annexure a: acknowledgement form 4073... · web viewdeviations from and amendments to the documents...
TRANSCRIPT
Invitation to Tender/ Request for Proposal (RFP)
Unique Identifier
240-114238630
Revision
Rev 0
Revision Date
July 2019
Group Technology and Commercial
Enquiry no
CORP 4073
ESKOM HOLDINGS SOC LTD
INVITATION TO TENDER/REQUEST FOR PROPOSAL (RFP)
FOR
IT PROFESSIONAL SERVICES
ANNEXURES TO CORP 4073
CONTENTS OF ANNEXURES TO CORP 4073
1.Annexure A: Acknowledgement Form22.Annexure B: Tenderers Particulars83.Annexure C: Integrity Declaration Form114.Annexure D: Confirmation of Receipt of Addenda to The Enquiry165.Annexure E: Tax Evaluation Questionnaire176.Annexure F: Supplier B-BBEE And Shareholder Information187.Annexure G: Contract Conditions198.Annexure H: Technical Response Form (B2) (Excel Template)449.Annexure I: List Of Roles4510.Annexure J: Roles and Roles Description48
Invitation to Tender/ Request for Proposal (RFP)
Unique Identifier
240-114238630
Revision
Rev 0
Revision Date
July 2019
Group Technology and Commercial
Enquiry no
CORP 4073
Invitation to Tender/ Request for Proposal (RFP)
Unique Identifier
240-114238630
Revision
Rev 0
Revision Date
July 2019
Group Technology and Commercial
Enquiry no
CORP 4073
240-114238630 Invite to tender/ Request for proposal (RFP) CONFIDENTIAL TE Group Technology & Commercial
Effective July 2016
Page 1 of 2
ANNEXURES
1. Annexure A: Acknowledgement Form
Invitation to Tender/Request for Proposal No. CORP 4073 ________________________________
Name of company/JV: _______________________________________
Country of registration____________________________________
Name of contact person:___________________________________
Contact details of contact person:
Tel (landline) ______________________
Cell phone________________________
e-mail address_______________________
Acknowledgement:
We are in receipt of the Invitation to Tender/Proposal from Eskom Holdings SOC Ltd and the following addenda issued by Eskom:
-------------------------------------------------------------------------------------------------------------------------
We confirm that the documentation received by us is: (Indicate by ticking the box)
Correct as stated in the Invitation to Tender / RFP Content List, and that each document is complete.
Or:Incorrect or incomplete for the following reasons:
Cataloguing Acknowledgement:
[Please select the relevant statement by ticking the appropriate box below]:
We agree to provide the cataloguing information as described in the tender submission.
We have already supplied Eskom with the cataloguing information pertaining to this enquiry in a previous contract/order [insert previous invitation to tender/RFQ number] __________
We do not intend to provide the cataloguing information for the required scope / specifications. for the reasons stated hereunder:
_________________________________________________________________________________________________________________________________________________________________________________________________________
I confirm that I am a Distributor/Importer/Agent and my Principal, being the Original Equipment Manufacturer (OEM) is or is not in the position to supply cataloguing information for items. See attached letter from OEM confirming his position.
Single tenderers
I, the undersigned, _________________________________________(Full names) hereby confirm that I am duly authorised to sign all documents in connection with this tender and any contract resulting from it, on behalf of ___________________ (insert the full legal name of the tenderer).
Signature: _______________
Designation: ____________________
Date: _________________
Joint Ventures
We, the undersigned, are submitting this tender in Joint Venture and hereby authorise Mr/Ms _______________________________________(full names), an authorised signatory of _______________________________________, (insert the full legal name of the business entity serving as the lead partner) acting in the capacity of lead partner, to sign all documents in connection with the tender and any contract resulting from it on our behalf.
We attach to this Schedule a copy of the joint venture agreement which incorporates a statement that all partners are liable jointly and severally for the execution of the contract and that the lead partner is authorised to incur liabilities, receive instructions and payments and be responsible for the entire execution of the contract for and on behalf of any and all the partners.
Legal Name of Joint Venture Member
Full Name and Capacity of Authorised Signatory
Signature
240-114238630 Invite to tender/ Request for proposal (RFP) CONFIDENTIAL TE Group Technology & Commercial
Effective July 2016
Page 7 of 8
2. Annexure B: Tenderers Particulars
The tenderer must furnish the following particulars where applicable:
Indicate the type of tendering structure by marking with an X (where applicable provide registration number):
Individual tenderer
Unincorporated Joint venture (registration number for each member of the JV)
Incorporated JV
Other
Please complete the following:
Name of lead partner/member in case of JV
CIPC Registration Number (for each individual company / JV member)
VAT registration number (for each individual company / JV member)
CIDB registration number (for each individual company/JV member if applicable)
Shareholding information (for each individual company/JV member) clearly identifying percentages owned by individual shareholders (full names & ID Numbers) and other entity shareholders (provide full legal/trading name and respective identifying registration/trust numbers)
Include as separate tender returnable if required.
Contact person
Telephone number
E-mail address
Postal address (also of each member in the case of a JV)
Physical address (also of each member of the JV)
If subcontractors are to be used, indicate the following for the main subcontractor(s). Add to the list of applicable.
Name of contractor
CIPC Registration number
VAT registration number
CIDB Registration number (if applicable)
Shareholding organogram /breakdown (for each individual company/JV member) clearly identifying percentages owned by individual shareholders (full names& ID Numbers) and other entities (provide full legal/trading name and respective identifying registration/trust numbers)
Proposed Scope of work to be done by sub-contractor
Contact person
Telephone number
Fax number
E-mail address
Postal address
Physical address
If you are currently registered as a vendor with Eskom, please provide your Vendor registration number with Eskom.________________
If you are currently registered as a vendor on the Treasury Central Supplier Database(CSD) please provide your supplier registration number with Treasury_____________
Please note that it is mandatory for you to register on National Treasurys CSD, if you intend doing work with any State department or State owned entity/company.
You may register online at National Treasury website on www.treasury.gov.za
Alternatively, you may contact:
Name: Babalwa Mhlophe
Designation Middle Manager: SD&L
Signature: _______________
Date: ___________________
3. Annexure C: Integrity Declaration Form
Declaration Of Interest
I/We understand that any natural/legal person, including employees of the State and/or those related to an Eskom employee/director (as per the definition of related set out hereunder), may tender to Eskom. However, in view of possible allegations of favouritism (the practice of showing favour to, or giving preference to some person/group, to the detriment of, or at the expense of another that is entitled to equal treatment or an equal opportunity), should the resulting tender, or part thereof, be awarded to such natural/legal person, as described herein, it is required that the tenderer/s declare such interest/relationship where:-
the tenderer/s employees/directors are also employees/contractors/consultants/ directors in the state or a state-owned entity.
the tenderer/s employees/directors are also employees/contractors/consultants/ directors of Eskom
the tenderer/s employees/directors are also employees/contractors/consultants or directors in another entity together with Eskom employees/consultants/contractors/ directors
the legal person/s (including its employees/contractors/directors/members/ shareholders) on whose behalf the tender documents are signed, is in some other way related to an Eskom employee/contractor/consultant/director involved in the tender evaluation/tender adjudication/tender negotiation. Related meaning that:-
an individual is related to another individual of they are married, or live together in a relationship similar to marriage;
or are separated by no more than two degrees of natural or adopted consanguinity or affinity;
an individual is related to a juristic person if the individual directly or indirectly controls the juristic person, as determined in accordance with the definition of control (as per Companies Act section 2(1) ) ; and
a juristic person is related to another juristic person if :-
(1)either of them directly/indirectly controls the other, or the business of the other, as determined in accordance with the definition of control(as per Companies Act section 2(1) );
(2) either is a subsidiary of the other; or
(3)a person directly/indirectly controls each of them, or the business of each of them, as determined in accordance with the definition of control
the tenderer/s and one or more of the tenderers in this tendering/RFP process have a controlling partner in common, or a relationship with each other, directly or through common third parties, that puts them in a position to have access to information about or influence on the tender/proposal of another tenderer, or influence the decisions of Eskom regarding this bidding process;
To give effect to the provisions above, please complete the table hereunder with all required information.
