______________________________________
Note: (i) Enclose attested copy of Registration Certificate
Signature
IRRI/IW-1068 (b)/ P-24
-25-
A P P E N D I X - 2
STRUCTURE AND ORGANIZATION
(a) an individual
(b) a proprietary firm
(c) a firm in partner-ship
(d) a Limited Company or Corporation
3. Number of years of experience
(a) as a Prime Contractor (contractor shouldering Major responsibility)
(i) in own Country
(ii) Other Countries specify country)
Note: Enclose certified copy of your constitution
Signature
Full Name:
1. The applicant is
2. Attach the Organization Chart showing the
structure of Organization, including the name
of the Director and position of others.
7. Have you sublet any work at any time?
(If yes, specify the work and extent of subletting)
4. How many years has your organization
been in business of similar work?
5. Has any work been withdrawn from you?
(If yes, give details and reason thereof)
6. Have you ever left the work awarded to you in-complete?
(If so, give name of Project and reason for not completing work)
IRRI/IW-1068 (b)/ P-25
________________________________________________________________________
-26-
A P P E N D I X – 3
GENERAL EXPERIENCE
Annual Turn-over (Construction work only)
All applicants & individual firms are requested to complete this form. The
information supplied should be annual turnover of the applicant in terms of the accounts
billed to clients for each year, for work in progress or completed.
Name of Applicant: - ______________________________________________
Sl.
No.
Year Completed works
(Rupees)
Works in progress
(Rupees)
Working
Capital (Rupees)
1.
2.
3.
4.
5.
2011-2012
2012-2013
2013-2014
2014-2015
2015-2016
Note: Supporting papers such as audited reports, balance sheets, income tax returns, and
experience certificates from an officer not below the rank of the Executive Engineer,
shall be enclosed.
This sheet is to be detached and filled up and signed by chartered Accountant and submit
alongwith the balance sheets.
Signature of the Contractor.
Full Name:__________________
Seal of the CA Office. Signature of CA.
IRRI/IW-1068 (b)/ P-26
-27-
A P P E N D I X – 4
DETAILS OF EXPERIENCE IN _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _ _
(Details of Works During Last Five Years)
Sl.
No
Name of work Name
of employer and
address
Volume of
work
Nature of
work
Value
of the work
Time of
completion as
per agreement
Date of
award
Date
of completion
Bill amount
(Rs. in lakhs)
Reasons of
delay,
if any
Signature of Applicant:
Full Name ________________________
Note: Additional sheets may be enclosed.
IRRI/IW-1068 (b)/ P-27
-28-
A P P E N D I X – 5
SUMMARY SHEET: CURRENT CONTRACT COMMITMENTS/WORKS IN PROGRESS
Applicants should provide information on their current commitments on all contracts that have been awarded or for which a letter of
intent or acceptance has been received, or contracts approaching completion, but for which full completion certificate has yet to be issued.
Name of Applicant: - _________________________________________
Sl.No. Name of Contract Name of Client Contract Value Stipulated date
of completion
Bill already
paid (Rs. in
lakhs)
Value of
Outstanding
work
Estimated
completion
date
Signature of Applicant:
Full Name ________________________
IRRI/IW-1068 (b)/ P-28
Note: Additional sheets may be enclosed
-29-
A P P E N D I X – 6
PERSONNEL IN THE EMPLOYMENT OF THE TENDERER
Sl. Personnel Minimum Minimum Name Qualification Experience
No Qualification Requirement
required (numbers)
1. Project Manager Degree Holder
3 years Exp. 1
2. Site Engineer B.E.Civil-3
years Exp.*
1
3. Quality Control Dip. Civil 5 1
Personnel years Exp.*
4. No. of
Labourers
Skilled
Unskilled
* Contractor has to furnish undertakings from the technical personnel proposed to be engaged along with their attested technical qualification
and experience certificates.
The tenderer should also furnish the number of labourers both skilled and unskilled employed by the tenderer Signature of Applicant:
Full Name ________________________
IRRI/IW-1068 (b)/ P-29
-30-
APPEDNDIX – 7
FINANCIAL STATEMENT:-
(For Joint Venture Consortium, the Statement is to be given separately for each partner)
1. Name of firm
2. Capital
(a) Authorized:
(b) Issued and paid up:
3. Attach audited balance sheets and profit and loss statement for the past three years
4. Financial position:
(Exact amount in Rupees to be stated)
(a) Cash
(b) Current Assets
(c) Current Liabilities
(d) Working Capital
(e) Net Work
(a) Current ratio: Current Assets to current liabilities
(b) Acid test ratio: Cash, temporary investment held in lieu of cash and current receipt to
current liabilities.
Note: Information asked against each item to be carefully filled in Mere reference to
balance sheet concerning above points is not acceptable.
IRRI/IW-1068 (b)/ P-30
5. Total Liabilities
(c) Total liability to net work
________________________________________________________________________
-31-
APPENDIX – 7 (Continued)
7. Net profit before tax.
8. Applicant’s financial arrangements for the proposed work (exact amount in Rupees to be
mentioned).