Full Name & Capacity/ Position within tenderer (e.g. employee/Director/member/ owner/shareholder)
Identity Number
Confirm and provide details (including employee number) if you are a State/State owned entity employee/contractor/ director.
Full Names & Capacity/Position of Eskom employee/ director/ consultant and details of the relationship or interest(marital/
familial/personal/
financial etc.)
To your knowledge
is this person involved in the evaluation/
adjudication/
negotiation of tenders
If any employee/director/member/shareholder/owner of tenderer/s is also currently employed by Eskom, state whether this has been declared and whether there is authorisation(Y/N) to undertake remunerative work outside public sector employment, and attach proof to this declaration. _________________________
Do the tenderer/s and other tenderer in this tendering/RFP process share a controlling partner or have any relationship with each other, directly or through common third parties? (Y/N) If Yes, attach proof to this declaration.________________________
Declaration of fair tendering practices
This serves as a declaration that when goods/services are being procured, all reasonable steps have been taken to address and/or prevent the exploitation of the procurement process and the use of any unfair tendering practices.
A [tender/proposal] will be disqualified if the tenderer/s, or any of its directors have:
abused the institutions procurement process (e.g. bid rigging/collusion)
committed fraud or any other improper conduct in relation to such system.
Please complete the declaration with an X under YES or NO
Item
Question
Yes/No
No
1.1
Is the tenderer/s(or any of its directors/members/shareholders) listed on National Treasurys Database of Restricted Suppliers as companies/persons prohibited from doing business with the public sector, or listed on the Register for Tender Defaulters in terms of section 29 of the Prevention and Combatting of Corrupt Activities Act (No 12 of 2004)
The Database of Restricted Suppliers and the Register for Tender Defaulters can be accessed on the National Treasurys website (www.treasury.gov.za).
1.2
Was the tenderer/s (or any of its directors/members/shareholders) convicted by a court of law (including a court outside South Africa) for fraud and/or corruption with respect to the procurement/tendering processes/procedures during the past five years?
1.2.1
Provide details.
1.3
Was the tenderer/s(or any of its directors/members/shareholders) prohibited from doing business with any International Financial Development/funding Agency or Lending Institution
I, the undersigned, ________________________________________hereby confirm that I am duly authorised to sign all documents in connection with this tender and any contract resulting from it on behalf of ____________________________________ (insert the full legal name of the tenderer)
I declare that I have read and understood the provisions of the Supplier Integrity Pact, that all information furnished herein is correct, that it is understood that the tenderers tender/proposal may be rejected, and that Eskom will act against the tenderer should any aspect of this this declaration prove to be false.
Signature:
Designation and capacity in which signing:
Date:
Joint Ventures
I, the undersigned, ______________________________________________hereby confirm that acting in the capacity of lead partner, I am duly authorised to sign all documents in connection with the tender and any contract resulting from it on behalf of ______________________________________________________________(insert the full legal name of the JV ).
I declare that I have read and understood the provisions of the Supplier Integrity Pact, that all information furnished herein is correct, that it is understood that the JVs tender/proposal may be rejected, and that Eskom will act against the JV should any aspect of this this declaration prove to be false.
Signature:
Designation and capacity in which signing :
Date:
(A copy of the joint venture agreement which incorporates a statement that all partners are liable jointly and severally for the execution of the contract and that the lead partner is authorised to incur liabilities, receive instructions and payments and be responsible for the entire execution of the contract for and on behalf of any and all the partners is attached to the invitation to tender/Request for proposal).
4. Annexure D: Confirmation of Receipt of Addenda to The Enquiry
We confirm that the following communications received from the Employer before the submission of this proposal, amending the tender documents, have been taken into account in the proposal:
Item
Date Received
Title or Description
1.
2.
3.
4.
5.
6.
(Attach additional pages if more space is required)
__________________________________________________
Name and Designation
_____________________________________________________
Signature
5. Annexure E: Tax Evaluation Questionnaire
THE ATTACHED QUESTIONNAIRE TO BE COMPLETED AT CONTRACTING
6. Annexure F: Supplier B-BBEE And Shareholder Information
This template must be completed as instructed and returned as an excel file together with supporting attachments.
7. Annexure G: Contract Conditions
NEC3 Professional Services Contract (PSC3)
Contract between
Eskom Holdings SOC Ltd
(Reg No. 2002/015527/30)
and
A N Other
for
IT Professional Services and Turnkey projects
Insert title of the services
Contents:
Part C1
Agreements & Contract Data
Part C2
Pricing Data
Part C3
Scope of Work: The Scope
CONTRACT No.
PART C1:AGREEMENTS & CONTRACT DATA
Document reference
Title
C1.1
Form of Offer & Acceptance
C1.2a
Contract Data provided by the Employer
C1.2b
Contract Data provided by the Consultant
C1.1 Form of Offer & Acceptance
Offer
The Employer, identified in the Acceptance signature block, has solicited offers to enter into a contract for the procurement of:
IT Professional Services and Turnkey projects
The tenderer, identified in the Offer signature block, has
examined the draft contract as listed in the Acceptance section and agreed to provide this Offer.
By the representative of the tenderer, deemed to be duly authorised, signing this part of this Form of Offer and Acceptance the tenderer offers to perform all of the obligations and liabilities of the Consultant under the contract including compliance with all its terms and conditions according to their true intent and meaning for an amount to be determined in accordance with the conditions of contract identified in the Contract Data.
The offered total of the Prices exclusive of VAT is
Not Applicable Cost reimbursable
Value Added Tax @ 14% is
Not Applicable Cost reimbursable
The offered total of the Prices inclusive of VAT is
Not Applicable Cost reimbursable
This Offer may be accepted by the Employer by signing the Acceptance part of this Form of Offer and Acceptance and returning one copy of this document including the Schedule of Deviations (if any) to the tenderer before the end of the period of validity stated in the Tender Data, or other period as agreed, whereupon the tenderer becomes the party named as the Consultant in the conditions of contract identified in the Contract Data.
Signature(s)
Name(s)
Capacity
For the tenderer:
Name & signature of witness
Date
Acceptance
By signing this part of this Form of Offer and Acceptance, the Employer identified below accepts the tenderers Offer. In consideration thereof, the Employer shall pay the Consultant the amount due in accordance with the conditions of contract identified in the Contract Data. Acceptance of the tenderers Offer shall form an agreement between the Employer and the tenderer upon the terms and conditions contained in this agreement and in the contract that is the subject of this agreement.
The terms of the contract, are contained in:
Part C1Agreements and Contract Data, (which includes this Form of Offer and Acceptance)
Part C2Pricing Data
Part C3Scope of Work: The Scope
and drawings and documents (or parts thereof), which may be incorporated by reference into the above listed Parts.
Deviations from and amendments to the documents listed in the Tender Data and any addenda thereto listed in the Returnable Schedules as well as any changes to the terms of the Offer agreed by the tenderer and the Employer during this process of offer and acceptance, are contained in the Schedule of Deviations attached to and forming part of this Form of Offer and Acceptance. No amendments to or deviations from said documents are valid unless contained in this Schedule.
The tenderer shall within two weeks of receiving a completed copy of this agreement, including the Schedule of Deviations (if any), contact the Employers agent (whose details are given in the Contract Data) to arrange the delivery of any securities, bonds, guarantees, proof of insurance and any other documentation to be provided in terms of the conditions of contract identified in the Contract Data at, or just after, the date this agreement comes into effect. Failure to fulfil any of these obligations in accordance with those terms shall constitute a repudiation of this agreement.
Notwithstanding anything contained herein, this agreement comes into effect on the date when the tenderer receives one fully completed and signed original copy of this document, including the Schedule of Deviations (if any).
Signature(s)
Name(s)
Mr Sean Maritz
Capacity
CIO and Group Executive Group Information Technology Division (Acting)
for the Employer
Eskom Holdings SOC Ltd
Reg No. 2002/015527/30
Name & signature of witness
Date
C1.2 PSC3 Contract Data
Part one - Data provided by the Employer
Clause
Statement
Data
1
General
The conditions of contract are the core clauses and the clauses for main Option
G:Term contract
dispute resolution Option
W1:Dispute resolution procedure
and secondary Options
X1:Price adjustment for inflation
X2Changes in the law
X7:Delay damages
X9:Transfer of rights
X10Employers Agent
X11:Termination by the Employer
X18:Limitation of liability
Z:Additional conditions of contract
of the NEC3 Professional Services Contract (April 2013)[footnoteRef:2] [2: Available from Engineering Contract Strategies Tel 011 803 3008 Fax 011 803 3009 and www.ecs.co.za ]
If 2005 Edition is to be used delete April 2013 and replace with June 2005 with amendments June 2006. Always delete this note before finalising this Data
10.1
The Employer is (Name):
Eskom Holdings SOC Ltd (reg no: 2002/015527/30), a state owned company incorporated in terms of the company laws of the Republic of South Africa
Address
Registered office at Megawatt Park, Maxwell Drive, Sandton, Johannesburg
Tel No.
(011) 800 3361
11.2(9)
The services are
IT professional services and Turnkey projects
11.2(10)
The following matters will be included in the Risk Register
To be logged as and when identified
11.2(11)
The Scope is in
Part 3: Scope of Work
12.2
The law of the contract is the law of
the Republic of South Africa
13.1
The language of this contract is
English
13.3
The period for reply is
5 calendar days
13.6
The period for retention is
5 years following Completion or earlier termination.
2
The Parties main responsibilities
25.2
The Employer provides access to the following persons, places and things
access to
Eskom facilities
access date
As and when needed.
3
Time
31.2
The starting date is.
11.2(3)
The completion date for the whole of the services is.
31 May 2021
31.1
The Consultant is to submit a first programme for acceptance within
4 weeks of the Contract Date where applicable
32.2
The Consultant submits revised programmes at intervals no longer than
4 weeks where applicable.
4
Quality
40.2
The quality policy statement and quality plan are provided within
4 weeks of the Contract Date.
42.2
The defects date is
26 weeks after Completion of the whole of the services.
5
Payment
50.1
The assessment interval is
Between the 26th day of each successive month.
50.3
The expenses stated by the Employer are
Item
N/A
Amount
N/A
51.1
The period within which payments are made is
Within 30 days of the submission of the valid VAT invoice.
51.2
The currency of this contract is the
South African Rand.
51.5
The interest rate is
The publicly quoted prime rate of interest charged by Standard Bank of South Africa Limited at the time an amount payable in SA Rand was due.
6
Compensation events
There is no reference to Contract Data in this section of the core clauses and terms in italics used in this section are identified elsewhere in this Contract Data.
7
Rights to material
There is no reference to Contract Data in this section of the core clauses and terms in italics used in this section are identified elsewhere in this Contract Data.
8
Indemnity, insurance and liability
81.1
The amounts of insurance and the periods for which the Consultant maintains insurance are
Event
Cover
Period following Completion of the whole of the services or earlier termination
Liability for failure by the Consultant to use the skill and care normally used by professionals providing services similar to the services
Whatever the Consultant deems necessary in respect of each claim, without limit to the number of claims
See Notes to Consultants in Annexure A
death of or bodily injury to a person (not an employee of the Consultant) or loss of or damage to property arising from or in connection with the Consultants Providing the Services.
Whatever the Consultant deems necessary for any occurrence or series of occurrences arising out of one event without limit to the number of claims.
See Notes to Consultants in Annexure A
death of or bodily injury to employees of the Consultant arising out of and in the course of their employment in connection with this contract
As prescribed by the Compensation for Occupational Injuries and Diseases Act No. 130 of 1993 and the Consultants common law liability for people falling outside the scope of the Act with a limit of indemnity of not less than R500 000-00 (five hundred thousand) in respect of each claim, without limit to the number of claims
As Consultant deems necessary
81.1
The Employer provides the following insurances
Refer to Annexure A for details of insurance provided by the Employer.
82.1
The Consultants total liability to the Employer for all matters arising under or in connection with this contract, other than the excluded matters, is limited to
The total of the Prices
9
Termination
There is no reference to Contract Data in this section of the core clauses and terms in italics used in this section are identified elsewhere in this Contract Data.
10
Data for main Option clause
G
Term contract
21.4
The Consultant prepares forecasts of the total Time Charge and expenses at intervals no longer than
4 weeks.
11
Data for Option W1
W1.1
The Adjudicator is
the person selected from the ICE-SA Division (or its successor body) of the South African Institution of Civil Engineering Panel of Adjudicators by the Party intending to refer a dispute to him. (see www.ice-sa.org.za). If the Parties do not agree on an Adjudicator the Adjudicator will be appointed by the Arbitration Foundation of Southern Africa (AFSA).
W1.2(3)
The adjudicator nominating body is:
the Chairman of the ICE-SA Division (or its successor body) of the South African Institution of Civil Engineering. (See www.ice-sa.org.za).
W1.4(2)
The tribunal is:
arbitration
W1.4(5)
The arbitration procedure is
the latest edition of Rules for the Conduct of Arbitrations published by The Association of Arbitrators (Southern Africa) or its successor body.
The place where arbitration is to be held is
South Africa
The person or organisation who will choose an arbitrator
if the Parties cannot agree a choice or
if the arbitration procedure does not state who selects an arbitrator, is
the Chairman for the time being or his nominee of the Association of Arbitrators (Southern Africa) or its successor body.
12
Data for secondary Option clauses
X1
Price adjustment for inflation
X1.1
The index is
Year on Year CPI at time of Contract anniversary date, or as negotiated at renewal date.
X2
Changes in the law
X2.1
The law of the project is
South African Law
X7
Delay damages
X7.1
Delay damages for late Completion of the whole of the services are
In the case of a fixed cost deliverable, with set delivery/payment dates, the following will apply in the case of delays:
2.5 % of value of the Deliverable can be levied against the Consultant. The Consultant will be granted a grace period of 10 calendar days after the deemed end date of the deliverable/task order. On day 11 the delay damages will be invoked, after which 5 calendar days are given to resolve the issue. If not resolved on day 5, a further 2.5% delay damages will be invoked on day 21. The delay damages will be limited to 10% of the Deliverable value.
Furthermore, no delay damages shall be incurred should the delay result from circumstances outside of the control of the Consultant or due to the Employers act or omission. As such delay damages shall only apply where the delay results from the fault of the Consultant in delivering the Deliverable.
X9
Transfer of rights
All intellectual property owned by Consultant shall remain the sole and exclusive property of the Consultant and all intellectual property owned by Employer (including Employer proprietary software) shall remain the sole and exclusive property of Employer.
In relation to Employer proprietary software and other intellectual property and software owned by third parties and licences (subject to the consent of such licensor) to Employer, no title, licence or other similar rights therein or thereto shall pass to the Consultant.
Material prepared expressly and exclusively for the Employer shall vest in the Employer provided that the Employer has effected payment of the agreed charges in respect thereof to the Consultant. All intellectual property generally developed in the provision of the services shall vest in the Consultant.
X10
The Employers Agent
X10.1
The Employers Agent is
Name:
Frans Marais
Address
Eskom Holdings SOC Ltd
Megawatt Park
Maxwell Drive
Sunninghill
Sandton
2109
The authority of the Employers Agent is
to carry out all the actions of the Employer in this contract with the exception of those required by clauses 51.1 and 81.1.
X11
Termination by the Employer
For fixed cost deliverables only:
X11.1 The Employer may terminate the Consultants obligation to Provide the Services for a reason not stated in this contract by notifying the Consultant.
X11.2 If the Employer terminates for a reason not stated in this contract, an additional amount is due on termination which is 5% of the difference between
the forecast of the final total of the Prices in the absence of termination and
the total of the other amounts and costs included in the amount due on termination.
X18
Limitation of liability
X18.1
The Consultants liability to the Employer for indirect or consequential loss is limited to:
R0.00 (Zero Rand)
X18.2
The Consultants liability to the Employer for Defects that are not found until after the defects date is limited to:
The total of the Prices
X18.3
The end of liability date is
one year after Completion of the whole of the services/task order.
Z
The Additional conditions of contract are
Z1 to Z11 always apply.
Z1
Cession delegation and assignment
Z1.1
The Consultant does not cede, delegate or assign any of its rights or obligations to any person without the written consent of the Employer.