6. Annual value of construction works undertaken for each of the last five years and
projected for current years:-
Year Current One year Two years Three years Four years Five years
before before years before before
before
Home
Abroad
(a) Current period
(b) During the last financial year
(c) During each of the four previous financial year
(a) Own Resource : Rs
(b) Bank Credits : Rs
(c) Other (Specify) : Rs
9. Certificate of financial soundness from Bankers of applicants
The profit and loss statement have been certify through by
together with their full
addresses:
10. Approximate value of work in hand: - Rs.
11. Value of anticipated order for next financial year
Home:
Abroad
IRRI/IW-1068 (b)/ P-31
-32-
-31(a)-
A P P E N D I X – 7(A)
Sl. No. Year Annual Turnover Working Capital
1. 2011 - 12
2. 2012 -13
3. 2013 -14
4. 2014-15
5. 2015-16
NB: This sheet is to be detached and filled up and signed by Chartered Accountant and submit
alongwith the balance sheets.
IRRI/IW-1068 (b)/ P-32
ABSTRACT OF BALANCE SHEETS TO BE GIVEN BY CHARTERED ACCOUNTANT ALONGWITH THE BALANCE SHEETS
-33-
- - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - -
- - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - - -
________________________________________________________________________
------------------------------------------------------------------------------------------------------------
-32-
A P P E N D I X – 8
LITIGATION
LITIGATION HISTORY:
Applicants should provide information in any history of litigation or arbitration resulting from
contracts executed or currently under execution
Name of Applicant: -
Year Award for or Name of Client Dispute amount Actual awarded
against the cause a litigation (current value in amount in
applicant and matter in Indian Rs.) Indian Rs.
dispute
Signature
Name in full__________________
IRRI/IW-1068 (b)/ P-33
-34-
-33-
A P P E N D I X – 8 (Continued)
INFORMATION REGARDING CURRENT LITIGATION, DEBARRING/EXPELLING OF TENDERER OR ABANDONMENT OF WORK BY TENDERER
1. (a) Does the Applicant or its constituent
partners have a consistent history of
litigation awarded against him? Yes/No
(b) If yes, give details:
2. (a) Has any work awarded to the Applicant
been subsequently withdrawn by any
agency in India? Yes/No
(b) If yes, give details:
3. (a) Has the Applicant or any of its constituent
partners abandoned any contract work in India? Yes/No
(b) If yes, give details:
4. (a) Has the Applicant or any of its constituent partners
been declared bankrupt during the last 5 years? Yes/No
(b) If yes, give details:
Note: If any information in this schedule is found to be incorrect or concealed prequalification
application will be summarily rejected.
Signature
Name in full__________________
IRRI/IW-1068 (b)/ P-34
-35-
-34-
CERTIFICATE
This is to certify that I have read the Terms and Conditions of the Detailed Tender Notice
issued by the Water Resources Department Vide No.
__________________________________Dt_______________ and I have quoted my rates
taking into consideration the recovery rates of stock materials as per current issue rate of the
Division and the terms and conditions as at page…… to …..of the above Detailed Tender Notice.
This is also to certify that I have also taken into consideration the Forest Royalty and
minor minerals.
Witness Signature of Contractor…………………………..
Signature……………………….. Name in Block Letters……………………………
……………………………………. ……………………………………………………..
…………………………………….. Registration No……………………………………
Address…………………………… Address………………………………PIN……………
Date Date
IRRI/IW-1068 (b)/ P-35
-36-
-35-
UNDERTAKING FORM_A
I do here by declare that the work will be done by myself and also declare that the signature in
all pages of the tender papers are signed by me.
Full name of contractor_____________________________
Full address _____________________________________
PIN _____________________________________
Registration No: __________________________________
IRRI/IW-1068 (b)/ P-36
-37-
-36-
Tender Documents for Sealed cover “B”
NAME OF WORK:
GROUP No. ITEMS OF ESTIMATED REMARKS
WORK AMOUNT
1 2 3 4
Contractor’s Signature
DETAIL
IRRI/IW-1068 (b)/ P-37
-38-
_______________________________
______________________________________________________________________________
______________________________________________________________________________
______________________________________________________________________________
__________________________________________________________
______________________________________________________________________________
______________________________________________________________________________
-37-
ANNEXURE – R
NAME OF WORK
ESTIMATED AMOUNT – RS_________________________________
GROUP No.___________________
LOCATION________________________________________________
I am/we are agreeable to execute the work for
___________________________________________________________________________ @
_______________(Rupees______________________________________________________as
per the Schedule of Rates
____and as per the Terms and Conditions of the Detailed Notice Inviting Tender taking into
consideration the recovery rates of issued materials and of Forest Royalty as per prevailing rate
and other taxes including VAT as applicable.
Witness:- Signature of the Contractor
……………………………………………. Name in Block letters……………………………….
……………………………………………. Address……………………………………………..
……………………………………………. ………………………………………………………
……………………………………………. Registration No:…………………………………….
Dated……………………………………... Telephone No:………………………………………
Dated………………………………………………..
Note:-
1. Delete which is not applicable with dated signature
2. The rate should be quoted legibly on figures as well as in words.
IRRI/IW-1068 (b)/ P-38