Z1.2
Notwithstanding the above, the Employer may on written notice to the Consultant cede and delegate its rights and obligations under this contract to any of its subsidiaries or any of its present divisions or operations which may be converted into separate legal entities as a result of the restructuring of the Electricity Supply Industry.
Z2
Joint ventures
Z2.1
If the Consultant constitutes a joint venture, consortium or other unincorporated grouping of two or more persons or organisations then these persons or organisations are deemed to be jointly and severally liable to the Employer for the performance of this contract.
Z2.2
Unless already notified to the Employer, the persons or organisations notify the Employer within two weeks of the Contract Date of the key person who has the authority to bind the Consultant on their behalf.
Z2.3
The Consultant does not alter the composition of the joint venture, consortium or other unincorporated grouping of two or more persons without the consent of the Employer having been given to the Consultant in writing.
Z3
Change of Broad Based Black Economic Empowerment (B-BBEE) status
Z3.1
Where a change in the Consultants legal status, ownership or any other change to his business composition or business dealings results in a change to the Consultants B-BBEE status, the Consultant notifies the Employer within seven days of the change.
Z3.2
The Consultant is required to submit an updated verification certificate and necessary supporting documentation confirming the change in his B-BBEE status to the Employer within thirty days of the notification or as otherwise instructed by the Employer.
Z3.3
Where, as a result, the Consultants B-BBEE status has decreased since the Contract Date the Employer may either re-negotiate this contract or alternatively, terminate the Consultants obligation to Provide the Services.
Z3.4
Failure by the Consultant to notify the Employer of a change in its B-BBEE status may constitute a reason for termination. If the Employer terminates in terms of this clause, the procedures on termination are those stated in core clause 91. The payment on termination includes a deduction of the forecast of the additional cost to the Employer of completing the whole of the services in addition to the amounts due in terms of core clause 92.1.
Z4
Ethics
Z4.1
Any offer, payment, consideration, or benefit of any kind made by the Consultant which constitutes or could be construed either directly or indirectly as an illegal or corrupt practice, as an inducement or reward for the award or in execution of this contract constitutes grounds for terminating the Consultants obligation to Provide the Services or taking any other action as appropriate against the Consultant (including civil or criminal action).
Z4.2
The Employer may terminate the Consultants obligation to Provide the Services if the Consultant (or any member of the Consultant where the Consultant constitutes a joint venture, consortium or other unincorporated grouping of two or more persons or organisations) is found guilty by a competent court, administrative or regulatory body of participating in illegal or corrupt practices.
Such practices include making of offers, payments, considerations, or benefits of any kind or otherwise, whether in connection with any procurement process or contract with the Employer or other people or organisations and including in circumstances where the Consultant or any such member is removed from the an approved vendor data base of the Employer as a consequence of such practice.
Z4.3
If the Employer terminates in terms of this clause, the procedures on termination are those stated in core clause 91. The payment on termination includes a deduction of the forecast of the additional cost to the Employer of completing the whole of the services in addition to the amounts due in terms of core clause 92.1.
Z5
Confidentiality
Z5.1
The Consultant does not disclose or make any information arising from or in connection with this contract available to Others. This undertaking does not, however, apply to information which at the time of disclosure or thereafter, without default on the part of the Consultant, enters the public domain or to information which was already in the possession of the Consultant at the time of disclosure (evidenced by written records in existence at that time). Should the Consultant disclose information to Others in terms of clause 23.1, the Consultant ensures that the provisions of this clause are complied with by the recipient.
Z5.2
If the Consultant is uncertain about whether any such information is confidential, it is to be regarded as such until notified otherwise by the Employer.
Z5.3
In the event that the Consultant is, at any time, required by law to disclose any such information which is required to be kept confidential, the Consultant, to the extent permitted by law prior to disclosure, notifies the Employer so that an appropriate protection order and/or any other action can be taken if possible, prior to any disclosure. In the event that such protective order is not, or cannot, be obtained, then the Consultant may disclose that portion of the information which it is required to be disclosed by law and uses reasonable efforts to obtain assurances that confidential treatment will be afforded to the information so disclosed.
Z5.4
The taking of images (whether photographs, video footage or otherwise) of the Employers project works or any portion thereof, in the course of Providing the Services and after Completion, requires the prior written consent of the Employer. All rights in and to all such images vests exclusively in the Employer.
Z6
Waiver and estoppel: Add to core clause 12.3:
Z6.1
Any extension, concession, waiver or relaxation of any action stated in this contract by the Parties, or the Adjudicator does not constitute a waiver of rights, and does not give rise to an estoppel unless the Parties agree otherwise and confirm such agreement in writing.
Z7
Provision of a Tax Invoice. Add to core clause 51
Z7.1
The Consultant (if registered in South Africa in terms of the companies Act) is required to comply with the requirements of the Value Added Tax Act, no 89 of 1991 (as amended) and to include the Employers VAT number 4740101508 on each invoice he submits for payment.
Z8
Notifying compensation events
Z8.1
Delete from the last sentence in core clause 61.3, unless the Employer should have notified the event to the Consultant but did not.
Z9
Employers limitation of liability
Z9.1
The Employers liability to the Consultant for the Consultants indirect or consequential loss is limited to R0.00 (zero Rand)
Z10
Termination: Add to core clause 90.1, at the second main bullet point, fourth sub-bullet point, after the words "against it":
Z10.1
or had a business rescue order granted against it.
Z11
Delay damages: Addition to secondary Option X7 Delay damages (if applicable in this contract)
Z11.1
If the Consultants payment of delay damages reaches the limits stated in this Contract Data for Option X7, the Employer may terminate the Consultants obligation to Provide the Services.
Z11.2
If the Employer terminates in terms of this clause, the procedures on termination are those stated in core clause 91. The payment on termination includes a deduction of the forecast of the additional cost to the Employer of completing the whole of the services in addition to the amounts due in terms of core clause 92.1.
Z12
Change in contact person details - Consultant
Z12.1
It is the Consultants responsibility to inform Eskom when there is a change in the Contact Persons details.
Z13
Resource and rates
Z13.1
Eskom reserves the right to negotiate resource rates per individual task order.
See Annexure A for base rates.
Z13.2
Eskom reserves the right to ask for new roles and new rates when needed.
Z14
SD&L obligations
Z14.1
See Annexure B
The Consultant will train 1 resource for every R5 million paid. It will apply cumulatively.
Skills development candidates shall be currently unemployed graduates from TVTCs (Technical and Vocational Training Colleges) universities or schools. These candidates shall also be representative of the population demographics of South Africa.
Z15
RFP responses
Z15.1
The number of CVs per submission per role will be limited to three (3) with each CV not exceeding 4 pages. If a panel member fails to submit a responsive bid, for a third time, the panel member will be removed from the panel for periods of 6 months.
Annexure A:Notes to Consultants
This is guidance to Consultants to assist their decision making about what cover to arrange in the insurance to be provided by the Consultant. The guidance is not part of the contract and the Employer carries no liability for it. The Consultant must obtain its own advice.
For the purpose of works contracts, insurance provided by Eskom (the Employer) has been arranged on the basis of project or contract value, where the value is the total of the Prices at Completion of the whole of the works including VAT.
A project is a collection of contracts or work packages to be undertaken as part of a single identified capital expansion or refurbishment of a particular asset or facility.
A contract is a single contract not linked to or being part of a project.
Further information and full details of all Eskom provided policies and procedures may be obtained from:
http://www.eskom.co.za/Tenders/InsurancePoliciesProcedures/Pages/EIMS_Policies_
From_1_April_2014_To_31_March_2015.aspx
The Insurance which the Consultant is to provide against his liability for claims made against him arising out of his failure to use reasonable skill and care (first row in the Insurance Table of clause 81.1 in the PSC3) should also indemnify the Consultant for those sums which he could become legally liable to pay as damages arising from any claim first made against him and reported to Insurers some time after Completion of the whole of the services. Hence the Consultant needs to ensure that his cover is in place at least until all his liabilities under the contract have expired. Such claims could arise out of any negligent act, error or omission committed or alleged to have been committed by the Consultant in the conduct of professional services in connection with the contract.
Annexure B:The Employers Panel of Adjudicators
The following persons listed in alphabetical order of their surname have indicated their willingness to be included in the Eskom Panel of Adjudicators. Their CVs may be obtained by using the contact details provided.
Name
Location
Contact details (phone & e mail)
Nigel ANDREWS
Gauteng
+27 11 836-6760
Andrew BAIRD
Gauteng
+27 11 803 3008
Christopher BINNINGTON
Gauteng
+27 11 888-6141
Peter HIGGINS
UK
+44 1293 873 868
Bruce LEECH
Gauteng
+27 11 290 4000
Nigel NILEN
Gauteng
+27 11 465 3601; [email protected]
Peter THURLOW
Gauteng
+27 11 787 6226
Information about the Panel and appointment of the selected Adjudicator is available from Eskom Supply Chain Operations management.
C1.2 Contract Data
Part two - Data provided by the Consultant
Clause
Statement
Data
10.1
The Consultant is (Name):
Contact person:
E-mail address
Tel No.
Fax No.
11.2(3)
The completion date for the whole of the services is
31 May 2021
11.2(10)
The following matters will be included in the Risk Register
To be logged as and when identified.
11.2(13)
The staff rates are:
See Annexure A
25.2
The Employer provides access to the following persons, places and things
access to
Eskom facilities
50.3
The expenses stated by the Consultant are as per Eskoms T&S standards.
Part 2: Pricing Data
PSC3 Option G
Document reference
Title
C2.1
Pricing assumptions : Option G
C2.2
Staff rates, expenses and the task schedule.
C2.1 Pricing assumptions: Option G
How work is priced and assessed for payment
From Option G: Term contract
Identified and defined terms
11
11.2
(17) The Price for Services Provided to Date is, for each Task, the total of
the Time Charge for work which has been completed on time based items on the Task Schedule and
a proportion of the lump sum price for each other item on the Task Schedule which is the proportion of work completed on that item.
(20) The Prices are
the Time Charge for items described as time based on the Task Schedule and
the lump sum price in the Task Schedule for each other item.
From the Core Clauses:
Identified and defined terms
11.2
(13) The Time Charge is the sum of the products of each of the staff rates multiplied by the total staff time appropriate to that rate properly spent on work in this contract.
and
Assessing the amount due
50.3
The amount due is
the Price for Services Provided to Date,
the amount of the expenses properly spent by the Consultant in Providing the Services and
other amounts to be paid to the Consultant less amounts to be paid by or retained from the Consultant.
Any tax which the law requires the Employer to pay to the Consultant is included in the amount due.
C2.2 Staff rates, expenses & the task schedule
The staff rates are:
See Annexure A
The expenses are (subject to change):
Kms:
Km Rate:
From workplace (i.e. Megawatt Park / Eskom Convention Centre) to the venue of Business appointment or meeting. Claims must specify distance travelled destination and purpose.
When Eskom provides offices for the duration of the contract, then kms from consultants office to Eskoms office cannot be claimed. Kms from the consultants home to Eskom office also cannot be claimed.
R3.18 per kilometre (effective 1 March 2016)
Car rentals:
All travellers may not hire vehicles from a category higher than Group B or an equivalent class. Group B vehicles contain the following specifications:
5 Door
Manual
Air Conditioning
Radio/CD
Power Steering
Airbags
Central Locking
ABS
Accommodation:
Domestic hotel accommodation may not exceed one thousand three hundred rand (R1 400), inclusive of VAT, per night per person (including dinner, breakfast and parking).
Cost of Meals:
Travelling on Eskom business: the cost of a meal should not exceed R142.50 (including VAT).
Alcoholic beverages cannot be claimed for.
Flights:
Economy class.
To be made and paid for by consultants. This must then be claimed back once a month together with all other T&S expenses on a VAT invoice.
Telephone calls:
When Eskom provides offices and telephone facilities, any telephone claims (cell phone) must be properly motivated. Claims will only be paid if call details are specified.
Part 3: Scope of Work
Document reference
Title
This cover page
C3.1
Employers Scope
C3.1: Employers scope
The scope of work is to supply IT resources and/or to deliver work on a Turnkey basis on an as and when needed basis.
There will be a full scope document for each request
Invoicing and payment
The following details shall be shown on or attached to each Invoice to show how the amount due has been assessed:
The Consultant shall address the tax invoice to Eskom Holdings SOC Ltd and include on it the following information:
Name and address of the Consultant and the Employers Agent;
The contract number and title;
Consultants VAT registration number;
The Employers VAT registration number 4740101508;
Total amount invoiced excluding VAT, the VAT and the invoiced amount including VAT;
(add other as required)
Invoices shall be mailed to [email protected]
Annexure A: Roles and Rates
Annexure B: SD&L Obligations
Skills Development Framework for ICT Professional service
Dear Supplier
As a condition of being awarded a contract by Eskom all suppliers are required to fulfil skills development obligations. Effective 01 June 2016, suppliers in the ICT professional service panel are required to comply with this requirement by taking on the responsibility of paying for the cost of skills development which may be undertaken by the training providers that are accredited by the MICT SETA.
Assignment of candidates
The supplier is required to assign one candidate for every R5, 000,000.00 (five million rand) of the cumulative contract amount paid. Contained in the table below, is the type of skills that must be developed over the five year contract duration. The assignment of candidates shall be carried out within one month of reaching or exceeding this threshold.
The supplier shall assign the candidates to the MICT SETA accredited training providers from which they shall be issued with certified qualifications as a proof of having attained the competency and proficiency in the skills listed in Table 1.
The supplier, before commencing with the skills development effort, shall select the skill types from the Table 1 and Eskom shall advise and confirm based on whether the targets have been reached.
Table 1: Skills Development for ICT Professional Services
No
Skill type
Number
1
Business architect
20
2
Data Architect
20
3
Information Security Business Analyst
5
4
Information Security Systems Analyst
5
5
Integration analyst
10
6
Integration Architect
10
7
Integration System Analyst
10
8
Mobility Solutions Architect
10
9
Performance Scripter - Senior
10
10
SAP ABAP Developer
10
11
SAP Technical Architect
15
12
SAP technical specialist
15
13
SAS Administrator
5
14
Senior BI Developer (SAP Business Objects and SAS Developers)
10
15
Senior SAP Basis Administrator
5
16
SharePoint Developer
5
17
Snr Application Technical/Server Specialist
10
18
Software Quality Specialist
10
19
Test Analyst Senior
10
20
Test Environment Specialist
5
Availability of candidates
Eskom and MICT SETA have lists of eligible students from which the suppliers may draw candidates for skills development. The candidates selected for skills development shall be currently unemployed graduates from TVTC (Technical and Vocational Training Centre) colleges, universities and matriculants.
These candidates shall be representative of the population demographics of South Africa.
Reporting
During contract award, the supplier shall be issued with the following two SD&L templates to track skills development commitments:
The implementation schedule template
The supplier data collection template
The skills development sheets of the implementation schedule template shall be completed by the supplier and submitted to the Supplier Development & Localisation: Monitoring & Reporting team (SD&L) each time new candidates are assigned for skills development.
Every quarter of the year, the supplier shall report to the Supplier Development & Localisation team in Eskom on the progress of fulfilling the skills development obligation by completing the skills development sheet of the supplier data collection template.
8. Annexure H: Technical Response Form (B2) (Excel Template)
This annexure is an excel template and must be completed as instructed. The completed template must be returned as an excel file together with supporting attachments.
9. Annexure I: List Of Roles
No
ROLE
1
Application Technical/Server Analyst
2
Application Technical/Server Lead
3
ARIS Specialist
4
BI Microsoft SSRS Developer
5
Business architect
6
Certified Ethical Hacker / Penetration Tester
7
Data Architect
8
Digital Certificate Scanning Specialist
9
Functional Tester - Junior
10
Functional Tester - Senior
11
Information Security Business Analyst
12
Information Security Crisis Management Specialist
13
Information Security Solution Architect
14
Information Security Systems Analyst
15
Integration analyst
16
Integration Architect
17
Integration business analyst
18
Integration Developer
19
Integration Message Analyst/Designer
20
Integration Solution Architect
21
Integration Specialist
22
Integration System Analyst
23
Integration Technical Architect
24
Integration Technical Specialist
25
Intermediate SAP Basis Administrator
26
Investigation & Digital Forensics Specialist
27
ISO/IEC 27001 Lead Auditor
28
IT Vulnerability Management Expert
29
Mobility Developer
30
Mobility Solutions Architect
31
Monitoring Analyst
32
Performance Scripter - Junior
33
Performance Scripter - Senior
34
Project Manager
35
SAP ABAP Developer
36
SAP Business Analyst
37
SAP Module Specialist
38
SAP PI Developer and architecture
39
SAP Technical Architect
40
SAP technical specialist
41
SAS / Netezza Administrator - Senior
42
SAS Administrator
43
Security Incident and Event Management (SIEM) and Security Operations Centre (SOC) Services Specialist
44
Senior BI Developer (SAP Business Objects and SAS Developers)
45
Senior BI Microsoft SSRS developers
46
Senior DBA
47
Senior Developer
48
Senior Monitoring Specialist
49
Senior SAP Basis Administrator
50
Senior SAS developers
51
Senior SharePoint Advisor
52
SharePoint Developer
53
Snr Application Technical/Server Specialist
54
Snr Java Developer/.Net/Delphi/Cobol
55
Snr Monitoring Developer
56
SOA Governance Specialist
57
Software Quality Specialist
58
Solution Architect
59
Systems Analyst
60
Technical Test Analyst
61
Test Analyst - Junior
62
Test Analyst - Senior
63
Test Automation - Junior
64
Test Automation - Senior
65
Test Environment Specialist
66
Test Manager - Intermediate
67
Test Manager - Senior
68
Senior Smart Plant Business Analyst
69
Senior Smart Plant Systems Analyst
70
Senior Smart Plant Developer
71
Senior Smallworld Systems Analyst
72
Senior Smallworld Developer
73
Senior Smallworld DBA
74
ESRi ArcGIS Designer
75
ESRi ArcGIS Developer and Configurator
76
Mobility Systems Analyst
77
CC&B Batch Scheduler
10. Annexure J: Roles and Roles Description
Project Manager
Manages Project Scope:
Plans scope management by documenting how the project scope will be defined, validated and controlled;
Collects requirements by determining, documenting and managing stakeholder needs and requirements;
Defines scope by developing a detailed description of the project and product;
Creates a Work Breakdown Structure by subdividing project deliverables and project work into smaller more manageable components;
Validates scope by formalising acceptance of the completed project deliverables.
Controls scope by monitoring the status of the project and product scope and managing changes to the scope baseline.
Manages Project Time:
Plans schedule management by establishing the policies, procedures and documentation for planning, developing, managing, executing and controlling the project schedule;
Defines activities by identifying and documenting the specific actions to be performed to produce the project deliverables;
Sequences activities by identifying and documenting relationships amongst the project activities;
Estimates activity resources by estimating the type and quantities of material, human resources, equipment or supplies required to perform each activity;
Estimates activity duration by estimating the number of work periods needed to complete individual activities with estimated resources;
Develops a schedule by analysing activity sequences, durations, resource requirements and schedule constraints to create the project schedule model;
Controls the schedule by monitoring the status of project activities to update project progress and manage changes to the schedule baseline to achieve the plan.
Manages Project Cost:
Plans cost management by establishing the policies, procedures and documentation for planning, managing, expending and controlling project costs;
Estimates cost by developing an approximation of the monetary resources needed to complete project activities;
Determines budget by aggregating the estimated costs of individual activities or work packages to establish an authorised cost baseline;
Controls cost by monitoring the status of the project to update the project costs and managing changes to the cost baseline.
Manages Project Quality:
Plans quality management by identifying quality requirements and I or standards for the project and its deliverables and documenting how the project will demonstrate compliance with the relevant quality requirements;
Performs quality assurance by auditing the quality requirements and the results from quality control measurements to ensure that appropriate quality standards and operational definitions are used;
Controls quality by monitoring and recording results of executing the quality activities to assess performance and recommend necessary changes.
Manages Project Risk:
Plans risk management by defining how to conduct risk management activities for a project;
Identifies risks by determining which risks may affect the project and documenting their characteristics;
Performs qualitative risk analysis by prioritising risks for further analysis or action by assessing and combining their probability of occurrence and impact;
Performs quantitative risk analysis by numerically analysing the effect of identified risks on overall project objectives;
Plans risk responses by developing options and actions to enhance opportunities and to reduce threats to project objectives;
Controls risks by implementing risk response plans, tracking identified risks, monitoring residual risks, identifying new risks and evaluating risk process effectiveness throughout the project.
Manages Project Stakeholders:
Identifies stakeholders by identifying the people, groups, organisations that could impact or be impacted by a decision, activity or outcome of the project, analysing and documenting relevant information regarding their interests, involvement, interdependencies, influence and potential impact on project success;
Plans stakeholder management by developing appropriate management strategies to effectively engage stakeholders throughout the project lifecycle, based on the analysis of their needs, interests and potential impact on project success;
Manages stakeholder engagement by communicating and working with stakeholders to meet their needs I expectations, address issues as they occur and foster appropriate stakeholder engagement in project activities throughout the project lifecycle;
Controls stakeholder engagement by monitoring overall project stakeholder relationships and adjusting strategies and plan for engaging stakeholders.
Manages Project Integration:
Develops the project charter by developing a document that formally authorises the existence of the project and provides the project manager with the authority to apply organisation resources to project activities;
Develops the project management plan by defining, preparing and coordinating all subsidiary plans and integrating them into a comprehensive project management plan;
Directs and manages project work by leading and performing the work defined in the project management plan and implementing approved changes to achieve the project's objectives;
Monitors and controls project work by tracking, reviewing and reporting the progress to meet the performance objectives defined in the project management plan;
Performs integrated change control by reviewing all change requests, approving changes and managing changes to deliverables, organisational process assets, project documents and the project management plan, and communicating their disposition;
Closes the project or the phase by finalising all activities across the all the project management process groups to formally complete the project or phase.
Manages Human Resources:
Plans human resource management by identifying and documenting project roles, responsibilities, required skills, reporting relationships and creating a staffing management plan;
Acquiring a project team by confirming human resource availability and obtaining the team necessary to complete project activities;
Develops the project team by improving competencies, team member interaction and overall team environment to enhance project performance;
Manages the project team by tracking team member performance, providing feedback, resolving issues and managing team changes to optimise project performance.
Manages Project Communication:
Plans communication management by developing an appropriate approach and plan for project communications based on stakeholder's information needs and requirements, and available organisational assets;
Manages communication by creating, collecting, distributing, storing, retrieving and the ultimate disposition of project information in accordance to the communications management plan;
Controls communication by monitoring and controlling communications throughout the entire project lifecycle to ensure the information needs of the project stakeholders are met.
Information Security
Functionality Evaluation criteria for: Certified Ethical Hacker I Penetration Tester
Evaluation Gatekeeper Criteria
Weighting
Number of years' experience the company has in business area relevant to the scope
15%
Number of years' experience of their human resources' relevant to the scope
15%
The respondent must provide a list of all reference clients their human resources have provided relevant Information Security services to in the last two (2) years and details of the service. Eskom reserves the right to validate the references.
20%
The respondent must produce proof of each proposed job roles that are accredited I certified members and in good standing with relevant recognised international bodies for a specific role(s) as per the scope. The bodies can include, but not limited to:
Global Information Assurance Certification (GIAC)
Council of Registered Ethical Security Testers (CREST)
International Systems Security Consortium (ISC2)
Information Systems Audit and Control Association (ISACA)
SABSA Certified Professional Architect (SCPA)
Sherwood Applied Business Security Architecture (SABSA)
20%
The respondent must indicate it's adopted Internationally recognised Information Security Governance I Standard framework. Provide the details thereof.
15%
The respondent must indicate the number of resources that they currently employ and will be available for the initiative as per the roles stipulated in the scope
15%
Total
100%
Functionality Evaluation criteria for: IT Vulnerability Management Expert
Evaluation Gatekeeper Criteria
Weighting
Number of years' experience the company has in business area relevant to the scope
15%
Number of years' experience of their human resources' relevant to the scope
15%
The respondent must provide a list of all reference clients their human resources have provided relevant Information Security services to in the last two (2) years and details of the service. Eskom reserves the right to validate the references.
20%
The respondent must produce proof of each proposed job roles that are accredited I certified members and in good standing with relevant recognised international bodies for a specific role(s) as per the scope. The bodies can include, but not limited to:
Global Information Assurance Certification (GIAC)
Council of Registered Ethical Security Testers (CREST)
International Systems Security Consortium (ISC2)
Information Systems Audit and Control Association (ISACA)
SABSA Certified Professional Architect (SCPA)
Sherwood Applied Business Security Architecture (SABSA)
20%
The respondent must indicate it's adopted Internationally recognised Information Security Governance I Standard framework. Provide the details thereof.
15%
The respondent must indicate the number of resources that they currently employ and will be available for the initiative as per the roles stipulated in the scope
15%
Total
100%
Functionality Evaluation criteria for: Security Incident and Event Management (SIEM) and Security Operations Centre (SOC) Services Specialist
Evaluation Gatekeeper Criteria
Weighting
Number of years' experience the company has in business area relevant to the scope
15%
Number of years' experience of their human resources' relevant to the scope
15%
The respondent must provide a list of all reference clients their human resources have provided relevant Information Security services to in the last two (2) years and details of the service. Eskom reserves the right to validate the references.
20%
The respondent must produce proof of each proposed job roles that are accredited I certified members and in good standing with relevant recognised international bodies for a specific role(s) as per the scope. The bodies can include, but not limited to:
Global Information Assurance Certification (GIAC)
Council of Registered Ethical Security Testers (CREST)
International Systems Security Consortium (ISC2)
Information Systems Audit and Control Association (ISACA)
SABSA Certified Professional Architect (SCPA)
Sherwood Applied Business Security Architecture (SABSA)
20%
The respondent must indicate it's adopted Internationally recognised Information Security Governance I Standard framework. Provide the details thereof.
15%
The respondent must indicate the number of resources that they currently employ and will be available for the initiative as per the roles stipulated in the scope
15%
Total
100%
Functionality Evaluation criteria for: Investigation & Digital Forensics Specialist
Evaluation Gatekeeper Criteria
Weighting
Number of years' experience the company has in business area relevant to the scope
15%
Number of years' experience of their human resources' relevant to the scope
15%
The respondent must provide a list of all reference clients their human resources have provided relevant Information Security services to in the last two (2) years and details of the service. Eskom reserves the right to validate the references.
20%
The respondent must produce proof of each proposed job roles that are accredited I certified members and in good standing with relevant recognised international bodies for a specific role(s) as per the scope. The bodies can include, but not limited to:
Global Information Assurance Certification (GIAC)
Council of Registered Ethical Security Testers (CREST)
International Systems Security Consortium (ISC2)
Information Systems Audit and Control Association (ISACA)
SABSA Certified Professional Architect (SCPA)
Sherwood Applied Business Security Architecture (SABSA)
20%
The respondent must indicate it's adopted Internationally recognised Information Security Governance I Standard framework. Provide the details thereof.
15%
The respondent must indicate the number of resources that they currently employ and will be available for the initiative as per the roles stipulated in the scope
15%
Total
100%
Functionality Evaluation criteria for: ISO/lEG 27001 Lead Auditor
Evaluation Gatekeeper Criteria
Weighting
Number of years' experience the company has in business area relevant to the scope
15%
Number of years' experience of their human resources' relevant to the scope
15%
The respondent must provide a list of all reference clients their human resources have provided relevant Information Security services to in the last two (2) years and details of the service. Eskom reserves the right to validate the references.
20%
The respondent must produce proof of each proposed job roles that are accredited I certified members and in good standing with relevant recognised international bodies for a specific role(s) as per the scope. The bodies can include, but not limited to:
Global Information Assurance Certification (GIAC)
Council of Registered Ethical Security Testers (CREST)
International Systems Security Consortium (ISC2)
Information Systems Audit and Control Association (ISACA)
SABSA Certified Professional Architect (SCPA)
Sherwood Applied Business Security Architecture (SABSA)
20%
The respondent must indicate it's adopted Internationally recognised Information Security Governance I Standard framework. Provide the details thereof.
15%
The respondent must indicate the number of resources that they currently employ and will be available for the initiative as per the roles stipulated in the scope
15%
Total
100%
Functionality Evaluation criteria for: Information Security Crisis Management Specialist
Evaluation Gatekeeper Criteria
Weighting
Number of years' experience the company has in business area relevant to the scope
15%
Number of years' experience of their human resources' relevant to the scope
15%
The respondent must provide a list of all reference clients their human resources have provided relevant Information Security services to in the last two (2) years and details of the service. Eskom reserves the right to validate the references.
20%
The respondent must produce proof of each proposed job roles that are accredited I certified members and in good standing with relevant recognised international bodies for a specific role(s) as per the scope. The bodies can include, but not limited to:
Global Information Assurance Certification (GIAC)
Council of Registered Ethical Security Testers (CREST)
International Systems Security Consortium (ISC2)
Information Systems Audit and Control Association (ISACA)
SABSA Certified Professional Architect (SCPA)
Sherwood Applied Business Security Architecture (SABSA)
20%
The respondent must indicate it's adopted Internationally recognised Information Security Governance I Standard framework. Provide the details thereof.
15%
The respondent must indicate the number of resources that they currently employ and will be available for the initiative as per the roles stipulated in the scope
15%
Total
100%
Functionality Evaluation criteria for: Information Security Business Analyst
Evaluation Gatekeeper Criteria
Weighting
Number of years' experience the company has in business area relevant to the scope
15%
Number of years' experience of their human resources' relevant to the scope
15%
The respondent must provide a list of all reference clients their human resources have provided relevant Information Security services to in the last two (2) years and details of the service. Eskom reserves the right to validate the references.
20%
The respondent must produce proof of each proposed job roles that are accredited I certified members and in good standing with relevant recognised international bodies for a specific role(s) as per the scope. The bodies can include, but not limited to:
Global Information Assurance Certification (GIAC)
Council of Registered Ethical Security Testers (CREST)
International Systems Security Consortium (ISC2)
Information Systems Audit and Control Association (ISACA)
SABSA Certified Professional Architect (SCPA)
Sherwood Applied Business Security Architecture (SABSA)
20%
The respondent must indicate it's adopted Internationally recognised Information Security Governance I Standard framework. Provide the details thereof.
15%
The respondent must indicate the number of resources that they currently employ and will be available for the initiative as per the roles stipulated in the scope
15%
Total
100%
Functionality Evaluation criteria for: Information Security Systems Analyst
Evaluation Gatekeeper Criteria
Weighting
Number of years' experience the company has in business area relevant to the scope
15%
Number of years' experience of their human resources' relevant to the scope
15%
The respondent must provide a list of all reference clients their human resources have provided relevant Information Security services to in the last two (2) years and details of the service. Eskom reserves the right to validate the references.
20%
The respondent must produce proof of each proposed job roles that are accredited I certified members and in good standing with relevant recognised international bodies for a specific role(s) as per the scope. The bodies can include, but not limited to:
Global Information Assurance Certification (GIAC)
Council of Registered Ethical Security Testers (CREST)
International Systems Security Consortium (ISC2)
Information Systems Audit and Control Association (ISACA)
SABSA Certified Professional Architect (SCPA)
Sherwood Applied Business Security Architecture (SABSA)
20%
The respondent must indicate it's adopted Internationally recognised Information Security Governance I Standard framework. Provide the details thereof.
15%
The respondent must indicate the number of resources that they currently employ and will be available for the initiative as per the roles stipulated in the scope
15%
Total
100%
Functionality Evaluation criteria for: Information Security Solution Architect
Evaluation Gatekeeper Criteria
Weighting
Number of years' experience the company has in business area relevant to the scope
15%
Number of years' experience of their human resources' relevant to the scope
15%
The respondent must provide a list of all reference clients their human resources have provided relevant Information Security services to in the last two (2) years and details of the service. Eskom reserves the right to validate the references.
20%
The respondent must produce proof of each proposed job roles that are accredited I certified members and in good standing with relevant recognised international bodies for a specific role(s) as per the scope. The bodies can include, but not limited to:
Global Information Assurance Certification (GIAC)
Council of Registered Ethical Security Testers (CREST)
International Systems Security Consortium (ISC2)
Information Systems Audit and Control Association (ISACA)
SABSA Certified Professional Architect (SCPA)
Sherwood Applied Business Security Architecture (SABSA)
20%
The respondent must indicate it's adopted Internationally recognised Information Security Governance I Standard framework. Provide the details thereof.
15%
The respondent must indicate the number of resources that they currently employ and will be available for the initiative as per the roles stipulated in the scope
15%
Total
100%
Functionality Evaluation criteria for: Digital Certificate Scanning Specialist
Evaluation Gatekeeper Criteria
Weighting
Number of years' experience the company has in business area relevant to the scope
15%
Number of years' experience of their human resources' relevant to the scope
15%
The respondent must provide a list of all reference clients their human resources have provided relevant Information Security services to in the last two (2) years and details of the service. Eskom reserves the right to validate the references.
20%
The respondent must produce proof of each proposed job roles that are accredited I certified members and in good standing with relevant recognised international bodies for a specific role(s) as per the scope. The bodies can include, but not limited to:
Global Information Assurance Certification (GIAC)
Council of Registered Ethical Security Testers (CREST)
International Systems Security Consortium (ISC2)
Information Systems Audit and Control Association (ISACA)
SABSA Certified Professional Architect (SCPA)
Sherwood Applied Business Security Architecture (SABSA)
20%
The respondent must indicate it's adopted Internationally recognised Information Security Governance I Standard framework. Provide the details thereof.
15%
The respondent must indicate the number of resources that they currently employ and will be available for the initiative as per the roles stipulated in the scope
15%
Total
100%
Test resources
Role
Years of Experience
Role description
Test Manager Senior
Between 6 and
11 years test management experience with greater than 11 years IT experience
On one major or more than one smaller initiative(s), oversee test analysts and testers in the analysing of requirements to establish test scenarios/business processes and determine test cases
Draft and/or oversee the creation and maintenance of test plans according to Eskom standards
Utilise HP QC for the management of testing
Install requirements traceability to test scenarios/test cases
Create and manage test schedules
Create and manage test approaches
Manage and report test defects
Manage manual and automation testers
Monitor and report on test coverage
Interface with and ensure all impacted parties are informed of progress, risks, and issues timeously
Guidance to Testing CoE teams on practices regarding solution test management
Training of test resources on solution testing best practices
Governance of compliance with test outputs and practices
Direction to customers of the Testing CoE regarding solution quality practices
Reviews of test repositories and the artefacts in them to ensure currency
Overseeing the updating of practices and processes re solution quality
Training on or education of updated solution quality practices etc.
Test Manager Intermediate
Less than 6 years test management experience
On one major or more than one smaller initiative(s), oversee test analysts and testers in the analysing of requirements to establish test scenarios/business processes and determine test cases
Draft and/or oversee the creation and maintenance of test plans according to Eskom standards
Utilise HP QC for the management of testing
Install requirements traceability to test scenarios/test cases
Create and manage test schedules
Create and manage test approaches
Manage and report test defects
Manage manual and automation testers
Monitor and report on test coverage
Interface with and ensure all impacted parties are informed of progress, risks, and issues timeously
Guidance to Testing CoE teams on practices regarding solution test management
Training of test resources on solution testing best practices
Governance of compliance with test outputs and practices
Direction to customers of the Testing CoE regarding solution quality practices
Reviews of test repositories and the artefacts in them to ensure currency
Overseeing the updating of practices and processes re solution quality
Training on or education of updated solution quality practices etc.
Test Analyst Senior
Greater than 5 years test analysis experience
Analyse requirements to establish test scenarios/business processes and determine test cases
Draft and/or oversee the creation and maintenance of test plans according to Eskom standards
Utilise HP QC for the management of testing
Install requirements traceability to test scenarios/test cases
Create and manage test schedules
Create and manage test approaches
Manage and report test defects
Manage manual and automation testers
Monitor and report on test coverage
Interface with and ensure all impacted parties are informed of progress, risks, issues
Test Analyst Junior
Between 3 and
5 years test analysis experience
Analyse requirements to establish test scenarios/business processes and determine test cases
Draft and/or oversee the creation and maintenance of test plans according to Eskom standards
Utilise HP QC for the management of testing
Install requirements traceability to test scenarios/test cases
Create and manage test schedules
Create and manage test approaches
Manage and report test defects
Manage manual and automation testers
Monitor and report on test coverage
Interface with and ensure all impacted parties are informed of progress, risks, issues
Functional Tester Senior
Greater than 3 years "tester" experience
Execute manual tests according to the defined test plans and schedules in accordance with Eskom standards
Log and track defects regarding testing
Report risks, issues and progress to test analysts/test manager
Ensure HP QC is updated with test status
Functional Tester Junior
Less than 3 years "tester" experience
Execute manual tests according to the defined test plans and schedules in accordance with Eskom standards
Log and track defects regarding testing
Report risks, issues and progress to test analysts/test manager
Ensure HP QC is updated with test status
Technical Test Analyst
Greater than 12 years IT experience
with+- 10
years Testing
related experience
Analyse requirements regarding test environments and after analysing project or support initiatives, map actual test usage of environments to available physical resources available to draft and/or oversee the usage of test environment plans
Recommend test environment usage extensions and evictions
Analyse test environment requirements to determine resource requirements and recommend the acquisition of test environment equipment
Create and manage test usage schedules
Define and verify test environment entry and exit criteria
Manage test lab usage and equipment
Produce reports on test environment usage highlighting issues and risks
Manage technical test analysts in the execution of their test environment duties
Interface with and ensure all impacted parties are informed of progress, risks, issues
Test Environment Specialist
Greater than 12 years IT experience with
+_ 10 years Testing related experience
A testing specialist with in-depth knowledge of all IT aspects with specialist knowledge of testing the usage management of test environments.
Will guide and on all testing matters especially test environment usage concepts, controls and measures
Definition of processes, practices, templates and guidelines relative to testing and test environment usage management.
Transfer of knowledge to other TCoE resources
Active role in TCoE guidance
Active in establishing test approaches and adoption of new test processes and legislative matters impacting testing.
Software Quality
Expert - Test
Subject Matter Expert(SME)
Greater than 20 years IT experience
with+- 12 years Testing
related experience
Oversee solution quality practice implementation and usage
Provide guidance and do skills transfer to Eskom core team.
Oversee continuous improvement of Solution Quality assurance
Governance of Solution Quality practices
Measurement of efficiency and effectiveness of quality practices
Guidance on effective and efficient Test approaches and test strategies
Assurance of applicability re Solution Quality Assurance practices
Ensuring all related intellectual capital is appropriately stored
Ensure impacting areas and processes are not going to negatively impact re-use of artefacts
Ensure synergies between TESTING COE teams are being optimally achieved
Identifying continuous improvements to solution quality practices, processes, standards and procedures and overseeing the adoption of these
Performance Scripter Senior
Greater than 10 years performance testing experience
Definition of performance test approach/method
Arrange and drive workshops with the clients and SMEs
Provide guidance on performance test automation including; which tests to be included in performance testing
Performance testing approach
Measure effectiveness of performance testing
Put in place processes and practices to ensure performance test scripts remain current
Guiding performance testers in the execution of their duties
Resolution of any issues which could impact performance testing
Ensure performance scripts are version managed
Arrange scheduling of performance tests
Test and debug performance test scripts
Verify and secure documentation re performance test scripts
Obtain approval from the relevant stakeholders for the completed performance tests
Schedule regular performance runs to ensure performance test scripts are current
Performance Scripter Junior
Less than 10 years performance testing experience
Definition of performance test approach/method
Arrange and drive workshops with the clients and SMEs
Provide guidance on performance test automation including:
which tests to be included in performance testing
Performance testing approach
Measure effectiveness of performance testing
Put in place processes and practices to ensure performance test scripts remain current
Guiding performance testers in the execution of their duties
Resolution of any issues which could impact performance testing
Ensure performance scripts are version managed
Arrange scheduling of performance tests
Test and debug performance test scripts
Verify and secure documentation re performance test scripts
Obtain approval from the relevant stakeh